Prohibition of Inconvenience to the Public and Infringement on the Rights of Third Parties Sample Clauses

Prohibition of Inconvenience to the Public and Infringement on the Rights of Third Parties. 9.10.1 The Concessionaire undertakes that there shall be no inconvenience or unnecessary disturbance caused to the public during the execution of the Works (including to towns and villages located in proximity to the Site), nor shall there be any infringement on or unnecessary disturbance of any person’s right of use and right of way on a highway, road, pathway, sidewalk etc., or with the right of use and possession of any public property; should there be any such infringement, the Concessionaire undertakes to obtain prior, written authorization for this infringement from the Relevant Authority, and to the extent that the authorization would entail any payment - to render such payment. 9.10.2 The Concessionaire is responsible for ensuring that, during the execution of the Works, the roads leading to the Site shall not be blocked in any manner that might affect the regular flow of traffic on said roads, that the requisite license for the transport of exceptional truck loads shall be obtained in advance from the Relevant Authorities, and that all necessary steps shall be taken, including the selection of roads, vehicles and transport times, in order to minimize the disturbance of normal traffic on the said roads to the extent possible, as well as to prevent damage to roadways to the extent possible. 9.10.3 Notwithstanding the aforementioned, in the event that the Concessionaire shall be required to disturb the regular flow of traffic of public roads, such disturbance shall be subject to the prior written approval of the Relevant Authorities - including the Israeli Police and subject to the standard procedures. 9.10.4 In the event that any disturbance shall be caused as aforesaid in this Section, the Concessionaire undertakes to eliminate said disturbance immediately, and to indemnify and to compensate the State, within ten
Sample 1
AutoNDA by SimpleDocs

Related to Prohibition of Inconvenience to the Public and Infringement on the Rights of Third Parties

  • No Violation of Rights of Third Parties Executive warrants that the performance of all the terms of this Agreement does not and will not breach any agreement to keep in confidence proprietary information, knowledge or data acquired by Executive prior to Executive’s employment with Employer. Executive agrees not to disclose to Employer, or induce Employer to use, any confidential or proprietary information or material belonging to any previous employers or others. Executive warrants that Executive is not a party to any other agreement that will interfere with Executive’s full compliance with this Agreement. Executive further agrees not to enter into any agreement, whether written or oral, in conflict with the provisions of this Agreement while such provisions remain effective.

  • Procedures for Indemnification of Third Party Claims (a) If an Indemnified Party shall receive notice or otherwise learn of the assertion of any Third Party Claim or of the commencement by any such Person of any Action with respect to which an Indemnifying Party may be obligated to provide indemnification to such Indemnified Party pursuant to this Section 12.4, such Indemnified Party shall give such Indemnifying Party written notice thereof within 20 days after becoming aware of such Third Party Claim. Any such notice shall describe the Third Party Claim in reasonable detail. Notwithstanding the foregoing, the failure of any Indemnified Party or other Person to give notice as provided in this Section 12.4 shall not relieve the Indemnifying Party of its obligations under this Section 12.4, except to the extent that such Indemnifying Party is actually prejudiced by such failure to give notice. (b) An Indemnifying Party may elect to defend (and to seek to settle or compromise), at such Indemnifying Party’s own expense and by such Indemnifying Party’s own counsel, any Third Party Claim. Within 30 days after the receipt of notice from an Indemnified Party in accordance with Section 12.4(a) (or sooner, if the nature of such Third Party Claim so requires), the Indemnifying Party shall notify the Indemnified Party of its election whether the Indemnifying Party will assume responsibility for defending such Third Party Claim, which election shall specify any reservations or exceptions. After notice from an Indemnifying Party to an Indemnified Party of its election to assume the defense of a Third Party Claim, such Indemnified Party shall have the right to employ separate counsel and to participate in (but not control) the defense, compromise, or settlement thereof, but the fees and expenses of such counsel shall be the expense of such Indemnified Party except as set forth in the next sentence. If the Indemnifying Party has elected to assume the defense of the Third Party Claim but has specified, and continues to assert, any reservations or exceptions in such notice, then, in any such case, the reasonable fees and expenses of one separate counsel for all Indemnified parties shall be borne by the Indemnifying Party, but the Indemnifying Party shall be entitled to reimbursement by the Indemnified Party for payment of any such fees and expenses to the extent that it establishes that such reservations and exceptions were proper. (c) If an Indemnifying Party elects not to assume responsibility for defending a Third Party Claim, or fails to notify an Indemnified Party of its election as provided in Section 12.4(b) such Indemnified Party may defend such Third Party Claim at the cost and expense of the Indemnifying Party. (d) Unless the Indemnifying Party has failed to assume the defense of the Third Party Claim in accordance with the terms of this Agreement, no Indemnified Party may settle or compromise any Third Party Claim without the consent of the Indemnifying Party. No Indemnifying Party shall consent to entry of any judgment or enter into any settlement of any pending or threatened Third Party Claim in respect of which any Indemnified Party is or could have been a party and indemnity could have been sought hereunder by such Indemnified Party without the consent of the Indemnified Party if (i) the effect thereof is to permit any injunction, declaratory judgment, other order or other nonmonetary relief to be entered, directly or indirectly against such Indemnified Party and (ii) such settlement does not include an unconditional release of such Indemnified Party from all liability on claims that are the subject matter of such Third Party Claim.

  • Contracts (Rights of Third Parties) Xxx 0000 No term of this Agreement is enforceable under the Contracts (Rights of Third Parties) Xxx 0000 by a person who is not a party to this Agreement.

  • Indemnification of Third Party Claims The obligations and liabilities of any party to indemnify any other under this Article 6 with respect to Claims relating to third parties shall be subject to the following terms and conditions:

  • Indemnification Procedures for Third Party Claims If a claim by a third party (including claims for breaches of fiduciary duties) is made against an Indemnified Party and such Indemnified Party intends to seek indemnity with respect thereto from the Company (in the case of a Purchaser Indemnified Party seeking such indemnity) or the Purchaser (in the case of a Company Indemnified Party seeking indemnity) (each of the Company or the Purchaser, as the case may be, in such capacity, an “Indemnifying Party”), such Indemnified Party shall give notice in writing as promptly as reasonably practicable to such Indemnifying Party of any Proceeding commenced against or by it in respect of which indemnity may be sought hereunder, but failure to so notify such Indemnifying Party shall not relieve such Indemnifying Party from any liability that it may have on account of this Article VI, so long as such failure shall not have materially prejudiced the position of such Indemnifying Party. Upon such notification, the Indemnifying Party shall assume the defense of such Proceeding brought by a third party, and, after such assumption, the Indemnified Party shall not be entitled to reimbursement of any expenses thereafter incurred by it in connection with such Proceeding, except as described below. In any such Proceeding, any Indemnified Party shall have the right to retain its own counsel (including local counsel), but the fees and expenses of such counsel shall be at the expense of such Indemnified Party unless (i) the Indemnifying Party shall have failed to promptly assume and thereafter conduct such defense, (ii) the Indemnifying Party and the Indemnified Party shall have mutually agreed to the contrary, (iii) in the reasonable determination of counsel for the Indemnified Party, representation of such Indemnified Party by counsel obtained by the Indemnifying Party would be inappropriate due to actual or potential conflicting interests between such Indemnified Party and any other party represented by such counsel in such proceeding. No Indemnifying Party, in the defense of a third-party claim, shall, except with the consent of the Indemnified Party, consent to entry of any judgment or enter into any settlement that does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Indemnified Party of a release from all liability in respect of such claim. The Indemnifying Party shall not be liable for any settlement of any Proceeding effected without its written consent (which shall not be unreasonably withheld, delayed or conditioned by such Indemnifying Party), but if settled with such consent or if there be final judgment for the plaintiff, the Indemnifying Party shall indemnify the Indemnified Party from and against any Loss by reason of such settlement or judgment. The Indemnifying Party will advance expenses to an Indemnified Party as reasonably incurred so long as such indemnified party shall have provided the indemnifying party with a written undertaking to reimburse the indemnifying party for all amounts so advanced if it is ultimately determined that the indemnified party is not entitled to indemnification hereunder (which shall include breaches of fiduciary duty if permitted above).

  • Indemnification Procedure for Third Party Claims (a) In the event that any party (the “Indemnified Person”) desires to make a claim against any other party (the “Indemnifying Person”) in connection with any Losses for which the Indemnified Person may seek indemnification hereunder in respect of a claim or demand made by any Person not a party to this Agreement against the Indemnified Person (a “Third-Party Claim”), such Indemnified Person must notify the Indemnifying Person in writing, of the Third-Party Claim (a “Third-Party Claim Notice”) as promptly as reasonably possible after receipt, but in no event later than fifteen (15) calendar days after receipt, by such Indemnified Person of notice of the Third-Party Claim; provided, that failure to give a Third-Party Claim Notice on a timely basis shall not affect the indemnification provided hereunder except to the extent the Indemnifying Person shall have been actually and materially prejudiced as a result of such failure. Upon receipt of the Third-Party Claim Notice from the Indemnified Person, the Indemnifying Person shall be entitled, at the Indemnifying Person’s election, to assume or participate in the defense of any Third-Party Claim at the cost of Indemnifying Person. In any case in which the Indemnifying Person assumes the defense of the Third-Party Claim, the Indemnifying Person shall give the Indemnified Person ten (10) calendar days’ notice prior to executing any settlement agreement and the Indemnified Person shall have the right to approve or reject the settlement and related expenses; provided, however, that upon rejection of any settlement and related expenses, the Indemnified Person shall assume control of the defense of such Third-Party Claim and the liability of the Indemnifying Person with respect to such Third-Party Claim shall be limited to the amount or the monetary equivalent of the rejected settlement and related expenses. (b) The Indemnified Person shall retain the right to employ its own counsel and to discuss matters with the Indemnifying Person related to the defense of any Third-Party Claim, the defense of which has been assumed by the Indemnifying Person pursuant to Section 10.3(a) of this Agreement, but the Indemnified Person shall bear and shall be solely responsible for its own costs and expenses in connection with such participation; provided, however, that, subject to Section 10.3(a) above, all decisions of the Indemnifying Person shall be final and the Indemnified Person shall cooperate with the Indemnifying Person in all respects in the defense of the Third-Party Claim, including refraining from taking any position adverse to the Indemnifying Person. (c) If the Indemnifying Person fails to give notice of the assumption of the defense of any Third-Party Claim within a reasonable time period not to exceed forty-five (45) days after receipt of the Third-Party Claim Notice from the Indemnified Person, the Indemnifying Person shall no longer be entitled to assume (but shall continue to be entitled to participate in) such defense. The Indemnified Person may, at its option, continue to defend such Third-Party Claim and, in such event, the Indemnifying Person shall indemnify the Indemnified Person for all reasonable fees and expenses in connection therewith (provided it is a Third-Party Claim for which the Indemnifying Person is otherwise obligated to provide indemnification hereunder). The Indemnifying Person shall be entitled to participate at its own expense and with its own counsel in the defense of any Third-Party Claim the defense of which it does not assume. Prior to effectuating any settlement of such Third-Party Claim, the Indemnified Person shall furnish the Indemnifying Person with written notice of any proposed settlement in sufficient time to allow the Indemnifying Person to act thereon. Within fifteen (15) days after the giving of such notice, the Indemnified Person shall be permitted to effect such settlement unless the Indemnifying Person (a) reimburses the Indemnified Person in accordance with the terms of this Article 10 for all reasonable fees and expenses incurred by the Indemnified Person in connection with such Claim; (b) assumes the defense of such Third-Party Claim; and (c) takes such other actions as the Indemnified Person may reasonably request as assurance of the Indemnifying Person’s ability to fulfill its obligations under this Article 10 in connection with such Third-Party Claim.

  • Conduct of Third Party Claims If the matter or circumstance that may give rise to a Claim other than a Tax Claim is a result of or in connection with a claim by a third party (a “Third Party Claim”) then: 11.4.1 the Purchaser shall, to the extent reasonably practicable and subject to Applicable Law, consult with the Seller in relation to the conduct of the Third Party Claim and shall take reasonable account of the views of the Seller before taking any action in relation to the Third Party Claim; 11.4.2 no admissions in relation to the Third Party Claim shall be made by or on behalf of the Purchaser or any member of the Purchaser’s Group and the Third Party Claim shall not be compromised, disposed of or settled without the written consent of the Seller, such consent not to be unreasonably withheld or delayed; 11.4.3 subject to the Seller indemnifying the Purchaser or member of the Purchaser’s Group concerned against all reasonable costs and expenses (including legal and professional costs and expenses) that may be incurred thereby, the Purchaser shall, or the Purchaser shall procure that the members of the Purchaser’s Group shall, take such action as the Seller may reasonably request to avoid, dispute, deny, defend, resist, appeal, compromise or contest the Third Party Claim; 11.4.4 the Seller shall, subject in each case to being paid all reasonable out-of-pocket costs and expenses: (i) make available to the Purchaser and the relevant Group Company such persons and all such information as the Purchaser may reasonably request for assessing, contesting, disputing, defending, compromising or appealing the Third Party Claim; and (ii) shall give the Purchaser and the relevant Group Company reasonable access to its premises and to its books and records for such purpose during normal business hours on any Business Day following reasonable notice being given to the Seller; 11.4.5 subject to 11.4.3, the Seller shall be entitled at its own expense and in its absolute discretion, by notice in writing to the Purchaser, to assume conduct of any Third Party Claim and to have the conduct of any related proceedings, negotiations or appeals; 11.4.6 if the Seller sends a notice to the Purchaser pursuant to Clause 11.4.5 and until such time as any final compromise, agreement, expert determination or non-appealable decision of a court or tribunal of competent jurisdiction is made in respect of that Third Party Claim or that Third Party Claim is otherwise finally disposed of: (i) the Purchaser shall, and the Purchaser shall procure that any member of the Purchaser’s Group shall: (a) give, subject to being paid all reasonable costs and expenses, all such information and assistance including access to premises and personnel, and the right to examine and copy or photograph any assets, accounts, documents and records (excluding, in each case, information or documents which are protected by legal professional privilege but including, in each case, information or documents that are subject to common interest privilege), as the Seller may reasonably request, including instructing such professional or legal advisers as the Seller may nominate to act on behalf of the Purchaser or other member of the Purchaser’s Group concerned but in accordance with the Seller’s instructions, provided that the appointment of such adviser or advisers shall have been approved in writing by the Purchaser (such approval not to be unreasonably withheld, conditioned or delayed); and (b) not make any admission of liability, agreement or compromise in relation to that Third Party Claim without the prior written approval of the Seller (such approval not to be unreasonably withheld, conditioned or delayed); (ii) the Seller shall: (a) consult with the Purchaser and take reasonable account of the views of the Purchaser before taking any action in relation to the Third Party Claim; (b) without prejudice to its ability to defend the Third Party Claim, conduct the Third Party Claim with a view to minimising any material harm to the goodwill and reputation of the Wider Group or the Purchaser’s Group; (c) keep the Purchaser informed of all relevant matters relating to the Third Party Claim and shall promptly forward or procure to be forwarded to the Purchaser copies of all correspondence and other written communications with such other information, including non-written records (except information or documents which are protected by legal professional privilege), relating to the Third Party Claim; (d) not make any admission of liability, settlement or compromise of the Third Party Claim without the written consent of the Purchaser, such consent not to be unreasonably withheld, conditioned or delayed. If the Purchaser or member of the Purchaser’s Group fails to consent to a settlement or compromise, the maximum liability of the Seller shall (without prejudice to Clause 10) not exceed the full amount of the proposed settlement or compromise and the Purchaser or member of the Purchaser’s Group shall be liable for any damages awarded in excess of the proposed settlement or compromise and costs incurred from (and including) the date the Seller notified the Purchaser of the settlement or compromise; and (e) indemnify, save as set out in Clause 11.4.6(ii)(d), the Purchaser or other member of the Purchaser’s Group concerned against all reasonable costs and expenses (including legal and professional costs and expenses) that may be incurred as a result of the Seller assuming conduct of the Third Party Claim. 11.4.7 The covenants in this Clause 11.4 may be enforced: (i) by any Group Company against the Seller; and (ii) by any member of the Seller’s Group against the Purchaser or a Group Company, under the Contracts (Rights of Third Parties) Xxx 0000. 11.4.8 The provisions of this Clause 11.4 may be varied or terminated by agreement between the Seller and the Purchaser (and the Purchaser may also release or compromise in whole or in part any liability in respect of rights or claims contemplated by this Clause 11.4) without the consent of any Group Company.

  • Procedures for Third Party Claims In the case of any claim for indemnification arising from a claim of a third-party other than an Infringement Claim subject to Section 13.3 above (a “Third-Party Claim”), a party seeking indemnification hereunder (each an “Indemnified Party”) shall give prompt written notice, following such Indemnified Party’s receipt of such claim or demand, to the party from which indemnity is sought (each an “Indemnifying Party”) of any claim or demand of which such Indemnified Party has knowledge and as to which it may request indemnification hereunder; provided, however, that failure to give such notice will not affect such Indemnified Party’s rights hereunder unless, and then solely to the extent that, the rights of the Indemnifying Parties from whom indemnity is sought are prejudiced as a result of such failure. The Indemnifying Party shall have the right (and if it elects to exercise such right, shall do so within twenty (20) days after receiving such notice from the Indemnified Party) to defend and to direct the defense against any such claim or demand, in its name or in the name of the Indemnified Party, as the case may be, at the expense of the Indemnifying Party, and with counsel selected by the Indemnifying Party; provided, that the Indemnifying Party shall be entitled to assume control of the defense of such action only if the Indemnifying Party acknowledges in writing its indemnity obligations and assumes and holds the Indemnified Party harmless from and against all Losses resulting from such Third-Party Claim; and provided further that the Indemnifying Party shall not be entitled to assume control of such defense if (i) the Indemnifying Party shall not have notified the Indemnified Party of its exercise of its right to defend such Third-Party claim within such twenty (20) day period; (ii) such claim or demand seeks an injunction or other equitable relief against the Indemnified Party, (iii) the Indemnified Party shall have reasonably concluded that (x) there is a conflict of interest between the Indemnified Party and the Indemnifying Party in the conduct of the defense of such claim or demand or (y) the Indemnified Party has one or more defenses not available to the Indemnifying Party, (iv) such claim relates to or arises in connection with any criminal proceeding, action, indictment, allegation or investigation, or (v) the appropriate court rules that the Indemnifying Party failed or is failing to vigorously prosecute or defend such Third-Party Claim. Notwithstanding anything in this Agreement to the contrary, the Indemnified Party shall, at the expense of the Indemnifying Party, cooperate with the Indemnifying Party, and keep the Indemnifying Party fully informed, in the defense of such claim or demand. The Indemnified Party shall have the right to participate in the defense of any claim or demand with counsel employed at its own expense; provided, however, that, in the case of any claim or demand described in clause (i) or (ii) of the second preceding sentence or as to which the Indemnifying Party shall not in fact have employed counsel to assume the defense of such claim or demand, the reasonable fees and disbursements of such counsel shall be at the expense of the Indemnifying Party. The Indemnifying Party shall have no indemnification obligations with respect to any such claim or demand which shall be settled by the Indemnified Party without the prior written consent of the Indemnifying Party, which consent shall not be unreasonably withheld, delayed or conditioned. The Indemnifying Party shall not settle any such claim without the prior written consent of the Indemnified Party (which consent shall not be unreasonably withheld, delayed or conditioned if such settlement is accompanied by a document releasing the Indemnified Party from all liability with respect to the matter in controversy that is binding, valid and enforceable against all applicable Parties). Notwithstanding the foregoing, if the Indemnified Party fails to object to the settlement within five (5) Business Days of receipt of a written notice from the Indemnifying Party containing the terms and condition of such settlement, the Indemnified Party shall be deemed to have consented to the settlement.

  • Defense of Third Party Claims In the case of a Third-Party Claim, the Indemnifying Party shall have the right: (a) to control and conduct any proceedings or negotiations in connection therewith and necessary or appropriate to defend the claim, (b) to take all other reasonable steps or proceedings to settle or defend any such Third-Party Claim; provided, that the Indemnifying Party shall not settle any Third-Party Claim without the prior written consent of the Indemnified Party (which consent shall not be unreasonably withheld, conditioned, or delayed), and (c) to employ counsel designated by the Indemnifying Party to contest any such Third-Party Claim in the name of the Indemnified Party or otherwise. The Indemnifying Party shall, within fifteen (15) days of receipt of a Third-Party Claim Notice (the “Indemnity Notice Period”), give written notice to the Indemnified Party of its intention to assume the defense of such Third-Party Claim. If the Indemnifying Party does not deliver to the Indemnified Party within the Indemnity Notice Period written notice that the Indemnifying Party shall assume the defense of any such Third-Party Claim, then the Indemnified Party may defend against any such Third-Party Claim in any such manner as it may deem appropriate, provided, that the Indemnified Party shall not settle any such Third-Party Claim without the prior written consent of the Indemnifying Party, which consent shall not be unreasonably withheld, conditioned, or delayed. In the event that the Indemnifying Party does assume the defense of such Third-Party Claim, the Indemnified Party shall have the right to fully participate in (but not control) such defense (including with counsel of its choice), at its sole expense, and the Indemnifying Party shall reasonably cooperate with the Indemnified Party in connection with such participation. In the event that either the Indemnifying Party or the Indemnified Party assumes the defense of a Third-Party Claim as provided above (the “Controlling Party”), the non-Controlling Party shall have the right to fully participate (but not control) in such defense (including with counsel of its choice), at its sole expense, and the Controlling Party shall reasonably cooperate with the non-Controlling Party in connection with such participation; provided, however, that Buyer and Seller shall each use its commercially reasonable efforts with respect to any information shared pursuant to this Section 7.3(b) to preserve attorney-client privilege.

  • Indemnification for Third Party Claims ‌ (a) Seller shall defend, indemnify and hold harmless Buyer, its shareholders and Affiliates, and their respective directors, officers, employees and agents, from and against all third party Claims and Liabilities for injury, including death, and property damage caused by, arising out of, or in connection with the performance by any Project Party of the Transaction Documents to the extent any of such Claims or Liabilities were caused by the negligence, gross negligence or willful misconduct of Seller, the Contractor, any Subcontractor, and its respective employees or agents. (b) Buyer shall defend, indemnify and hold harmless Seller and its managers, officers, employees and agents, from and against all third party Claims and Liabilities for injury, including death, and property damage caused by, arising out of, or in connection with the performance of the Transaction Documents to the extent any of such Claims or Liabilities were caused by the negligence, gross negligence or willful misconduct of Buyer, its employees or agents. (c) Either Party seeking indemnification under this Agreement (the “Indemnified Party”) shall give notice to the Party required to provide indemnification hereunder (the “Indemnifying Party”) promptly after the Indemnified Party has actual knowledge of any Claim as to which indemnity may be sought hereunder, and the Indemnified Party shall permit the Indemnifying Party (at the expense of the Indemnifying Party) to assume the defense of any Claim or litigation resulting therefrom; provided that: (i) counsel for the Indemnifying Party who shall conduct the defense of such Claim or litigation shall be reasonably satisfactory to the Indemnified Party; (ii) the Indemnified Party may participate in such defense at its own expense, except the Indemnifying Party shall reimburse the Indemnified Party for its participation in such defense to the extent that the Indemnifying Party requests the Indemnified Party to participate in its own defense; and (iii) the omission by the Indemnified Party to give notice as provided herein shall not relieve the Indemnifying Party of its indemnification obligations hereunder except to the extent that such omission results in a failure of actual notice to the Indemnifying Party and Indemnifying Party is damaged as a result of such failure to give notice. Notwithstanding the foregoing, the Indemnifying Party may not settle any Claim related to the indemnity being provided hereunder without the consent of the Indemnified Party, such consent not to be unreasonably withheld. (d) With regard to any Claim or Liability which is the result of the joint or concurrent fault or negligence of Seller and Buyer, the Parties agree to jointly defend any Claim with respect thereto that is based on such joint or concurrent fault or negligence of Buyer and Seller. Any Claim of contribution or indemnification between Buyer and Seller relating to such Claims shall be resolved on the basis of the percentage of fault or negligence and the Parties agree to reserve the determination of such percentage until after resolution of such Claim. Such pro rata share shall be based upon a final judicial determination of the Parties’ comparative fault or negligence or, in the absence of such determination, by mutual agreement. (e) Nothing in this Section 26.1 is intended to allow any Indemnified Party to be indemnified from and against any third party Claims and Liabilities caused by, arising out of, or in connection with the performance of this Agreement to the extent any of such Claims or Liabilities were caused by, arose out of, or were in any way incidental to or in connection with its own negligence or intentional misconduct.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!