Product ACCEPTANCE Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User(s) shall have thirty (30) days from the date of delivery to accept hardware products and sixty (60) days from the date of delivery to accept all other Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty (30) day increment. Authorized User shall notify Contractor of acceptance upon successful completion of the documented installation test. Such cancellation shall not give rise to any cause of action against the Authorized User for damages, loss of profits, expenses, or other remuneration of any kind. If the Authorized User elects to provide a deficiency statement specifying how the Product fails to meet the specifications within the testing period, Contractor shall have thirty (30) days to correct the deficiency, and the Authorized User shall have an additional sixty (60) days to evaluate the Product as provided herein. If the Product does not meet the specifications at the end of the extended testing period, Authorized User, upon prior written notice to Contractor, may then reject the Product and return all defective Product to Contractor, and Contractor shall refund any monies paid by the Authorized User to Contractor therefor. Costs and liabilities associated with a failure of the Product to perform in accordance with the functionality tests or product specifications during the acceptance period shall be borne fully by Contractor to the extent that said costs or liabilities shall not have been caused by negligent or willful acts or omissions of the Authorized User’s agents or employees. Said costs shall be limited to the amounts set forth in the Limitation of Liability Clause for any liability for costs incurred at the direction or recommendation of Contractor.
Product Recalls (a) If either Party reasonably decides or is required by any government authority or court of competent jurisdiction, to initiate a product recall, withdrawal or field correction with respect to, or if there is any governmental seizure of, the Product, the Party initiating or required to initiate such action will notify the other Party promptly of the details regarding such action, including providing copies of all relevant documentation concerning such action. The Parties will assist each other in investigating any such situation and all regulatory contacts that are made and all activities concerning seizure, recall, withdrawal or field correction will be jointly coordinated by HSL and LMI.
(b) If any such recall, withdrawal, field correction or seizure occurs due solely to (i) failure of any Product produced by HSL hereunder to conform to Specifications (including, without limitation, being adulterated or misbranded) or any warranty or other requirement set forth in this Agreement, (ii) the failure of HSL to comply in all material respects with any applicable law, rule, regulation, guideline, standard, court order or decree or (iii) the negligent or intentional wrongful act or omission of HSL in connection with the production of Product hereunder, then HSL shall bear the **** of any such seizure, recall, withdrawal or field correction and shall reimburse LMI for its ****, including any purchase price payments made to HSL and related taxes to the extent related to such recalled Product. To the extent any such recall, withdrawal, field correction or seizure occurs for any reason other than that set forth in the immediately preceding sentence, then LMI shall bear the **** of any such seizure, recall, withdrawal or field correction. If both HSL and LMI contribute to the cause of a seizure, recall, withdrawal or field correction, the cost and expense thereof will be shared in proportion to each Party’s contribution to the problem. For the purposes of this Agreement, the expenses of any recall, withdrawal, field correction or seizure shall include, without limitation, the out-of-pocket expenses of notification and destruction or return of the recalled Product and all other out-of-pocket costs incurred in connection with such recall but shall not include a Party’s lost profits. HSL’s reimbursement for the costs of LMI Materials related to such recall, withdrawal or field correction is limited by Section 5.6(c).
Product Recall (a) If a recall is required by applicable Law, or if Buyer or Supplier reasonably determines that a recall is advisable because the goods may create a potential safety hazard, are not in compliance with any applicable code, standard or legal requirement, or contain a defect or non-conformance with the requirements of this Order occurring or likely to occur in multiple goods, which such defects or non-conformances are substantially similar or have substantially similar causes or effects (collectively a “Serial Defect”), the parties shall promptly communicate such facts to each other. At Buyer’s request, Supplier shall promptly develop a corrective action plan satisfactory to Buyer, which shall include all actions required to recall and/or repair the goods and any actions required by applicable Law (“Corrective Action Plan”) for Buyer’s review and approval. At Buyer’s election, Xxxxx may develop the Corrective Action Plan. In no event shall Buyer and Supplier’s failure to agree on the Corrective Action Plan delay the timely notification of a potential safety hazard, non-compliance or Serial Defect to users of the goods, cause either party to be non-compliant with applicable Law or prevent Buyer from taking reasonable actions to prevent injury or damage to persons, equipment or other property. Supplier and Buyer shall cooperate with and assist each other in any corrective actions and/or filings, if applicable.
(b) To the extent a recall is required by applicable Law, or due to a potential safety hazard, non-compliance or Serial Defect, which is caused by Supplier, Supplier shall indemnify and hold Buyer harmless from all reasonable costs and expenses incurred in connection with any recall, repair, replacement or refund program, including all costs related to: (i) investigating and/or inspecting the affected goods; (ii) notifying Buyer’s customers; (iii) repairing, or where repair of the goods is impracticable or impossible, repurchasing or replacing the recalled goods; (iv) packing and shipping the recalled goods; and (v) media notification. Each party shall consult the other before making any statements to the public or a governmental agency relating to such recall, potential safety hazard, non- compliance or Serial Defect, except where such consultation would prevent timely notification required by Law.
PRODUCT MANUFACTURER'S SUPPLIERS Only those dealers/distributors listed by the manufacturer will be considered authorized to act on behalf of the Product Manufacturer.
Product Quality Isoprene, (hereinafter referred to as “Product”) supplied and maintained on consignment at Belpre in accordance with Article 6, and will be in accordance with specifications set forth in Exhibit A. Seller will facsimile to the Buyer at time of shipment a Certificate of Analysis (COA). Seller will provide Buyer six (6) months advanced notification if there is a change in the manufacturing process that will affect the material specifications of Product provided to the Buyer. Product produced by the Seller in different plants is viewed as coming from different supply sources and requires separate qualifications. Product to be shipped for the Seller from third parties must be from a third party qualified by the Buyer based on Buyer’s criteria as specified in Exhibit B. Buyer will have the right to confirm each such shipment-conforms to the agreed specification; Seller must obtain approval prior to shipment any material that does not meet the Buyers specifications. If Seller deliveries Product failing to comply with the specifications set out in Exhibit A, Seller will reimburse Buyer for freight expenses associated with such shipment and be entitled at its option to i) require Seller to replace such defective Product at a price not to exceed the invoice value or ii) to reimburse the invoice value of the defective Product. If, Buyer has cause to complain that the quality of Product delivered to it pursuant to the Contract does not comply with the specification set out in Exhibit A, Buyer will give written notice specifying the nature of its complaint and the parties will promptly meet so as to resolve that complaint. In absence of any agreement to resolve the complaint the parties will appoint at their joint cost a mutually acceptable independent surveyor to examine whether the quality of Product as delivered complied with the specifications set forth in Exhibit A. In the absence of any written notice from Buyer to Seller within 30 days after delivery of the Product, the Product shall be deemed to have been delivered and accepted by Buyer in a satisfactory condition and in all respects in accordance with the specifications and Seller shall have no liability to Buyer with respect to that delivery.
SHOP DRAWINGS, PRODUCT DATA AND SAMPLES 4.12.1 Shop Drawings are drawings, diagrams, schedules and other, data specially prepared for the Work by the Contractor or any Subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work.
4.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and other information furnished by the Contractor to illustrate a material, product or system for some portion of the Work.
4.12.3 Samples are physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged.
4.12.4 The Contractor shall review, approve and submit, with reasonable promptness and in such sequence as to cause no delay in the Work or in the work of the State or any separate contractor, all Shop Drawings, Product Data and Samples required by the Contract Documents.
4.12.5 By approving and submitting Shop Drawings, Product Data and Samples, the Contractor represents that he / she has determined and verified all materials, field measurements, and field construction criteria related thereto, or will do so, and that he / she has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents.
4.12.6 The Contractor shall not be relieved of responsibility for any deviation from the requirements of the Contract Documents by the Architect's approval of Shop Drawings, Product Data or Samples under Subparagraph 2.2.7 of these General Conditions unless the Contractor has specifically informed the Architect and the State in writing of such deviation at the time of sub- mission and the Architect and the State has given written approval to the specific deviation. The Contractor shall not be relieved from responsibility for errors or omissions in the Shop Drawings, Product Data or Samples by the Architect's approval thereof.
4.12.7 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data or Samples, to revisions other than those requested by the Architect on previous submittals.
4.12.8 No portion of the Work requiring submission of a Shop Drawing, Product Data or Sample shall be commenced until the submittal has been approved by the Architect as provided in Subparagraph 2.2.7 of these General Conditions. All such portions of the Work shall be in accordance with approved submittals.
Country Risk Country Risk shall mean, with respect to the acquisition, ownership, settlement or custody of Investments in a jurisdiction, all risks relating to, or arising in consequence of, systemic and markets factors affecting the acquisition, payment for or ownership of Investments including (a) the prevalence of crime and corruption, (b) the inaccuracy or unreliability of business and financial information, (c) the instability or volatility of banking and financial systems, or the absence or inadequacy of an infrastructure to support such systems, (d) custody and settlement infrastructure of the market in which such Investments are transacted and held, (e) the acts, omissions and operation of any Securities Depository, (f) the risk of the bankruptcy or insolvency of banking agents, counterparties to cash and securities transactions, registrars or transfer agents, and (g) the existence of market conditions which prevent the orderly execution or settlement of transactions or which affect the value of assets.
Third Party Products and Services Any third-party hardware, software and/or services that is delivered by ResMed for use either standalone or in conjunction with ResMed products and/or services, shall be subject to the third-party terms and conditions and/or license agreements between Customer and the third party. Such third-party hardware, software and/or services is provided by ResMed "AS IS," without any warranty of any kind. Any representations or warranties as to such hardware, software and/or services shall only be as granted by the applicable third parties, if any, that accompany such products and/or software and/or services. Any representations, warranties, or other similar obligations with respect to such third-party hardware, software and/or services flow directly from the third party to Customer and ResMed shall have no responsibility at all for any such representations, warranties, obligations or lack thereof.
Product Testing No later than [***] prior to a scheduled Delivery ARIAD US shall send to ARIAD SWISSCO the Delivery Documents for review. Following such review, unless within [***] of receipt of the Delivery Documents ARIAD SWISSCO gives written notice of rejection of the Product to be delivered, stating the reasons for such rejection, the Delivery shall proceed, and both Parties shall organize the same. Upon arrival at ARIAD SWISSCO nominated site it shall visually inspect the shipment of the Product to identify any damage to the external packaging. ARIAD SWISSCO may reject any shipment (or portion thereof) of the Product that is damaged by providing to ARIAD US reasonable evidence of damage within [***] after Delivery of such Product. If ARIAD SWISSCO does not so reject any shipment (or portion thereof) of the Product within [***] of Delivery of such Product, ARIAD SWISSCO shall be deemed to have accepted such shipment of the Product; provided, however, that in the case of the Product having any Latent Defect, ARIAD SWISSCO shall notify ARIAD US promptly once it becomes aware that a Product contains a Latent Defect and subsequently may reject such Product by giving written notice to ARIAD US of ARIAD SWISSCO’s rejection of such Product and shipping a representative sample of such Product or other evidence of Non-Conformance to ARIAD US within [***] after becoming aware of such Latent Defect, which notice shall include a description of the Latent Defect.
Product Warnings As of the Effective Date, all Products CORE sells and/or distributes for sale in California which do not qualify as Reformulated Products, will bear a clear and reasonable warning pursuant to this Section. CORE further agrees that the warning will be prominently placed with such conspicuousness when compared with other words, statements, designs or devices as to render it likely to be read and understood by an ordinary individual under customary conditions of use. For purposes of this Settlement Agreement, a clear and reasonable warning for the Products shall consist of a warning affixed directly to the product or product packaging, label, or tag, for Products sold in California and containing one of the following statements: WARNING: Reproductive Harm- xxx.X00Xxxxxxxx.xx.xxx OR WARNING: This product can expose you to chemicals, including DEHP, which are known to the State of California to cause birth defects or other reproductive harm. For more information go to xxx.X00Xxxxxxxx.xx.xxx