Delays and Extensions The CONSULTANT agrees that no charges or claim for damages shall be made by it for any minor delays from any cause whatsoever during the progress of any portion of the Services specified in this Contract. Such delays, if any, shall be compensated for by an extension of time for such period as may be determined by the LPA subject to the CONSULTANT's approval, it being understood, however, that permitting the CONSULTANT to proceed to complete any services, or any part of them after the date to which the time of completion may have been extended, shall in no way operate as a waiver on the part of the LPA of any of its rights herein. In the event of substantial delays or extensions, or change of any kind, not caused by the CONSULTANT, which causes a material change in scope, character or complexity of work the CONSULTANT is to perform under this Contract, the LPA at its sole discretion shall determine any adjustments in compensation and in the schedule for completion of the Services. CONSULTANT must notify the LPA in writing of a material change in the work immediately after the CONSULTANT first recognizes the material change.
Term of Contract; Contract Extension The Contract will be in effect from the Effective Date (15 December 2016) through 31 December 2018. DAS, in its sole discretion, may extend this Contract for additional terms beyond the original term, prior to Termination or expiration, one or more times for a combined total period not to exceed the complete length of the original term.
Amendment of Contract Period The parties may modify the contract termination date by written supplemental agreement prior to the date of termination as set forth in Article 6, Supplemental Agreements, of attachment A, General Provisions, provided, however, that the termination date may, in no event, be extended past the fifth anniversary of execution.
Contract Extensions This Contract may be extended on an annual basis beyond the Initial Term if the Local Board successfully meets the terms of the Contract for at least three or more years as determined by the State Board.
EXPIRATION DATE AND EXTENSION This Contract expires January 31, 2023, unless it is terminated sooner pursuant to Article XX of the General Terms and Conditions, which are incorporated into this Contract by reference. This Contract may be extended up to three additional one-year periods upon request of Sourcewell and with written agreement by the Contractor, not to exceed a total of four years.
F8 Extension of Initial Contract Period F8.1 The Authority may, by giving written notice to the Contractor, extend the Contract for a further period up to the date set out in the Form of Contract. The provisions of the Contract will apply throughout any such extended period.
TAM Extension Service The TAM Extension Service is an extension of a Red Hat Enterprise Linux TAM Service to provide additional technical knowledge such as SAP implementations on Red Hat Enterprise Linux. The TAM Extension Service requires a separate active and paid standard TAM Service Subscription.
C4 Price adjustment on extension of the Initial Contract Period C4.1 The Contract Price shall apply for the Initial Contract Period. In the event that the Client agrees to extend the Initial Contract Period pursuant to clause F8 (Extension of Initial Contract Period) the Client shall, in the 6 month period prior to the expiry of the Initial Contract Period, enter into good faith negotiations with the Contractor (for a period of not more than 30 Working Days) to agree a variation in the Contract Price.
Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.
Contract Extension The City may, in its sole discretion, unilaterally exercise an option to extend the Contract as described in the Contract Documents. In addition, the City may, in its sole discretion, unilaterally extend the Contract on a month-to-month basis following contract expiration if authorized under Charter section 99 and the Contract Documents. Contractor shall not increase its pricing in excess of the percentage increase described in the Contract.
