Quarterly Progress Reports The goal of this task is to periodically verify that satisfactory and continued progress is made towards achieving the objectives of this Agreement on time and within budget. The objectives of this task are to summarize activities performed during the reporting period, to identify activities planned for the next reporting period, to identify issues that may affect performance and expenditures, and to form the basis for determining whether invoices are consistent with work performed. The Recipient shall: • Prepare a Quarterly Progress Report which summarizes all Agreement activities conducted by the Recipient for the reporting period, including an assessment of the ability to complete the Agreement within the current budget and any anticipated cost overruns. Progress reports are due to the CAM the 10th day of each January, April, July, and October. The Quarterly Progress Report template can be found on the ECAMS Resources webpage available at xxxxx://xxx.xxxxxx.xx.xxx/media/4691. Product: • Quarterly Progress Reports
Progress Reports The Recipient shall submit to the OPWC, at the OPWC's request, summary reports detailing the progress of the Project pursuant to this Agreement and any additional reports containing such information as the OPWC may reasonably require.
Monthly Progress Reports During the Construction Period, the Concessionaire shall, no later than 7 (seven) days after the close of each month, furnish to the Authority and the Independent Engineer a monthly report on progress of the Construction Works and shall promptly give such other relevant information as may be required by the Independent Engineer.
Progress Report 10.1 If required, you shall submit progress reports in connection with the Service (“Report”) on at least a monthly basis, or as we may require. The Report shall include a summary of the activities and accomplishments during the previous reporting period.
Contract Quarterly Sales Reports The Contractor shall submit complete Quarterly Sales Reports to the Department’s Contract Manager within 30 calendar days after the close of each State fiscal quarter (the State’s fiscal quarters close on September 30, December 31, March 31, and June 30). Reports must be submitted in MS Excel using the DMS Quarterly Sales Report Format, which can be accessed at xxxxx://xxx.xxx.xxxxxxxxx.xxx/business_operations/ state_purchasing/vendor_resources/quarterly_sales_report_format. Initiation and submission of the most recent version of the Quarterly Sales Report posted on the DMS website is the responsibility of the Contractor without prompting or notification from the Department’s Contract Manager. If no orders are received during the quarter, the Contractor must email the DMS Contract Manager confirming there was no activity.
Monthly Progress Report This report shall include a description of the activities during the reporting period and the activities planned for the ensuing reporting period. The first reporting period consists of the first full month of performance plus any fractional part of the initial month. Thereafter, the reporting period shall consist of each calendar month. The Contractor shall submit a Monthly Progress Report on or before the 15th calendar day following the last day of each reporting period and shall include the following: Title Page: The title page for this report shall include the contract number and title; the type of report and period that it covers; the Contractor’s name, address, telephone number, fax number, and e-mail address; and the date of submission.
Progress Reports and Invoices The goals of this subtask are to: (1) periodically verify that satisfactory and continued progress is made towards achieving the project objectives of this Agreement; and (2) ensure that invoices contain all required information and are submitted in the appropriate format. The Recipient shall: • Submit a monthly Progress Report to the CAM. Each progress report must: o Summarize progress made on all Agreement activities as specified in the scope of work for the preceding month, including accomplishments, problems, milestones, products, schedule, fiscal status, and an assessment of the ability to complete the Agreement within the current budget and any anticipated cost overruns. See the Progress Report Format Attachment for the recommended specifications. • Submit a monthly or quarterly Invoice that follows the instructions in the “Payment of Funds” section of the terms and conditions, including a financial report on Match Fund and in-state expenditures. Products: • Progress Reports • Invoices
Quarterly Sales Reports The Contractor shall submit a completed Quarterly Sales Report electronically, in the required format, to the Department’s Contract Manager within thirty (30) calendar days after close of each quarter. The quarterly sales report can be found here: xxxxx://xxx.xxx.xxxxxxxxx.xxx/business_operations/ state_purchasing/vendor_resources/quarterly_sales_report_format. The Contract Quarterly Sales Report will include all sales and orders associated with this Contract from Customers received during the reporting period. Initiation and submission of the Sales Report is the responsibility of the Contractor without prompting or notification from the DMS Contract Manager. Failure to provide the quarterly sales report will result in the imposition of financial consequences and may result in the Contractor being found in default and the termination of the Contract. Initiation and submission of the quarterly sales report are the responsibility of the Contractor without prompting or notification by the Department. Sales will be reviewed on a quarterly basis. If no sales are recorded during the period, the Contractor must submit a report stating that there was no activity. If no sales are recorded in two consecutive quarters, the Contractor may be placed in probationary status or the Department may terminate the Contract. Quarter 1 – (July-September) – due 30 calendar days after the close of the period Quarter 2 – (October-December) – due 30 calendar days after the close of the period Quarter 3 – (January-March) – due 30 calendar days after the close of the period Quarter 4 – (April-June) due 30 calendar days after the close of the period Exceptions may be made if a delay in submitting reports is attributable to circumstances that are clearly beyond the control of the Contractor. The burden of proof of unavoidable delay shall rest with the Contractor and shall be supplied in a written form and submitted to the Department. The Department reserves the right to request additional sales information as needed.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
FINANCIAL STATEMENTS TO OWNER The Agent shall render statements of receipts, expenses, and other charges for the Property as requested by the Owner with no more than one (1) statement per month.
