Nonperformance As used in this Contract, “failure to perform” means failure, for whatever reason, to deliver goods and/or perform work as specified and scheduled in this Contract. If Contractor fails to perform under this Contract, then District, after giving seven days’ written notice and opportunity to cure to Contractor, has the right to complete the work itself, to obtain the contracted goods and/or services from other contractors, or a combination thereof, as necessary to complete the work. Both parties agree that Contractor shall bear any reasonable cost difference, as measured against any unpaid balance due Contractor, for these substitute goods or services.
Excuse for Nonperformance or Delayed Performance Except with respect to defaults of subcontractors, Contractor/Vendor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by Contractor/Vendor to make progress in the prosecution of the work hereunder which endangers such performance) if Contractor/Vendor has notified the Commission or designee within 15 days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes or other labor disputes; freight embargoes; or unusually severe weather. If the failure to perform is caused by the failure of a subcontractor to perform or to make progress, and if such failure arises out of causes similar to those set forth above, Contractor/Vendor shall not be deemed to be in default, unless the services to be furnished by the subcontractor were reasonably obtainable from other sources in sufficient time to permit Contractor to meet the contract requirements. Upon request of Contractor, the Commission or designee shall ascertain the facts and extent of such failure, and, if such officer determines that any failure to perform was occasioned by any one or more of the excusable causes, and that, but for the excusable cause, Contractor’s progress and performance would have met the terms of the contract, the delivery schedule shall be revised accordingly, subject to the rights of the State under the clause entitled (in fixed-price contracts, “Termination for Convenience,” in cost-reimbursement contracts, “Termination”). (As used in this Paragraph of this clause, the term “subcontractor” means subcontractor at any tier).
Reporting of Non-Force Majeure Events Each Party (the “Notifying Party”) shall notify the other Parties when the Notifying Party becomes aware of its inability to comply with the provisions of this Agreement for a reason other than a Force Majeure event. The Parties agree to cooperate with each other and provide necessary information regarding such inability to comply, including the date, duration, reason for the inability to comply, and corrective actions taken or planned to be taken with respect to such inability to comply. Notwithstanding the foregoing, notification, cooperation or information provided under this Article shall not entitle the Party receiving such notification to allege a cause for anticipatory breach of this Agreement.
Force Majeure Event After giving effect to any applicable provision, disruption fallback or remedy specified in, or pursuant to, the relevant Confirmation or elsewhere in this Agreement, by reason of force majeure or act of state occurring after a Transaction is entered into, on any day:—
(1) the Office through which such party (which will be the Affected Party) makes and receives payments or deliveries with respect to such Transaction is prevented from performing any absolute or contingent obligation to make a payment or delivery in respect of such Transaction, from receiving a payment or delivery in respect of such Transaction or from complying with any other material provision of this Agreement relating to such Transaction (or would be so prevented if such payment, delivery or compliance were required on that day), or it becomes impossible or impracticable for such Office so to perform, receive or comply (or it would be impossible or impracticable for such Office so to perform, receive or comply if such payment, delivery or compliance were required on that day); or
(2) such party or any Credit Support Provider of such party (which will be the Affected Party) is prevented from performing any absolute or contingent obligation to make a payment or delivery which such party or Credit Support Provider has under any Credit Support Document relating to such Transaction, from receiving a payment or delivery under such Credit Support Document or from complying with any other material provision of such Credit Support Document (or would be so prevented if such payment, delivery or compliance were required on that day), or it becomes impossible or impracticable for such party or Credit Support Provider so to perform, receive or comply (or it would be impossible or impracticable for such party or Credit Support Provider so to perform, receive or comply if such payment, delivery or compliance were required on that day), so long as the force majeure or act of state is beyond the control of such Office, such party or such Credit Support Provider, as appropriate, and such Office, party or Credit Support Provider could not, after using all reasonable efforts (which will not require such party or Credit Support Provider to incur a loss, other than immaterial, incidental expenses), overcome such prevention, impossibility or impracticability;
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
Termination for Force Majeure 15.5.1. The License Agreement may be terminated for Force Majeure Reasons as specified in Article -14.
Force Majeur In case the Show Facility is damaged or destroyed, or in case of war, government regulations or any other circumstances whatsoever which will make it impossible or impractical for Show Management to permit Exhibitor to occupy the exhibit space described in this Agreement, this Agreement will terminate and Exhibitor will waive any claim for damages for compensation except the pro rata return of the amount paid for space rented, diminished only by a pro rata portion of the amounts expended to produce the Show.
SAVINGS/FORCE MAJEURE A Force Majeure occurrence is an event or effect that cannot be reasonably anticipated or controlled and is not due to the negligence or willful misconduct of the affected party. Force Majeure includes, but is not limited to, acts of God, acts of war, acts of public enemies, terrorism, strikes, fires, explosions, actions of the elements, floods, or other similar causes beyond the control of the Contractor or the Commissioner in the performance of the Contract where non- performance, by exercise of reasonable diligence, cannot be prevented. The affected party shall provide the other party with written notice of any Force Majeure occurrence as soon as the delay is known and provide the other party with a written contingency plan to address the Force Majeure occurrence, including, but not limited to, specificity on quantities of materials, tooling, people, and other resources that will need to be redirected to another facility and the process of redirecting them. Furthermore, the affected party shall use its commercially reasonable efforts to resume proper performance within an appropriate period of time. Notwithstanding the foregoing, if the Force Majeure condition continues beyond thirty (30) days, the Parties shall jointly decide on an appropriate course of action that will permit fulfillment of the Parties’ objectives hereunder. The Contractor agrees that in the event of a delay or failure of performance by the Contractor, under the Contract due to a Force Majeure occurrence:
a. The Commissioner may purchase from other sources (without recourse to and by the Contractor for the costs and expenses thereof) to replace all or part of the Products which are the subject of the delay, which purchases may be deducted from the Contract quantities without penalty or liability to the State, or
b. The Contractor will make commercially reasonable efforts to provide Authorized Users with access to Products first in order to fulfill orders placed before the Force Majeure event occurred. The Commissioner agrees that Authorized Users shall accept allocated performance or deliveries during the occurrence of the Force Majeure event. Neither the Contractor nor the Commissioner shall be liable to the other for any delay in or failure of performance under the Contract due to a Force Majeure occurrence. Any such delay in or failure of performance shall not constitute default or give rise to any liability for damages. The existence of such causes of such delay or failure shall extend the period for performance to such extent as determined by the Contractor and the Commissioner to be necessary to enable complete performance by the Contractor if reasonable diligence is exercised after the cause of delay or failure has been removed. Notwithstanding the above, at the discretion of the Commissioner where the delay or failure will significantly impair the value of the Contract to the State or to Authorized Users, the Commissioner may terminate the Contract or the portion thereof which is subject to delays, and thereby discharge any unexecuted portion of the Contract or the relative part thereof. In addition, the Commissioner reserves the right, in his/her sole discretion, to make an equitable adjustment in the Contract terms and/or pricing should extreme and unforeseen volatility in the marketplace affect pricing or the availability of supply. "Extreme and unforeseen volatility in the marketplace" is defined as market circumstances which meet the following criteria: (i) the volatility is due to causes outside the control of Contractor; (ii) the volatility affects the marketplace or industry, not just the particular Contract source of supply; (iii) the effect on pricing or availability of supply is substantial; and (iv) the volatility so affects Contractor's performance that continued performance of the Contract would result in a substantial loss. Failure of the Contractor to agree to any adjustment shall be a dispute under the Disputes clause; provided however, that nothing in this clause shall excuse the Contractor from performing in accordance with the Contract as changed.
Termination Payment for Force Majeure Event 30.9.1 If Termination is on account of a Non-Political Event, the Authority shall make a Termination Payment to the Concessionaire in an amount equal to 55% (fifty five per cent) of the Debt Due less Insurance Cover.
30.9.2 If Termination is on account of an Indirect Political Event, the Authority shall make a Termination Payment to the Concessionaire in an amount equal to:
(a) 55% of the Debt Due less Insurance Cover; provided that if any insurance claims forming part of the Insurance Cover are not admitted and paid, then 80% (eighty per cent) of such unpaid claims shall be included in the computation of Debt Due;
(b) 60.5% (sixty point five per cent) of the Adjusted Equity; and
30.9.3 If Termination is on account of a Political Event, the Authority shall make a Termination Payment to the Concessionaire in an amount that would be payable under Clause 33.3.2 as if it were Authority’s Default.
Services Provided by Party A 1.1 Party B hereby appoints Party A as Party B’s exclusive services provider to provide Party B with comprehensive technical support, consulting services and other services during the term of this Agreement, in accordance with the terms and conditions of this Agreement, including but not limited to the follows:
(1) Licensing Party B to use any software legally owned by Party A;
(2) Development, maintenance and update of software involved in Party B’s business;
(3) Design, installation, daily management, maintenance and updating of network system, hardware and database design;
(4) Technical support and training for employees of Party B;
(5) Assisting Party B in consultancy, collection and research of technology and market information (excluding market research business that wholly foreign-owned enterprises are prohibited from conducting under PRC law);
(6) Providing business management consultation for Party B;
(7) Providing marketing and promotion services for Party B;
(8) Providing customer order management and customer services for Party B;
(9) Leasing of equipments or properties; and
(10) Other services requested by Party B from time to time to the extent permitted under PRC law.
1.2 Party B agrees to accept all the services provided by Party A. Party B further agrees that unless with Party A’s prior written consent, during the term of this Agreement, Party B shall not directly or indirectly accept the same or any similar services provided by any third party and shall not establish similar corporation relationship with any third party regarding the matters contemplated by this Agreement. Party A may designate other parties, who may enter into certain agreements described in Section 1.3 with Party B, to provide Party B with the services under this Agreement. For the purpose of this Agreement, Party A and other parties designated by Party A may be respectively referred to as a “Service Provider,” or collectively as “Service Providers.”
