Execution of Change Orders Change Orders shall be signed by the Contractor, ordinarily certified by the Design Professional, and approved by the Owner in accordance with the form of Change Order prescribed by the Owner. No request for payment by the Contractor for a Change Order shall be due, nor shall any such request appear on an Application for Payment, until the Change Order is executed by the Owner. In the event of emergency (see Article 1.4.4) or significant impact to the Overall Project Schedule, the Owner shall direct the Change Order to proceed upon a Force Account until the cost and time is resolved in the manner set forth in Paragraph 3.2.7.3 below.
Change Orders Any alteration or deviation from the Services mentioned or any other contractual specifications that result in a revision of this Agreement shall be executed and attached to this Agreement as a change order (“Change Order”).
Approval Process Tenant shall notify Landlord whether it approves of the submitted working drawings within three business days after Landlord’s submission thereof. If Tenant disapproves of such working drawings, then Tenant shall notify Landlord thereof specifying in reasonable detail the reasons for such disapproval, in which case Landlord shall, within five business days after such notice, revise such working drawings in accordance with Tenant’s objections and submit the revised working drawings to Tenant for its review and approval. Tenant shall notify Landlord in writing whether it approves of the resubmitted working drawings within one business day after its receipt thereof. This process shall be repeated until the working drawings have been finally approved by Landlord and Tenant. If Tenant fails to notify Landlord that it disapproves of the initial working drawings within three business days (or, in the case of resubmitted working drawings, within one business day) after the submission thereof, then Tenant shall be deemed to have approved the working drawings in question. Any delay caused by Tenant’s unreasonable withholding of its consent or delay in giving its written approval as to such working drawings shall constitute a Tenant Delay Day (defined below). If the working drawings are not fully approved (or deemed approved) by both Landlord and Tenant by the 15th business day after the delivery of the initial draft thereof to Tenant, then each day after such time period that such working drawings are not fully approved (or deemed approved) by both Landlord and Tenant shall constitute a Tenant Delay Day.
Approval of Agreement The Board of Directors of the Company has authorized the execution and delivery of this Agreement by the Company and has approved this Agreement and the transactions contemplated hereby.
Manufacturer's Recommendations All work or materials shall be installed in accordance with the manufacturer's recommendations and requirements. The Contractor shall obtain the manufacturer’s recommendations and requirements, for its use at the Site in executing the Work, copies of bulletins, circulars, catalogues, or other publications bearing the manufacturer’s titles, numbers, editions, dates, etc. If the manufacturer’s recommendations and requirements are not available, the Contractor shall request installation instructions from the Design Professional.
REGULATORY FILINGS AND CAISO TARIFF COMPLIANCE 3.1 Filing
Sole Source as Grounds for Rejection of a Change Order If a Change Order is submitted to Contractor for the purposes of adding a Bulletin to this Contract and said Bulletin designates a Sole Source from which Contractor is required to procure goods or services necessary to perform the Work, which Sole Source has not been designated previously, Contractor shall be entitled to reject the proposed Change Order if the designated Sole Source refuses to provide to Contractor the warranties, bonds, terms or schedule required under the Contract Documents, including any warranty or terms or schedule required by Bulletins referenced in the proposed Change Order. In such event, Contractor shall give written notice to the Owner rejecting the proposed Change Order and, if possible, shall accompany said written notice with a proposal from Contractor for changes or modifications to the Bulletin so as to eliminate the Sole Source designation but to achieve goods or services equal in quality or function. The Owner may then require the Design Professional to revise the subject Bulletin so as to eliminate the designation of the Sole Source by incorporation of Contractor's proposal or otherwise. Upon revision of the Bulletin by the Design Professional and approval thereof by the Owner, the Owner shall again submit to the Contractor a proposed Change Order for the purpose of adding the revised Bulletin to this Contract. If the Owner decides to retain the Sole Source in the Change Order and Contractor cannot acquire the full contractually required warranties from the Sole Source, Contractor shall be held only to the warranty terms and schedule obtainable from the Sole Source.
ROAD WORK PHASE APPROVAL Purchaser shall obtain written approval from the Contract Administrator upon completion of each of the following phases of road work: Drainage installation Subgrade compaction Rock compaction SUBSECTION RESTRICTIONS
State Approval of Replacement Personnel The Engineer may not replace the project manager or key personnel without prior consent of the State. The State must be satisfied that the new project manager or other key personnel is qualified to provide the authorized services. If the State determines that the new project manager or key personnel is not acceptable, the Engineer may not use that person in that capacity and shall replace him or her with one satisfactory to the State within forty-five (45) days.
APPROVAL OF GENERAL COMMUNICATIONS Competitive Supplier may only communicate with Program participants and/or use the lists of Eligible Consumers/Program participants to send Department-approved education materials, opt- out notices, or other communications essential to the operation of the Program. Such lists may not be used by Competitive Supplier to market any additional products or services to Eligible Consumers or Program Participants. Competitive Supplier shall cooperate with and assist the Town in the drafting and sending of messages and information to Eligible Consumers concerning the Program or any matter arising under or related to this Agreement or the Program. Competitive Supplier shall, prior to sending any direct mail, advertising, solicitation, bill insert, electronic mail, or other similar written or electronic communication (collectively, “General Communications”) to Participating Consumers (but excluding individually drafted or tailored communications responding to a specific complaint or communication of an individual consumer), provide a copy of such General Communication to the Town for its review (for consistency with the Town’s purposes and goals) and approval. The Town shall have the right to disapprove such General Communications and suggest revisions if it finds the communication inconsistent with the purposes and goals of the Town, factually inaccurate, not essential to the operation of the program, or likely to mislead provided, however, that: (i) the communication shall be deemed approved if the Town fails to respond within ten (10) Business Days, and (ii) no approval shall be necessary for any communication (a) regarding any emergency situation involving any risk to the public health, safety or welfare; (b) that has been approved by the Department, the DOER; or (c) in the nature of routine monthly or periodic bills, or collection notices, except that any bill insert or message included at the bottom of such bill not within the scope of (a) or (b) above shall require advanced review and approval by the Town; and (iii) no approval or lack of approval shall relieve the Competitive Supplier of its obligations and responsibility for its actions and omissions under this Agreement, or other than as set forth in sub-clause ‘i’ of this Section 7.6, result in a waiver of any rights, remedies or defenses of the Town. The Town may reject or exclude any proposed General Communication that, in its reasonable judgment, is contrary to the interests and objectives of the Program or the Town.
