Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Procedures for Advances (a) In the case of the making of any Advance, the repayment of any Advance, or any termination, increase or reduction of the Facility Amount and prepayments of Advances, the Borrower shall give the Administrative Agent a Borrower Notice. Each Borrower Notice shall specify the amount (subject to Section 2.1 hereof) of Advances to be borrowed or repaid and the Funding Date or repayment date (which, in all cases, shall be a Business Day) and whether such Advance is a Revolver Advance or a Swing Advance.
(b) Subject to the conditions described in Section 2.1, the Borrower may request an Advance from the Lenders by delivering to the Administrative Agent at certain times the information and documents set forth in this Section 2.2.
(c) No later than 12:00 noon (New York, New York time) five (5) Business Days prior to the proposed Funding Date for a Revolver Advance (or such shorter period of time or later date as may be agreed to by the Required Lenders), the Borrower shall notify (i) the Collateral Custodian by delivery to the Collateral Custodian of written notice of such proposed Funding Date, and (ii) the Administrative Agent by delivery to the Administrative Agent of a credit report and transaction summary for each Loan that is the subject of the proposed Advance setting forth the credit underwriting by the Originator of such Loan, including without limitation a description of the Obligor and the proposed loan transaction in the form of Exhibit M hereto; provided that, in the case of Advances funding Revolver Loans, the requirements of this Section 2.2(c) shall apply only with respect to the first Advance to be made with respect to each such Revolver Loan. By 5:00 p.m. (New York, New York time) on the next Business Day, the Administrative Agent shall use its best efforts to confirm to the Borrower the receipt of such items and whether it has reviewed such items and found them to be complete and in proper form. If the Administrative Agent makes a determination that the items are incomplete or not in proper form, it will communicate such determination to the Borrower. Failure by the Administrative Agent to respond to the Borrower by 5:00 p.m. (New York, New York time) on the day the related Funding Request is delivered by the Borrower shall constitute an implied determination that the items are incomplete or not in proper form. The Borrower will take such steps requested by the Administrative Agent to correct the problem(s). In the event of a delay in the actual Funding Date due to the need to correct any such problems, the Funding Date shall be no earlier than two (2) Business Days after the day on which the Administrative Agent confirms to the Borrower that the problems have been corrected.
(d) No later than 1:00 p.m. (New York, New York time) one (1) Business Day prior to the proposed Funding Date for a Revolver Advance (or such shorter period of time or later date as may be agreed to by the Required Lenders), the Administrative Agent, each Managing Agent and the Collateral Custodian, as applicable, shall receive or shall have previously received the following:
(i) a Funding Request in the form of Exhibit A;
(ii) a wire disbursement and authorization form shall be delivered to the Administrative Agent; and
(iii) a certification substantially in the form of Exhibit H concerning the Collateral Custodian’s receipt of certain documentation relating to the Eligible Loan(s) related to such Advance shall be delivered to the Administrative Agent, which may be delivered either as a separate document or incorporated in the Monthly Report. Each Funding Request for a Revolver Advance shall specify the aggregate amount of the requested Advance, which shall be in an amount equal to at least $500,000.
(e) No later than 12:00 noon (New York, New York time) on the Business Day proposed for a Swing Advance, the Administrative Agent shall receive or shall have previously received the following:
(i) a Funding Request in the form of Exhibit A; and
(ii) a wire disbursement and authorization form.
(f) Each Funding Request shall be accompanied by (i) a Borrower Notice, depicting the outstanding amount of Advances under this Agreement and representing that all conditions precedent for a funding have been met, including a representation by the Borrower that the requested Advance shall not, on the Funding Date thereof, exceed the Availability on such day, (ii) a calculation of the Borrowing Base as of the applicable Funding Date (which calculation may, for avoidance of doubt, take into account (A) Loans which will become Transferred Loans on or prior to such Funding Date and (B) an updated Loan List including each Loan that is subject to the requested Advance, (C) the proposed Funding Date, and (D) wire transfer instructions for the Advance; provided, however, the Funding Request for a Swing Advance shall be required to contain only the information described in Section 2.2(e)(i) and (ii) above. A Funding Request shall be irrevocable when delivered; provided however, that if the Borrowing Base calculation delivered pursuant to clause (ii) above includes a Loan which does not become a Transferred Loan on or before the applicable Funding Date as anticipated, and the Borrower cannot otherwise make the representations required pursuant to clause (i) above, the Borrower shall revise the Funding Request accordingly, and shall pay any loss, cost or expense incurred by any Lender in connection with the broken funding evidenced by such revised Funding Request.
(g) On the Funding Date following the satisfaction of the applicable conditions set forth in this Section 2.2 and Article III, the Lenders shall make available to the Administrative Agent at its address listed beneath its signature on its signature page to this Agreement (or on the signature page to the Joinder Agreement pursuant to which it became a party hereto), for deposit to the account of the Borrower or its designee in same day funds, at the account specified in the Funding Request, an amount equal to such Lender’s ratable share of the Advance then being made (except that in the case of a Swing Advance, the Swingline Lender will make available to the Borrower the amount of any such Swing Advance). Each wire transfer of an Advance to the Borrower shall be initiated by the applicable Lender no later than 3:00 p.m. (New York, New York time) on the applicable Funding Date.
Amounts and Terms of the Advances and Letters of Credit SECTION 2.01. The Advances and Letters of Credit.
No Construction Loans No Mortgage Loan was made in connection with (i) the construction or rehabilitation of a Mortgage Property or (ii) facilitating the trade-in or exchange of a Mortgaged Property other than a construction-to-permanent loan which has converted to a permanent Mortgage Loan;
Amounts and Terms of the Advances SECTION 2.01. The A Advances.
(a) Each Lender severally agrees, on the terms and conditions hereinafter set forth, to make A Advances to the Borrower from time to time on any Business Day during the period from the Closing until the Termination Date in an aggregate outstanding amount not to exceed at any time such Lender's Available Commitment, provided that the aggregate amount of the Commitments of the Lenders shall be deemed used from time to time to the extent of the aggregate amount of the B Advances then outstanding and such deemed use of the aggregate amount of the Commitments shall be applied to the Lenders ratably according to their respective Percentages (such deemed use of the aggregate amount of the Commitments being a "B Reduction"). Each A Borrowing shall be in an aggregate amount not less than $10,000,000 (or, if lower, the amount of the Available Commitments) or an integral multiple of $1,000,000 in excess thereof and shall consist of A Advances of the same Type made on the same day by the Lenders ratably according to their respective Percentages. Within the limits of each Lender's Commitment and as hereinabove and hereinafter provided, the Borrower may request Extensions of Credit hereunder, and repay or prepay Advances pursuant to Section 2.11 and utilize the resulting increase in the Available Commitments for further Extensions of Credit in accordance with the terms hereof.
(b) In no event shall the Borrower be entitled to request or receive any Extensions of Credit that would cause the principal amount outstanding hereunder to exceed the Commitments.
SUPERVISION AND CONSTRUCTION PROCEDURES 4.3.1 The Contractor shall supervise and direct the Work, using his / her best skill and attention. The Contractor shall be solely responsible for all construction means, methods, techniques, sequences and procedures and for coordinating all portions of the Work under the Contract. All aspects of the Project shall be subject to the inspection and approval of the State. Contractor guarantees to repair, replace, re-execute or otherwise correct any defect in workmanship, materials, or the like that fails to conform to the requirements of this Contract or that appears during the progress of the Work or within one year of final acceptance by the State.
4.3.2 The Contractor shall be responsible to the State for the acts and omissions of his / her employees, Subcontractors and their agents and employees, and other persons performing any of the Work under a contract with the Contractor.
4.3.3 The Contractor shall not be relieved from his / her obligations to perform the Work in accordance with the Contract Documents either by the activities or duties of the Architect in his / her administration of the Contract, or by inspections, tests or approvals required or performed under Paragraph 7.7 by persons other than the Contractor.
4.3.4 The Contractor shall acquaint himself (herself / itself) with the limits of the property or right- of-way of the State and shall not trespass on other property. The Contractor shall adequately protect the project, adjacent property and the public, and shall be responsible for any damage or injury due to the Contractor’s act or neglect, and shall save the State harmless in respect thereto.
4.3.5 All work shall be done in such a manner as not to interfere with the State’s operating functions. Contractor and his employees shall familiarize themselves and comply with all rules and regulations applicable to the project.
4.3.6 The Contractor shall keep the premises free from liens arising out of or from the Project. Contractor shall obtain and submit waivers of liens with a request for a progress or final payment.
Loan Procedures (a) In order to request a Borrowing, the Borrower --------------- shall hand deliver or telecopy (or notify by telephone and promptly confirm by hand delivery or telecopy) to the Agent the completed Borrowing Request (i) in the case of a Eurodollar Borrowing, not later than 2:00 p.m., Philadelphia time, three Business Days before a proposed Borrowing and (ii) in the case of a Base Rate Borrowing, not later than 11:00 a.m., Philadelphia time, on the day of a proposed Borrowing. Such notice shall be irrevocable and shall in each case specify (x) whether the Borrowing then being requested is to be a Eurodollar Borrowing or a Base Rate Borrowing; (y) the date of such Borrowing (which shall be a Business Day) and the amount thereof; and (z) if such Borrowing is to be a Eurodollar Borrowing, the Interest Period with respect thereto. If no election as to the Type of Borrowing is specified in any such notice, then the requested Revolving Borrowing shall be a Base Rate Borrowing. If no Interest Period with respect to any Eurodollar Borrowing is specified in any such notice, then the Borrower shall be deemed to have selected an Interest Period of one month's duration. The Agent shall promptly advise the Lenders of any notice given pursuant to this Section 2.2 and of each Lender's portion of the requested Borrowing.
(b) Subject to Section 2.3(a), each Lender shall make each Loan to be made by it hereunder on the proposed date thereof by wire transfer of immediately available funds to the designated account of the Agent in Philadelphia, Pennsylvania, not later than 2:00 p.m., Philadelphia time, and the Agent shall by 3:00 p.m., Philadelphia time, wire transfer the amounts so received to the designated account of the Borrower or, if a Borrowing shall not occur on such date because any condition precedent herein specified shall not have been met, return the amounts so received to the respective Lenders. Unless the Agent shall have received notice from a Lender prior to the date of any Borrowing that such Lender will not make available to the Agent such Lender's portion of such Borrowing, the Agent may assume that such Lender has made such portion available to the Agent on the date of such Borrowing in accordance with this paragraph (b) and the Agent may, in reliance upon such assumption, make available to the Borrower on such date a corresponding amount. If and to the extent that such Lender shall not have made such portion available to the Agent, such Lender and the Borrower severally agree to repay to the Agent forthwith on demand such corresponding amount together with interest thereon, for each day from the date such amount is made available to the Borrower until the date such amount is repaid to the Agent at the interest rate applicable at the time to the Loans comprising such Borrowing. If such Lender shall repay to the Agent such corresponding amount, such amount shall constitute such Lender's Loan as part of such Borrowing for purposes of this Agreement.
Procedures for Borrowing Subject to the prior satisfaction of all other applicable conditions to the making of a Term Loan set forth in this Agreement, to obtain a Term Loan, Borrower shall notify the Lenders (which notice shall be irrevocable) by electronic mail, facsimile, or telephone by 12:00 noon Eastern time three (3) Business Days prior to the date the Term Loan is to be made. Together with any such electronic, facsimile or telephonic notification, Borrower shall deliver to the Lenders by electronic mail or facsimile a completed Disbursement Letter executed by a Responsible Officer or his or her designee. The Lenders may rely on any telephone notice given by a person whom a Lender reasonably believes is a Responsible Officer or designee. On the Funding Date, each Lender shall credit and/or transfer (as applicable) to the Designated Deposit Account, an amount equal to its Term Loan Commitment.
Amounts and Terms of Loans 2 1.1 Loans...........................................................................................2 1.2
Amounts and Terms of the Loans 33 2.1. The Revolving Credit Loans............................................................................ 33 2.2. Making the Loans...................................................................................... 33 2.3. Fees ................................................................................................ 35 2.4. Reduction and Termination of the Commitments.......................................................... 36 2.5. Repayment............................................................................................. 36 2.6. Prepayments........................................................................................... 37 2.7. Conversion/Continuation Option........................................................................ 38 2.8. Interest.............................................................................................. 39 2.9. Interest Rate Determination and Protection............................................................ 40 2.10.
