Procedure for taking possession - The Promoter, upon obtaining the occupancy certificate* from the competent authority shall offer in writing the possession of the [Apartment/Plot], to the Allottee in terms of this Agreement to be taken within two months from the date of issue of occupancy certificate. [Provided that, in the absence of local law, the conveyance deed in favour of the allottee shall be carried out by the promoter within 3 months from the date of issue of occupancy certificate]. The Promoter agrees and undertakes to indemnify the Allottee in case of failure of fulfilment of any of the provisions, formalities, documentation on part of the Promoter. The Allottee, after taking possession, agree(s) to pay the maintenance charges as determined by the Promoter/association of allottees, as the case may be after the issuance of the completion certificate for the project. The promoter shall hand over the occupancy certificate of the apartment/plot, as the case may be, to the allottee at the time of conveyance of the same.
PROCEDURE FOR APPROVAL OF SETTLEMENT Acceptance of this Settlement Agreement shall be sought at a hearing of the Central Regional Council of the MFDA on a date agreed to by counsel for Staff and the Respondent.
Procedure for Rebate The Association represents to the Board that an internal rebate procedure has been established in accordance with Section 4117.09(C) of the Revised Code and that a procedure for challenging the amount of the representation fee has been established and will be given to each member of the bargaining unit who does not join the Association and that such procedure and notice shall be in compliance with all applicable state and federal laws and the Constitutions of the United States and the State of Ohio.
Procedure for Offer Subject to the terms hereof, Landlord shall notify Tenant (the “First Offer Notice”) prior to entering into any lease with a third party for the First Offer Space, which notice shall outline the base rent, allowance amounts if any, length of term, and other economic terms on which Landlord would be willing to lease the First Offer Space (as set forth in such proposal) to Tenant (the “Fundamental Terms”). Pursuant to such First Offer Notice, Landlord shall offer to lease to Tenant the applicable First Offer Space on the Fundamental Terms.
Procedure for Payment Whenever a payment for fractional Rights, Preferred Shares or Common Shares is to be made by the Rights Agent pursuant to this Agreement, the Company will (i) promptly prepare and deliver to the Rights Agent a certificate setting forth in reasonable detail the facts related to such payment and the prices or formulas utilized in calculating such payments; and (ii) provide sufficient monies to the Rights Agent to make such payments. The Rights Agent will be fully protected in relying upon such certificate and will have no duty with respect thereto, and will not be deemed to have knowledge of any payment for fractional Rights, Preferred Shares or Common Shares pursuant to this Agreement unless and until the Rights Agent has received such certificate and sufficient monies.
Procedure for Change of Scope 16.2.1 In the event of the Authority determining that a Change of Scope is necessary, it shall issue to the Concessionaire a notice specifying in reasonable detail the works and services contemplated thereunder (the “Change of Scope Notice”). 16.2.2 Upon receipt of a Change of Scope Notice, the Concessionaire shall, with due diligence, provide to the Authority such information as is necessary, together with preliminary Documentation in support of: (a) the impact, if any, which the Change of Scope is likely to have on the Project Completion Schedule if the works or services are required to be carried out during the Construction Period; and (b) the options for implementing the proposed Change of Scope and the effect, if any, each such option would have on the costs and time thereof, including a detailed breakdown by work classifications specifying the material and labour costs calculated in accordance with the schedule of rates applicable to the works assigned by the Authority to its contractors, along with the proposed premium/discount on such rates; provided that the cost incurred by the Concessionaire in providing such information shall be reimbursed by the Authority to the extent such cost is certified by the Independent Engineer as reasonable. 16.2.3 Upon receipt of information set forth in Clause 16.2.2, if the Authority decides to proceed with the Change of Scope, it shall convey its preferred option to the Concessionaire, and the Parties shall, with assistance of the Independent Engineer, thereupon make good faith efforts to agree upon the time and costs for implementation thereof. Upon reaching an agreement, the Authority shall issue an order (the “Change of Scope Order”) requiring the Concessionaire to proceed with the performance thereof. In the event that the Parties are unable to agree, the Authority may, by issuing a Change of Scope Order, require the Concessionaire to proceed with the performance thereof pending resolution of the Dispute, or carry out the works in accordance with Clause 16.5. 16.2.4 The provisions of this Agreement, insofar as they relate to Construction Works and Tests, shall apply mutatis mutandis to the works undertaken by the Concessionaire under this Article 16.
Procedure for Notification To obtain indemnification under this Agreement in respect of an Indemnifiable Claim or Indemnifiable Loss, Indemnitee shall submit to the Company a written request therefor, including a brief description (based upon information then available to Indemnitee) of such Indemnifiable Claim or Indemnifiable Loss. If, at the time of the receipt of such request, the Company has directors’ and officers’ liability insurance in effect under which coverage for such Indemnifiable Claim or Indemnifiable Loss is potentially available, the Company shall give prompt written notice of such Indemnifiable Claim or Indemnifiable Loss to the applicable insurers in accordance with the procedures set forth in the applicable policies. The Company shall provide to Indemnitee a copy of such notice delivered to the applicable insurers, and copies of all subsequent correspondence between the Company and such insurers regarding the Indemnifiable Claim or Indemnifiable Loss, in each case substantially concurrently with the delivery or receipt thereof by the Company. The failure by Indemnitee to timely notify the Company of any Indemnifiable Claim or Indemnifiable Loss shall not relieve the Company from any liability hereunder unless, and only to the extent that, the Company did not otherwise learn of such Indemnifiable Claim or Indemnifiable Loss and such failure results in forfeiture by the Company of substantial defenses, rights or insurance coverage.
Procedure for Claims (1) In the event the Indemnitee is named as a party in any action, claim, suit, proceeding or investigation upon which the Indemnitee intends to base a claim for indemnification hereunder, the Indemnitee shall give the Indemnitor prompt written notice of such action, claim, suit, proceeding or investigation (provided, however, that failure of the Indemnitee to provide such notice shall not relieve the Indemnitor of any liability to the Indemnitee the Indemnitor may have under this Agreement except to the extent that the Indemnitor is materially prejudiced by such failure). (2) The Indemnitor shall participate in and, assume the defence of any such action, including for certainty any derivative action, claim, suit, proceeding or investigation all at the Indemnitor's expense provided, however, that counsel retained by the Indemnitor shall be satisfactory to the Indemnitee in the exercise of his reasonable judgement. Notwithstanding the Indemnitor's assumption of the defense of such action, claim, suit, proceeding or investigation, the Indemnitee shall have the right to employ separate counsel and to participate in, but not control, the defense of such action, claim, suit, proceeding or investigation, and the Indemnitor shall bear the reasonable fees, costs and expenses of such separate counsel as such fees, costs and expenses are incurred (provided that with respect to any single action, claim, suit, proceeding or investigation, the Indemnitor shall not be required to bear the fees, costs and expenses of more than one such counsel in any single jurisdiction) if (a) the use of counsel chosen by the Indemnitor to represent the Indemnitee would present such counsel with a conflict of interest; (b) the defendants, respondents or other parties in any such action, claim, suit, proceeding or investigation include both the Indemnitee on the one hand and the Indemnitor on the other hand, and the Indemnitee has reasonably concluded that representation of both parties by the same counsel would be inappropriate due to actual or potential differing interests between them (in which case the Indemnitor shall not have the right to direct the defense of such action, claim, suit, proceeding or investigation on behalf of the Indemnitee); (c) the Indemnitor shall not have employed counsel satisfactory to the Indemnitee in the exercise of the Indemnitee's reasonable judgment to represent him, within a reasonable time after notice of the institution of such action, proceeding or investigation; or (d) the Indemnitor authorizes the Indemnitee to employ separate counsel at the Indemnitor's expense. (3) The Indemnitee shall cooperate with the Indemnitor in the Indemnitor's defense by providing such information and other assistance which the Indemnitor may reasonably request in connection with such defense. (4) The Indemnitor shall not, without the Indemnitee's prior written consent, settle, compromise, consent to the entry of any judgment in or otherwise seek to terminate any action, claim, suit or proceeding in respect of which indemnification may be sought hereunder (whether or not the Indemnitee is a party thereto) unless such settlement, compromise, consent or termination includes a release of the Indemnitee from any liabilities arising out of such action, claim, suit or proceeding. The Indemnitee shall not, without the Indemnitor's prior written consent, admit liability, settle, compromise, consent to the entry of any judgment in or otherwise seek to terminate any action, claim, suit, investigation or proceeding referred to in the preceding paragraph and the Indemnitee shall not disclose the existence of this Agreement unless required by law, subpoena, court order or upon the advice of counsel.
Notice of Appeal In the event that an employee who has been laid off out of seniority order believes the decision based upon performance and/or qualifications is incorrect, the employee may request that the Association appeal the Sheriff’s determination. If the Association finds there is good reason to believe that the Sheriff has erred in his decision, it may appeal through the process set forth in this Article. Such appeal shall be filed within five (5) working days of delivery of the layoff notice to the employee.
Procedure for Advances (a) During the Reinvestment Period, the Note Purchaser will make Advances on any Business Day at the request of the Borrower, subject to and in accordance with the terms and conditions of Sections 2.01 and 2.02 and subject to the provisions of Article III hereof. (b) Each Advance shall be made on at least one Business Day’s irrevocable written notice from the Borrower to the Agent, with a copy to the Trustee and the Collateral Custodian, in the form of a Notice of Borrowing; provided that such Notice of Borrowing shall be deemed to have been received by the Agent on a Business Day if delivered no later than 5:00 p.m. (New York City time) on such Business Day and if not delivered by such time, shall be deemed to have been received on the following Business Day. The Borrower or Servicer shall post all Loan Agreements and other loan documents and information with respect to each proposed Eligible Loan Asset, if any, to an IntraLinks (or other replacement) website to which the Agent has access. Each Notice of Borrowing shall include a duly completed Borrowing Base Certificate (updated to the date such Advance is requested and giving pro forma effect to the Advance requested and the use of the proceeds thereof), and shall specify: (i) the aggregate amount of such Advance, which amount shall not cause the Advances Outstanding to exceed the Borrowing Base; provided that, except with respect to an Advance pursuant to Section 2.02(f), the amount of such Advance must be at least equal to $500,000; (ii) the proposed date of such Advance; (iii) a representation that all conditions precedent for an Advance described in Article III hereof have been satisfied; and (iv) the amount of cash that will be funded into the Unfunded Exposure Account in connection with the Advance, if applicable. On the date of each Advance, the Note Purchaser shall, upon satisfaction of the applicable conditions set forth in Article III, make available to the Borrower on the applicable Advance Date in same day funds, the amount of such Advance, by payment into the account which the Borrower has designated in writing; provided that, with respect to an Advance funded pursuant to Section 2.02(f), the Note Purchaser shall remit the Advance equal to the Exposure Amount Shortfall in same day funds to the Unfunded Exposure Account. (c) The Advances shall bear interest at the Yield Rate. (d) Subject to Section 2.18 and the other terms, conditions, provisions and limitations set forth herein (including, without limitation, the payment of the Make-Whole Premium, as applicable), the Borrower may (i) borrow and reborrow Advances without any penalty, on and after the Restatement Date and prior to the end of the Reinvestment Period and (ii) repay or prepay Advances without any penalty, on and after the Restatement Date and prior to the Facility Maturity Date. (e) Determinations by the Note Purchaser of the existence of any Eurodollar Disruption Event (any such determination to be communicated to the Borrower by written notice from the Agent promptly after the Agent learns of such event), or of the effect of any Eurodollar Disruption Event on its making or maintaining Advances at LIBOR, shall be conclusive absent manifest error. (f) Notwithstanding anything to the contrary herein (including, without limitation, the occurrence of an Event of Default or the existence of an Unmatured Event of Default or a Borrowing Base Deficiency), if, on the last day of the Reinvestment Period, the amount on deposit in the Unfunded Exposure Account is less than the aggregate of all Exposure Amounts, the Borrower shall request an Advance in the amount of such shortfall (the “Exposure Amount Shortfall”). Following receipt of a Notice of Borrowing (which shall specify the account details of the Unfunded Exposure Account where the funds will be made available), the Note Purchaser shall fund such Exposure Amount Shortfall in accordance with Section 2.02(b), notwithstanding anything to the contrary herein (including, without limitation, the Borrower’s failure to satisfy any of the conditions precedent set forth in Section 3.02).