Privileges and Immunities of EBRD Sample Clauses

Privileges and Immunities of EBRD. Nothing in this Agreement shall be construed as a waiver, renunciation or other modification of any immunities, privileges or exemptions of EBRD accorded under the Agreement Establishing the European Bank for Reconstruction and Development, international convention or any applicable law. Notwithstanding the foregoing, EBRD has made an express submission to arbitration under Section 8.09(a) and accordingly, and without prejudice to its other privileges and immunities (including, without limitation, the inviolability of its archives), it acknowledges that it does not have immunity from suit and legal process under Article 5(2) of Statutory Instrument 1991, No. 757 (The European Bank for Reconstruction and Development (Immunities and Privileges) Order 1991), or any similar provision under English law, in respect of the enforcement of an arbitration award duly made against it as a result of its express submission to arbitration pursuant to Section 8.09(a).
Sample 1Sample 2Sample 3See All (19)
AutoNDA by SimpleDocs
Privileges and Immunities of EBRD. Nothing in this Agreement shall be construed as a waiver, renunciation or other modification of any immunities, privileges or exemptions of EBRD accorded under the Agreement Establishing the European Bank for Reconstruction and Development, international convention or any applicable law.
Sample 1Sample 2Sample 3See All (10)
Privileges and Immunities of EBRD. Nothing in this Agreement shall be construed as a waiver, renunciation or other modification of any immunities, privileges or exemptions of EBRD accorded under the Agreement Establishing the European Bank for Reconstruction and Development, international convention or any Applicable Law. Notwithstanding the foregoing, EBRD has made an express submission to arbitration under Section 12.09 (a) of the Agreement on Pledge of Bank Accounts and accordingly, and without prejudice to its other privileges and immunities (including, without limitation, the inviolability of its archives), it acknowledges that it does not have immunity from suit and legal process under Article 5(2) of Statutory Instrument 1991, No. 757 (The European Bank for Reconstruction and Development (Immunities and Privileges) Order 1991), or any similar provision under English law, in respect of the enforcement of an arbitration award duly made against it as a result of its express submission to arbitration pursuant to Section 12.09 (a) of the Agreement on Pledge of Bank Accounts.
Sample 1Sample 2See All (4)
Privileges and Immunities of EBRD. Nothing in this Agreement shall be construed as a waiver, renunciation or other modification of any immunities, privileges or exemptions of EBRD accorded under the Agreement Establishing the European Bank for Reconstruction and Development, international convention or any applicable law. Notwithstanding the foregoing, EBRD has made an express submission to arbitration under Section 5.08(a) and accordingly, and without prejudice to its other privileges and immunities (including, without limitation, the inviolability of its archives), it acknowledges that it does not have immunity from suit and legal process under Article 5(2) of Statutory Instrument 1991, No. 757 (The European Bank for Reconstruction and Development (Immunities and Privileges) Order 1991), or any similar provision under English law, in respect of the enforcement of an arbitration award duly made against it as a result of its express submission to arbitration pursuant to Section 5.08(a). Section 5.10. Successors and Assigns (a) This Agreement shall bind and inure to the benefit of the respective successors and assigns of the parties hereto, except that none of the Sponsor or the Participant may assign or otherwise transfer all or any part of its rights or obligations under this Agreement without the prior written consent of EBRD except in accordance with Article IV.
Sample 1
Privileges and Immunities of EBRD. Nothing in this Agreement shall be construed as a waiver, renunciation or other modification of any immunities, privileges or exemptions of EBRD accorded under the Agreement Establishing the European Bank for Reconstruction and Development, international convention or any applicable law. Notwithstanding the foregoing, EBRD has made an express submission to arbitration under Section 11.8(b), above, and accordingly, and without prejudice to its other privileges and immunities (including, without limitation, the inviolability of its archives), it acknowledges that it does not have immunity from suit and legal process under Article 5(2) of Statutory Instrument 1991, No. 757 (The European Bank for Reconstruction and Development (Immunities and Privileges) Order 1991), or any similar provision under English law, in respect of the enforcement of an arbitration award duly made against it as a result of its express submission to arbitration pursuant to Section 11.8(b). In witness whereof, the parties hereto have caused this Agreement to be executed as of the date first set forth above. GALATA ACQUISITION CORP. By: /s/ Kemal Kaya Name: Kemal Kaya Title: Chief Executive Officer In witness whereof, the parties hereto have caused this Agreement to be executed as of the date first set forth above. By: /s/ Axxxx Xxxxx Name: Axxxx Xxxxx Title: Chief Executive Officer In witness whereof, the parties hereto have caused this Agreement to be executed as of the date first set forth above. By: /s/ Yxxxxx Xxxxxx Name: Yxxxxx Xxxxxx Title: Managing partner In witness whereof, the parties hereto have caused this Agreement to be executed as of the date first set forth above. WRITTEN CONSENT PARTIES: By: /s/ Esra Unlauaslan Durgun Name: Esra Unlauaslan Durgun Title: an Individual In witness whereof, the parties hereto have caused this Agreement to be executed as of the date first set forth above. WRITTEN CONSENT PARTIES: AUTOTECH FUND II, L.P. By: /s/ Dxxxxx Xxxxxx Name: Dxxxxx Xxxxxx Title: Managing Director In witness whereof, the parties hereto have caused this Agreement to be executed as of the date first set forth above. WRITTEN CONSENT PARTIES: By: /s/ Oxxx Xxxxx Oktem Name: Oxxx Xxxxx Oktem Title: an Individual In witness whereof, the parties hereto have caused this Agreement to be executed as of the date first set forth above. WRITTEN CONSENT PARTIES: By: /s/ Sxxx Xxxxx Name: Sxxx Xxxxx Title: an Individual In witness whereof, the parties hereto have caused this Agreement to...
Sample 1

Related to Privileges and Immunities of EBRD

  • Liabilities and Indemnities The Sponsor shall indemnify the Participating Site and its Agents, against any reasonable claims, proceedings and related costs, expenses, losses, damages and demands to the extent they arise or result from the negligent acts or omissions of, or the wilful misconduct of the Sponsor, and/or contracted third party, in its performance of this Agreement or in connection with the Non-Interventional Study. The CRO shall indemnify the Participating Site and its Agents, against any reasonable claims, proceedings and related costs, expenses, losses, damages and demands to the extent they arise or result from the negligent acts or omissions of, or the wilful misconduct of the CRO, and/or contracted third party, in its performance of this Agreement or in connection with the Non-Interventional Study. The Sponsor and the CRO shall maintain all proper insurance arrangements to cover liabilities arising from their conduct in the Non-Interventional Study, in respect of any claims brought by or on behalf of a Non-Interventional Study Subject. The Sponsor and the CRO shall provide the Participating Site such evidence of their insurance maintained pursuant to clauses 5.1 and 5.2 as the Participating Site shall from time to time reasonably request. In no circumstances shall any Party be liable to another Party in contract, tort or delict (if the Participating Organisation is constituted in Scotland) (including negligence or breach of statutory duty) or otherwise howsoever arising or whatever the cause thereof, for any loss of profit, business, reputation, contracts, revenues or anticipated savings or for any special, indirect or consequential damage of any nature, which arises directly or indirectly from any default on the part of any other Party. Subject to Clauses 5.6 and 5.7 the Participating Organisation’s liability to the Sponsor and CRO arising out of or in connection with any breach of this Agreement or any act or omission of the Participating Organisation in connection with the performance of the Non-Interventional Study shall in no event exceed the amount of fees payable by the Sponsor or CRO to the Participating Organisation under this Agreement. [DELETE IF NOT APPLICABLE] In the case of equipment loaned to the Participating Organisation for the purposes of the Non-Interventional Study, the Participating Organisation’s liability for loss or damage to this equipment arising from its negligence shall exclude fair wear and tear and shall not exceed the value of the equipment. In respect of any wilful and/or deliberate breach by the Participating Organisation, or any breach of Clauses 6, 8, 10 or 11 the Participating Organisation’s liability to the Sponsor and CRO arising out of or in connection with the breach shall not exceed two times the value of the Agreement. Nothing in this Clause 5 shall operate so as to restrict or exclude the liability of any Party in relation to death or personal injury caused by the negligence or wilful misconduct of that Party or its Agents or employees, or to restrict or exclude any other liability of any Party that cannot be so restricted or excluded in law. Nothing in this Agreement will operate to limit or exclude any liability for fraud.

  • Liabilities and Remedies 8.6.1 Any breach by PNG, or PNG’s employees, agents or contractors, of the provisions of Sections 8.4 or 8.5 of this Attachment shall be deemed a material breach of this Agreement. In addition, if PNG or an employee, agent or contractor of PNG at any time breaches a provision of Sections 8.4 or 8.5 of this Attachment and such breach continues for more than ten (10) days after written notice thereof from Verizon, then, except as otherwise required by Applicable Law, Verizon shall have the right, upon notice to PNG, to suspend the license to use Verizon OSS Information granted by Section 8.5.1 of this Attachment and/or the provision of Verizon OSS Services, in whole or in part. 8.6.2 PNG agrees that Verizon would be irreparably injured by a breach of Sections 8.4 or 8.5 of this Attachment by PNG or the employees, agents or contractors of PNG, and that Verizon shall be entitled to seek equitable relief, including injunctive relief and specific performance, in the event of any such breach. Such remedies shall not be deemed to be the exclusive remedies for any such breach, but shall be in addition to any other remedies available under this Agreement or at law or in equity.

  • LIABILITIES AND INDEMNITY 5.1 In the event of any claim or proceeding in respect of personal injury made or brought against the Trust by a Clinical Trial Subject, the Sponsor shall indemnify the Trust, its servants, Agents and employees in accordance with the terms of the indemnity set out at Appendix 4 hereto. 5.2 Nothing in this clause 5 shall operate so as to restrict or exclude the liability of any Party in relation to death or personal injury caused by the negligence of that Party or its servants, Agents or employees or to restrict or exclude any other liability of any Party which cannot be so restricted or excluded in law. The CRO expressly disclaims any liability in connection with the Investigational Medicinal Product caused by or allegedly caused by the use or misuse of the Investigational Medicinal Product other than liability for death, personal injury or loss of or damage to property which liability is the result of negligence on the part of the CRO. 5.3 In no circumstances shall any Party be liable to another Party in contract, tort (including negligence or breach of statutory duty) or otherwise howsoever arising or whatever the cause thereof, for any loss of profit, business, reputation, contracts, revenues or anticipated savings for any special, indirect or consequential damage of any nature, which arises directly or indirectly from any default on the part of any other Party. 5.4 Subject to clauses 5.2 and 5.5, the Trust's liability to the Sponsor and CRO arising out of or in connection with any breach of this Agreement or any act or omission of the Trust in connection with the performance of the Clinical Trial shall in no event exceed in total the amount of fees payable by the Sponsor or CRO to the Trust under this Agreement. In the case of equipment loaned to the Trust for the purposes of the Clinical Trial, the Trust’s liability arising from its negligence shall exclude fair wear and tear and shall not exceed the value of the equipment. 5.5 In respect of any wilful and/or deliberate breach by the Trust, or any breach of clauses 6, 8 and/or 9, the Trust’s liability to the Sponsor and CRO arising out of or in connection with the breach shall not exceed in total twice the value of the contract. 5.6 The Sponsor will take out appropriate insurance cover or will provide an indemnity satisfactory to the Trust in respect of its potential liability under clause 5.1 above and such cover shall be for a minimum of £[…insert amount…] in respect of any one occurrence or series of occurrences arising from one event. The Sponsor shall produce to the Trust, on request, copies of insurance certificates, together with evidence that the policies to which they refer remain in full force and effect, or other evidence concerning the indemnity. The terms of any insurance or the amount of cover shall not relieve the Sponsor of any liabilities under this Agreement.

  • RESPONSIBILITIES OF CITY City or its representative shall issue all communications to Contractor. City has the authority to request changes in the work in accordance with the terms of this Agreement and with the terms in Exhibit A – Scope of Work. City has the authority to stop work or to suspend any work.

  • Liabilities of the Manager A. In the absence of willful misfeasance, bad faith, gross negligence, or reckless disregard of obligations or duties hereunder on the part of the Manager, the Manager shall not be subject to liability to the Trust or the Fund or to any shareholder of the Fund for any act or omission in the course of, or connected with, rendering services hereunder or for any losses that may be sustained in the purchase, holding or sale of any security by the Fund. B. Notwithstanding the foregoing, the Manager agrees to reimburse the Trust for any and all costs, expenses, and counsel and trustees’ fees reasonably incurred by the Trust in the preparation, printing and distribution of proxy statements, amendments to its Registration Statement, holdings of meetings of its shareholders or trustees, the conduct of factual investigations, any legal or administrative proceedings (including any applications for exemptions or determinations by the Securities and Exchange Commission) which the Trust incurs as the result of action or inaction of the Manager or any of its affiliates or any of their officers, directors, employees or stockholders where the action or inaction necessitating such expenditures (i) is directly or indirectly related to any transactions or proposed transaction in the stock or control of the Manager or its affiliates (or litigation related to any pending or proposed or future transaction in such shares or control) which shall have been undertaken without the prior, express approval of the Trust’s Board of Trustees; or, (ii) is within the control of the Manager or any of its affiliates or any of their officers, directors, employees or stockholders. The Manager shall not be obligated pursuant to the provisions of this Subparagraph 7.B., to reimburse the Trust for any expenditures related to the institution of an administrative proceeding or civil litigation by the Trust or a shareholder seeking to recover all or a portion of the proceeds derived by any stockholder of the Manager or any of its affiliates from the sale of his shares of the Manager, or similar matters. So long as this Agreement is in effect, the Manager shall pay to the Trust the amount due for expenses subject to this Subparagraph 7.B. within 30 days after a xxxx or statement has been received by the Manager therefor. This provision shall not be deemed to be a waiver of any claim the Trust may have or may assert against the Manager or others for costs, expenses or damages heretofore incurred by the Trust or for costs, expenses or damages the Trust may hereafter incur which are not reimbursable to it hereunder. C. No provision of this Agreement shall be construed to protect any trustee or officer of the Trust, or director or officer of the Manager, from liability in violation of Sections 17(h) and (i) of the 1940 Act.

  • Liabilities of the Adviser A. In the absence of willful misfeasance, bad faith, gross negligence, or reckless disregard of obligations or duties hereunder on the part of the Adviser, the Adviser shall not be subject to liability to the Trust or the Fund or to any shareholder of the Fund for any act or omission in the course of, or connected with, rendering services hereunder or for any losses that may be sustained in the purchase, holding or sale of any security by the Fund. B. Notwithstanding the foregoing, the Adviser agrees to reimburse the Trust for any and all costs, expenses, and counsel and trustees’ fees reasonably incurred by the Trust in the preparation, printing and distribution of proxy statements, amendments to its Registration Statement, holdings of meetings of its shareholders or trustees, the conduct of factual investigations, any legal or administrative proceedings (including any applications for exemptions or determinations by the Securities and Exchange Commission) which the Trust incurs as the result of action or inaction of the Adviser or any of its affiliates or any of their officers, directors, employees or stockholders where the action or inaction necessitating such expenditures (i) is directly or indirectly related to any transactions or proposed transaction in the stock or control of the Adviser or its affiliates (or litigation related to any pending or proposed or future transaction in such shares or control) which shall have been undertaken without the prior, express approval of the Trust’s Board of Trustees; or, (ii) is within the control of the Adviser or any of its affiliates or any of their officers, directors, employees or stockholders. The Adviser shall not be obligated pursuant to the provisions of this Subparagraph 6.B., to reimburse the Trust for any expenditures related to the institution of an administrative proceeding or civil litigation by the Trust or a shareholder seeking to recover all or a portion of the proceeds derived by any stockholder of the Adviser or any of its affiliates from the sale of his shares of the Adviser, or similar matters. So long as this Agreement is in effect, the Adviser shall pay to the Trust the amount due for expenses subject to this Subparagraph 6.B. within thirty (30) days after a xxxx or statement has been received by the Adviser therefore. This provision shall not be deemed to be a waiver of any claim the Trust may have or may assert against the Adviser or others for costs, expenses or damages heretofore incurred by the Trust or for costs, expenses or damages the Trust may hereafter incur which are not reimbursable to it hereunder. C. No provision of this Agreement shall be construed to protect any trustee or officer of the Trust, or director or officer of the Adviser, from liability in violation of Sections 17(h) and (i) of the 1940 Act.

  • Activities of JCM The services of JCM to the Trust hereunder are not to be deemed to be exclusive, and JCM and its affiliates are free to render services to other parties. It is understood that trustees, officers and shareholders of the Trust are or may become interested in JCM as directors, officers and shareholders of JCM, that directors, officers, employees and shareholders of JCM are or may become similarly interested in the Trust, and that JCM may become interested in the Trust as a shareholder or otherwise.

  • Liabilities of the Company Except as stated in this Section 8, the Company shall have no liability for damages of any kind arising out of or related to events, acts, rights or privileges contemplated in this Agreement. a. The liability of the Company for damages resulting in whole or in part from or arising in connection with the furnishing of Service under this Agreement including, but not limited to, mistakes, omissions, interruptions, delays, errors or other defects or misrepresentations shall not exceed an amount equal to the charges under this Agreement applicable to the specific call (or portion thereof) that was affected. No other liability shall attach to the Company. b. The Company shall not be liable for any failure of performance hereunder due to causes beyond its control, including, but not limited to: (1) acts of God, fires, flood or other catastrophes; (2) any law, order, regulation, directive, action or request of the United States Government, or any other government, including state and local governments having jurisdiction over the Company, or of any department, agency, bureau, corporation or other instrumentality of any one or more of said governments, or of any civil or military authority; or (3) national emergencies, insurrections, riots, wars or other labor difficulties. c. The Company shall not be liable for any act or omission of any other entity furnishing facilities, equipment, or services used by a Customer, with the Company's Services. In addition, the Company shall not be liable for any damages or losses due to the failure or negligence of any customer or due to the failure of customer provided equipment, facilities or services.

  • Responsibilities of the District 12.1. The District shall examine the documents submitted by the Architect and shall render decisions so as to avoid unreasonable delay in the process of the Architect’s Services. 12.2. The District shall verbally or in writing advise Architect if the District becomes aware of any fault or defect in the Project, including any errors, omissions or inconsistencies in the Architect’s documents. Failure to provide such notice shall not relieve Architect of its responsibility therefore, if any. 12.3. Unless the District and Architect agree that a hazardous materials consultant shall be a Consultant of the Architect, the District shall furnish the services of a hazardous material consultant or other consultants when such services are requested in writing by Architect and deemed necessary by the District or are requested by the District. These services shall include: asbestos and lead paint survey; abatement documentation; and specifications related to said matters, which are to be incorporated into bid documents prepared by Architect. If the hazardous materials consultant is furnished by the District and is not a Consultant of the Architect, the specifications shall include a note to the effect that the hazardous materials consultant’s specifications are included in the Architect’s bid documents for the District’s convenience and have not been prepared or reviewed by the Architect. The note shall also direct questions about the hazardous materials consultant’s specifications related to asbestos and lead paint survey and/or abatement documentation to the preparer of the hazardous materials consultant’s specifications.

  • LIABILITIES OF THE PARTIES 11.1. The Parties acknowledge that the Seller has a legitimate interest in ensuring prompt payment under the Contract. Should the Buyer breach the terms of payment stipulated in Clause 6 of the Contract and corresponding additional agreements, the Buyer shall pay to the Seller liquidated damages of 0.05% of the amount outstanding per full calendar day of the payment delay. Should the Buyer fail to make 100% payment of Goods cost within 2 days of the time stipulated for payment, the Seller has the right, at its sole discretion, to terminate the Contract by written notice to the Buyer and without further liability upon the Seller. Should the Buyer breach the terms of signing of additional agreements both on provisional price and on final one, and the terms of fulfillment of final settlement, indicated in cl.8.3, the Seller reserves the right at its sole discretion, not to nominate the future Goods lots with further postponement of the delivery or decrease of the whole amount under the current Contract and / or to terminate the Contract without further liability upon the Seller. The Seller and the Buyer are relieved from any responsibility for the partial or complete default of their obligations under the Supply Сontract, if they prove by the documents that proper fulfillment of their obligations became impossible due to shut-down, unscheduled repairs of JSC Naftan OR facilities or due to force-majeure occurrence. The Parties shall bear no responsibility for the failure to properly fulfil their obligations under the Contract by virtue of provisions of law or other laws and regulations (other documents binding for the Seller / consignor) currently in force that prevent the Contract fulfilment, adopted by the respective state authorities or organizations and Belarusian State Concern of Oil and Chemistry (Belneftekhim concern) in particular, in case they were adopted (published) after the Contract signing and directly affect its fulfillment. 11.2. The Parties acknowledge that the Seller has a legitimate interest in ensuring prompt and full loading of the stipulated quantity of Goods and that any failure of the Buyer to load the full quantity of Goods at the time specified in the Contract could cause the Seller significant loss and inconvenience. In particular, the Buyer understands that any such failure may cause the Seller to incur costs including, but not limited to, terminal storage charges, railway demurrage and / or infrastructure charges, and / or vessel demurrage in respect of other vessels. Accordingly, should the Buyer fail to load the full quantity of Goods at the time specified in the Contract: 11.2.1. the final price (Pr(F)) of the Goods shall be increased by 0,05% of the Contract value of the unlifted goods, per full calendar day of delay in lifting; and 11.2.2. the Seller shall have the right, at its sole discretion, to cancel the delivery of the unlifted Goods and / or to terminate the Contract without further liability upon the Seller. 11.2.3. Сompensates to the Seller losses suffered, including, but not limited to the following: charges of the Seller for storage of the Goods in the tanks of the terminal and in tanks of park of Ministry of Railways, charges of the Seller for using an infrastructure of the railways, other connected with this charges including demurrage claims of other vessels. 11.3. The Buyer shall exercise reasonable efforts to ensure that: 11.3.1. for vessels carrying persistent oil products as cargo, the vessel carries on board a certificate of insurance as described in the Civil Liability Convention for Oil Pollution Damage; and 11.3.2. the vessel has in place insurance cover for oil pollution no less in scope and amounts than available under the Rules of P&I Clubs entered into the International Group of P&I Clubs. 11.3.3. the vessel shall comply with the requirements of the International Ship and Port Facility Security Code and the relevant amendments to chapter XI of SOLAS (ISPS Code). 11.4. The Seller shall procure that the loading port/terminal/installation shall comply with the requirements of the International Ship and Port Facility Security Code and the relevant amendments to Chapter XI of SOLAS (ISPS Code).

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!