Prerequisites for Certificate of Practical Completion Sample Clauses

Prerequisites for Certificate of Practical Completion. The Developer must ensure that before the issue of any Certificate of Practical Completion: (a) where relevant, copies of all necessary documents and Approvals issued by the Consent Authority or relevant accredited certifier acknowledging completion of a specific aspect of the Contribution Works have been delivered to the Council; and (b) copies of all other certificates, consents and Approvals required of any relevant Authority, whose certificate, consent or approval is required for the erection, use or occupancy of the Contribution Works (other than an Occupation Certificate for the Community Facility Work) have been delivered to the Council.
Sample 1Sample 2
AutoNDA by SimpleDocs
Prerequisites for Certificate of Practical Completion. Despite paragraph 1.19 in this Schedule 4, a Certificate of Practical Completion for a Contribution Works Portion may not issue unless and until: (a) where relevant copies of all necessary documents and Approvals issued by the Consent Authority or relevant accredited certifier acknowledging completion of the Contribution Works Portion, and if appropriate permitting use and occupation (if applicable) of the Contribution Works Portion, including an Occupation Certificate (if required) have been delivered to the Council; and (b) copies of all other certificates, consents and Approvals required of any relevant Authority, whose certificate, consent or approval is required for the erection, use or occupancy of that Contribution Works Portion have been delivered to the Council;
Sample 1Sample 2
Prerequisites for Certificate of Practical Completion. Despite clause 24.5 ("Independent Certifier to certify"), a Certificate of Practical Completion for the Works may not issue unless and until: (a) the Developer has given WSPT a survey prepared by a Surveyor showing that the Works are within the Premises; (b) the Independent Certifier has issued a certificate addressed to WSPT stating that the Works have been completed in accordance with the Documentation and otherwise in accordance with this deed; (c) all compliance reports have been delivered to the relevant Consent Authority and WSPT; (d) copies of all necessary documents and Approvals issued by the relevant Authority acknowledging completion of the Works, and permitting use and occupation of the Development (including a Compliance Certificate and an Occupation Certificate) have been delivered to WSPT; (e) copies of all other certificates (including any Part 4A Certificate and any Complying Development Certificate), consents and Approvals required of any relevant Authority, whose certificate, consent or approval is required for the erection, use or occupancy of each part of the Works have been delivered to WSPT; and (f) the ESD Consultant has certified to the Independent Certifier and WSPT that the WSPT ESD Principles as contained in the Environmental Guidelines have been incorporated, and reflected in the Final Plans and Specifications.
Sample 1

Related to Prerequisites for Certificate of Practical Completion

  • Certificate of Completion The Interconnection Customer shall provide the EDC with a completed copy of the Interconnection Agreement Certificate of Completion, including evidence of the electrical inspection performed by the local authority having jurisdiction. The evidence of completion of the electrical inspection may be provided on inspection forms used by local inspecting authorities. The Interconnection request shall not be finally approved until the EDC’s representative signs the Interconnection Agreement Certificate of Completion.

  • Certificate of Substantial Completion The Date of Substantial Completion of the Work or designated portion thereof is the Date certified by the City when construction is sufficiently complete, in accordance with the Contract Documents, so the City of Roanoke, Virginia (City or Owner) can occupy or utilize the Work or designated portion thereof for the use for which it is intended, as expressed in the Contract Documents. ITB NO.: PROJECT: CONTRACTOR: PROJECT OR DESIGNATED PORTION SHALL INCLUDE: The Work or portion thereof designated above performed under this Contract has been reviewed and found to be substantially complete. The Date of Substantial Completion of the Project or portion thereof designated above is hereby established as . The City will assume possession thereof at a.m./p.m. on that date. A list of items ("punch list"), prepared by the A/E and/or Director, Department of Public Works, to be completed or corrected by the Contractor, is attached hereto. The failure to include any items on such list does not alter the responsibility of the Contractor to complete all Work in accordance with the Contract Documents. The Contractor will complete any portion of the Work that is not substantially complete and will complete or correct the work on the punch list in accordance with the Contract Documents. The establishment of a date of substantial completion and/or the acceptance of the Work or designated portion thereof does not relieve the Contractor of any responsibility for any faulty materials or workmanship or operate to relieve the Contractor or its Surety from any obligation under the Contract with the City or the Performance Bond or Labor and Material Payment Bond. This Certificate is subject to the terms and conditions of the Contract Documents, including but not limited to Section 20.8 of the General Conditions. Contractor By Date City of Roanoke, Virginia City By Date CITY OF ROANOKE, VIRGINIA AFFIDAVIT OF PAYMENT OF CLAIMS By: This day personally appeared before me, , and, being by me first duly sworn states that all subcontractors and suppliers of labor and materials have been paid all sums due them for work performed or materials furnished in the performance of the Contract between the City of Roanoke, Virginia, and ,Contractor, dated , 20 , for or arrangements have been made by the Contractor satisfactory to such subcontractors and suppliers with respect to the payment of such sums as may be due from the Contractor to the subcontractors and suppliers. COMMONWEALTH OF VIRGINIA CITY/COUNTY OF I, , a Notary Public in and for the Commonwealth of Virginia, do hereby certify that , whose name is signed to the foregoing, has subscribed, sworn to and acknowledged the same before me this day of , 20 . Seal: Notary Public Registration #: My Commission Expires:

  • PREREQUISITES FOR PAYMENT The following applicable requirements shall be fulfilled in order to establish an employee's eligibility for sick leave benefits.

  • FINAL COMPLETION AND FINAL PAYMENT 9.9.1 Upon receipt of written notice that the Work is ready for final inspection and acceptance and upon receipt of a final Application for Payment, the Architect will promptly make such 9.9.2 Neither the final payment nor the remaining retained percentage shall become due until the Contractor submits to the Architect (1) an affidavit that all payrolls, bills for materials and equipment, and other indebtedness connected with the Work for which the State or its property might in any way be responsible, have been paid or otherwise satisfied; (2) consent of surety, if any, to final payment; (3) Other data establishing payment or satisfaction of all such obligations, including, but not limited to, receipts, releases, or other supporting documentation. and (4) final waivers of liens arising out of the Contract, to the extent and in such form as may be designated by the State. If any Subcontractor refuses to furnish a release or waiver required by the State, the Contractor may furnish a bond satisfactory to the State to indemnify him against any such lien. If any such lien remains unsatisfied after all payments are made, the Contractor shall refund to the State all moneys that the latter may be compelled to pay in discharging such lien, including all costs and reasonable attorneys' fees. 9.9.3 If, after Substantial Completion of the Work, final completion thereof is materially delayed through no fault of the Contractor or by the issuance of Change Orders affecting final completion, and the Architect so confirms, the State shall, upon application by the Contractor and certification by the Architect, and without terminating the Contract, make payment of the balance due for that portion of the Work fully completed and accepted. If the remaining balance for Work not fully completed or corrected is less than the retainage stipulated in the Contract Documents, and if bonds have been furnished as required by the Contract Documents, the written consent of the surety to the payment of the balance due for that portion of the Work fully completed and accepted shall be submitted by the Contractor to the Architect prior to certification of such payment. Such payment shall be made under the terms and conditions governing final payment, except that it shall not constitute a waiver of claims. 9.9.4 The making of final payment shall constitute a waiver of all claims by the State except those arising from: (a) unsettled liens, (b) faulty or defective Work appearing after Substantial Completion, (c) failure of the Work to comply with the requirements of the Contract Documents, or (d) terms of any special warranties required by the Contract Documents. 9.9.5 The acceptance of final payment shall constitute a waiver of all claims by the Contractor except those previously made in writing and identified by the Contractor as unsettled at the time of the final Application for Payment.

  • Governing Law; Submission to Process EXCEPT TO THE EXTENT THAT THE LAW OF ANOTHER JURISDICTION IS EXPRESSLY ELECTED IN A TRANSACTION DOCUMENT, THIS AGREEMENT AND THE OTHER TRANSACTION DOCUMENTS, SHALL BE GOVERNED BY AND CONSTRUED IN ACCORDANCE WITH THE INTERNAL LAWS OF THE STATE OF NEW YORK, WITHOUT REGARD TO PRINCIPLES OF CONFLICTS OF LAW. EACH OF BIONOVA AND SAVIA HEREBY IRREVOCABLY SUBMITS ITSELF AND EACH OTHER RELATED PERSON TO THE NON-EXCLUSIVE JURISDICTION OF THE STATE AND FEDERAL COURTS SITTING IN THE STATE OF NEW YORK AND THE COUNTY OF NEW YORK AND AGREES AND CONSENTS THAT SERVICE OF PROCESS MAY BE MADE UPON IT OR ANY OF ITS SUBSIDIARIES IN ANY LEGAL PROCEEDING RELATING TO THE TRANSACTION DOCUMENTS BY ANY MEANS ALLOWED UNDER NEW YORK OR FEDERAL LAW. EACH OF BIONOVA AND SAVIA IRREVOCABLY WAIVES, TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW, ANY OBJECTION THAT IT MAY NOW OR HEREAFTER HAVE TO THE LAYING OF THE VENUE OF ANY SUCH PROCEEDING BROUGHT IN SUCH A COURT AND ANY CLAIM THAT ANY SUCH PROCEEDING BROUGHT IN SUCH A COURT HAS BEEN BROUGHT IN AN INCONVENIENT FORUM.

  • Final Completion The full and final completion of all Work in accordance with the Contract Documents.

  • Drug-Free Workplace Certification As required by Executive Order No. 90-5 dated April 12, 1990, issued by the Governor of Indiana, the Company hereby covenants and agrees to make a good faith effort to provide and maintain a drug-free workplace at the Project Location. The Company will give written notice to the IEDC within ten (10) days after receiving actual notice that the Company, or an employee of the Company in the State of Indiana, has been convicted of a criminal drug violation occurring in the workplace. False certification or violation of this certification may result in sanctions including, but not limited to, suspension of payments under the Agreement, termination of the Agreement and/or debarment of contracting opportunities with the State for up to three (3) years. In addition to the provisions of the above paragraph, if the total amount set forth in the Agreement is in excess of $25,000.00, the Company agrees that it will provide a drug-free workplace by: A. Publishing and providing to all of its employees a statement notifying them that the unlawful manufacture, distribution, dispensing, possession or use of a controlled substance is prohibited in the Company’s workplace, and specifying the actions that will be taken against employees for violations of such prohibition;

  • New Application for Licensure Any time after the three-month period has lapsed from the Effective Date of this Agreement and Respondent has paid the Administrative Penalty set forth in Section III, Paragraph 1 of this Order, Respondent may apply for a new mortgage loan originator license or, as applicable, petition for the reinstatement of an MLO Activity Endorsement in any or all of the Participating States with the understanding that each State Mortgage Regulator reserves the rights to fully investigate such application for licensure or petition for reinstatement of an MLO Activity Endorsement and may either approve or deny such application or petition pursuant to the normal process for such licensing or endorsement investigations. No license application or petition described in this paragraph will be denied solely based on the facts, circumstances, or consensual resolution provided for in this Agreement. Respondent further agrees that Respondent must satisfy the Administrative Penalty provision prior to submitting an application for a new mortgage loan originator license or, as applicable, petition for the reinstatement of an MLO Activity Endorsement.

  • Office of Inspector General Investigative Findings Expert Review In accordance with Senate Bill 799, Acts 2021, 87th Leg., R.S., if Texas Government Code, Section 531.102(m-1)(2) is applicable to this Contract, Contractor affirms that it possesses the necessary occupational licenses and experience.

  • Substantial Completion 9.8.1 When the Contractor considers that the Work, or a designated portion thereof which has been accepted in writing to by the State, is substantially complete as defined in Subparagraph

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!