Project Documents In addition to any other pertinent and necessary Project documents, the following documents shall be used in the development of the Project: A. TxDOT 2011 Texas Manual of Uniform Traffic Control Devices for Streets and Highways, including latest revisions B. Texas Department of Transportation's Standard Specifications for Construction of Highways, Streets, and Bridges, 2014 (English units)
Construction Documents Phase Bidding or Negotiation Phase:
Material Project Documents (a) The Company shall at all times (i) perform and observe all of the covenants under the Material Project Documents to which it is a party and take reasonable actions to enforce all of its rights thereunder, other than to the extent the same could not reasonably be expected to have a Material Adverse Effect, (ii) subject to the provisions of clause (b) of this Section 9.8, maintain the System Leases (other than Leases constituting System Leases only pursuant to clause (5) of the definition thereof) in full force and effect, and (iii) maintain the Leases (other than the System Leases referred to in the foregoing clause (ii) of this Section 9.8(a)) to which it or any of its Subsidiaries is a party in full force and effect, except to the extent the same could not reasonably be expected to have a Material Adverse Effect. (b) If the term of a Lease with the Company or one of its Subsidiaries expires and the Qualified Lessee under such Lease has either ceased operating the related assets or has ceased paying rent as required under the applicable Lease, the Company shall, or shall cause a Subsidiary, as applicable, to enter into a supplement or a new Lease with respect to the related leasehold assets with a Qualified Lessee that provides for rent that, when combined with all other expected revenue, will, in the reasonable judgment of the Company, as of the commencement date of such supplement or new Lease, generate sufficient revenue to satisfy the requirements of Section 9.9 and will not otherwise result in a materially worse position for the Company as compared to the terms of the applicable expired Lease. Each such new Lease shall have a term of at least five years. Notwithstanding the foregoing, if (i) such expired Lease relates to transmission and/or distribution assets that are not generating significant revenue, (ii) the failure to renew such Lease would not constitute a Material Adverse Effect and (iii) the Company reasonably believes it will generate sufficient revenue and hold sufficient assets (without giving effect to the leasehold assets with respect to such Lease) to satisfy the requirements of Section 9.9, then this Section 9.8(b) will not require a supplement or new lease with respect to such leasehold assets.
Project Documentation All documentation provided to the City other than Project drawings shall be furnished on a Microsoft compatible compact disc.
Material Contracts; Defaults (a) Other than as disclosed in the Company Reports filed prior to the date hereof or as set forth in Company Disclosure Schedule 3.13, neither Company nor any of its Subsidiaries is a party to, bound by or subject to any agreement, contract, arrangement, commitment or understanding (whether written or oral) (i) with respect to the employment of any directors, officers, employees or consultants, (ii) which would entitle any present or former director, officer, employee or agent of Company or any of its Subsidiaries to indemnification from Company or any of its Subsidiaries, (iii) the benefits of which will be increased, or the vesting of benefits of which will be accelerated, by the occurrence of any of the transactions contemplated by this Agreement, or the value of any of the benefits of which will be calculated on the basis of any of the transactions contemplated by this Agreement, (iv) which grants any right of first refusal, right of first offer or similar right with respect to any material assets or properties of Company and or Subsidiaries; (v) which provides for payments to be made by Company or any of its Subsidiaries upon a change in control thereof; (vi) which provides for the lease of personal property having a value in excess of $25,000 individually or $100,000 in the aggregate; (vii) which relates to capital expenditures and involves future payments in excess of $10,000 individually or $50,000 in the aggregate; (viii) which relates to the disposition or acquisition of assets or any interest in any business enterprise outside the ordinary course of Company’s business; (ix) which is not terminable on sixty (60) days or less notice and involving the payment of more than $25,000 per annum; or (x) which materially restricts the conduct of any business by Company of any of its Subsidiaries (collectively, “Material Contracts”). Company has previously delivered to Buyer true, complete and correct copies of each such document. (b) Neither Company nor any of its Subsidiaries is in default under any contract, agreement, commitment, arrangement, lease, insurance policy or other instrument to which it is a party, by which its assets, business, or operations may be bound or affected, or under which it or its assets, business, or operations receives benefits, and there has not occurred any event that, with the lapse of time or the giving of notice or both, would constitute such a default. No power of attorney or similar authorization given directly or indirectly by Company is currently outstanding.
Project Contracts Prior to the delivery of this Lease, the Company may have entered into a contract or contracts with respect to the acquisition and/or construction of the Improvements. Those contracts, and any such contracts entered into by the Company after delivery of this Lease are hereinafter referred to as the “Project Contracts.” Prior to the delivery hereof, certain work has been or may have been performed on the Improvements pursuant to said Project Contracts or otherwise. Subject to the Lender’s rights in the Project Contracts, the Company hereby conveys, transfers and assigns to the Issuer all of the Company’s rights in, but not its obligations under the Project Contracts and the Issuer hereby designates the Company as Issuer’s agent for the purpose of executing and performing the Project Contracts. After the execution hereof, the Company shall cause the Project Contracts to be fully performed by the contractor(s), subcontractor(s) and supplier(s) thereunder in accordance with the terms thereof, and the Company covenants to cause the Improvements to be acquired, constructed and/or completed in accordance with the Project Contracts. Any and all amounts received by the Issuer, the Trustee or the Company from any of the contractors or other suppliers by way of breach of contract, refunds or adjustments shall become a part of and be deposited in the Project Fund.
Construction Document Phase 1.4.1 Based on the approved Design Development Documents, Guaranteed Maximum Price, coordinated models and any further adjustments in the scope or quality of the Project or in the Amount Available for the Construction Contract authorized by the Owner, the Architect/Engineer shall prepare, for approval by the Owner and review by the Construction Manager, Construction Documents consisting of Drawings, Schedules and Specifications derived from the model(s) in accordance with Owner’s written requirements setting forth in detail the requirements for construction of the Project, including, without limitation, the BIM Execution Plan and “Facility Design Guidelines”. The Plans, Drawings and Specifications for the entire Project shall be so prepared that same will call for the construction of the building and related facilities, together with its built-in permanent fixtures and equipment which will cost not more than the Guaranteed Maximum Price accepted by Owner, or the Amount Available for the Construction Contract established by Owner if no Guaranteed Maximum Price proposal has been accepted by Owner. The Architect/Engineer will be responsible for managing the design to stay within such Guaranteed Maximum Price proposal or Amount Available for the Construction Contract. The Architect/Engineer shall review the Construction Documents as they are being prepared at intervals appropriate to the progress of the Project with the Owner and Construction Manager at the Project site or other location specified by Owner in the State of Texas. The Architect/Engineer shall utilize the model(s) to support the review process during Construction Documents. The Architect/Engineer shall provide the Construction Manager with a compact disc containing documents and data files derived from the model to assist the Construction Manager in fulfilling its responsibilities to the Owner. 1.4.2 As a part of Construction Documents Phase, Architect/Engineer shall accomplish model coordination, aggregation and “clash detection” to remove conflicts in design between systems, structures and components. Architect/Engineer shall demonstrate and provide written assurance to Owner that all conflicts/collisions between models have been resolved. 1.4.3 The Architect/Engineer shall consult with the Owner and Construction Manager on matters such as construction phasing and scheduling, bid or proposal alternates, liquidated damages, the construction contract time period, and other construction issues appropriate for the Project. The Architect/Engineer shall assist the Owner and Construction Manager in the preparation of the necessary bidding information, bidding forms, RFP information, and RFP forms, and the Conditions of the Contract. 1.4.4 The Architect/Engineer shall assist the Owner in connection with the Owner’s responsibility and procedures for obtaining approval of all building and accessibility authorities having jurisdiction over the Project. 1.4.5 The Architect/Engineer shall provide coordination and inclusion of sequence of operations for all operable systems in the facility as defined by Owner during Design Development. 1.4.6 The Architect/Engineer shall review the Estimated Construction Cost prepared by the Construction Manager, and shall provide written comments. 1.4.7 The Architect/Engineer shall participate in a final review of the Construction Documents and model(s) with the Owner and Construction Manager at the Project location or other location specified by Owner in the State of Texas. Prior to the Owner’s approval of the Construction Documents, the Architect/Engineer shall incorporate such changes as are necessary to satisfy the Owner’s review comments. 1.4.8 Before proceeding into the Bidding and Proposal Phase, the Architect/Engineer shall obtain Owner’s written acceptance of the Construction Documents and approval of the Final Amount Available for the Construction Contract as approved by the Board of Regents.
Contracts; No Defaults (a) Part 3.17(a) of the Disclosure Letter contains a complete and accurate list, and Sellers have delivered to Buyer true and complete copies, of: (i) each Contract that involves performance of services or delivery of goods or materials by the Company of an amount or value in excess of $100,000. (ii) each Contract that involves performance of services or delivery of goods or materials to the Company of an amount or value in excess of $10,000: (iii) each current Insurance Policy; (iv) each Contract that was not entered into in the Ordinary Course of Business and that involves expenditures or receipts of the Company in excess of $10,000; (v) each lease, rental or occupancy agreement, license, installment and conditional sale agreement, and other Contract affecting the ownership of, leasing of, title to, use of, or any leasehold or other interest in, any real or personal property (except personal property leases and installment and conditional sales agreements having a value per item of less than $10,000, and having an aggregate value of all items having a value per item of less than $10,000 items not exceeding $50,000.00); (vi) each licensing agreement or other Contract with respect to patents, trademarks, copyrights, or other intellectual property, including agreements between the Company and current or former employees, consultants, or contractors regarding the appropriation or the non-disclosure of any of the Intellectual Property Assets; (vii) each collective bargaining agreement and other Contract to or with any labor union or other employee representative of a group of employees; (viii) each joint venture, partnership, and other Contract (however named) involving a sharing of profits, losses, costs, or liabilities by the Company with any other Person; (ix) each Contract containing covenants that in any way purport to restrict the business activity of the Company or limit the freedom of the Company to engage in any line of business or to compete with any Person; (x) each Contract providing for payments to or by any Person based on sales, purchases, or profits, other than direct payments for goods; (xi) each power of attorney that is currently effective and outstanding; (xii) each Contract entered into other than in the Ordinary Course of Business that contains or provides for an express undertaking by the Company to be responsible for consequential damages; (xiii) each Contract for capital expenditures in excess of $10,000; (xiv) each written warranty, guaranty, and or other similar undertaking with respect to contractual performance extended by the Company other than in the Ordinary Course of Business; and (xv) each amendment, supplement, and modification (whether oral or written) in respect of any of the foregoing, except for change orders which will have no material adverse effect to the Company;. (b) Part 3.17(b) of the Disclosure Letter is a work in progress schedule setting forth the total amount of each contract and certain information as reflected in the captions thereto.
Construction Documents The architectural and engineering documents setting forth the design for the Project prepared by the Design Professional. Construction Documents include, but are not limited to, the Specifications, the Drawings, the Supplementary Conditions, the General Conditions, and all Addenda.
Obligations relating to Project Agreements 5.2.1 It is expressly agreed that the Concessionaire shall, at all times, be responsible and liable for all its obligations under this Agreement notwithstanding anything contained in the Project Agreements or any other agreement, and no default under any Project Agreement or agreement shall excuse the Concessionaire from its obligations or liability hereunder. 5.2.2 The Concessionaire shall submit to the Authority the drafts of all Project Agreements, or any amendments or replacements thereto, for its review and comments, and the Authority shall have the right but not the obligation to undertake such review and provide its comments, if any, to the Concessionaire within 15 (fifteen) days of the receipt of such drafts. Within 7 (seven) days of execution of any Project Agreement or amendment thereto, the Concessionaire shall submit to the Authority a true copy thereof, duly attested by a Director of the Concessionaire, for its record. For the avoidance of doubt, it is agreed that the review and comments hereunder shall be limited to ensuring compliance with the terms of this Agreement. It is further agreed that no review and/or observation of the Authority and/or its failure to review and/or convey its observations on any Document shall relieve the Concessionaire of its obligations and liabilities under this Agreement in any manner nor shall the Authority be liable for the same in any manner whatsoever. 5.2.3 The Concessionaire shall not make any addition, replacement or amendments to any of the Financing Agreements without the prior written consent of the Authority if such addition, replacement or amendment has, or may have, the effect of imposing or increasing any financial liability or obligation on the Authority, and in the event that any replacement or amendment is made without such consent, the Concessionaire shall not enforce such replacement or amendment nor permit enforcement thereof against the Authority. For the avoidance of doubt, the Authority acknowledges and agrees that it shall not unreasonably withhold its consent for restructuring or rescheduling of the Debt Due.
