Scope of Service Interconnection Service shall be provided to the Interconnection Customer at the Point of Interconnection (a), in the case of interconnection of the Customer Facility of a Generation Interconnection Customer, up to the Maximum Facility Output, and (b), in the case of interconnection of the Customer Facility of a Transmission Interconnection Customer, up to the Nominal Rated Capability. The location of the Point of Interconnection shall be mutually agreed by the Interconnected Entities, provided, however, that if the Interconnected Entities are unable to agree on the Point of Interconnection, the Transmission Provider shall determine the Point of Interconnection, provided that Transmission Provider shall not select a Point of Interconnection that would impose excessive costs on either of the Interconnected Entities and shall take material system reliability considerations into account in such selection. Specifications for the Customer Facility and the location of the Point of Interconnection shall be set forth in an appendix to the Interconnection Service Agreement and shall conform to those stated in the Facilities Study.
Attachment A, Scope of Services The scope of services is amended as follows:
Scope of Services The specific scope of work for each job shall be determined in advance and in writing between TIPS Member, Member’s design professionals and Vendor. It is permitted for the TIPS Member to provide a general scope description, but the awarded vendor should provide a written scope of work, and if applicable, according to the TIPS Member’s design Professional as part of the proposal. Once the scope of the job is agreed to, the TIPS Member will issue a PO and/or an Agreement or Contract with the Job Order Contract Proposal referenced or as an attachment along with bond and any other special provisions agreed by the TIPS Member. If special terms and conditions other than those covered within this solicitation and awarded Agreements are required, they will be attached to the PO and/or an Agreement or Contract and shall take precedence over those in this base TIPS Vendor Agreement.
General Scope of Services Contractor promises and agrees to furnish all labor, materials, tools, equipment, services, and incidental and customary work necessary to fully and adequately supply professional services, as more particularly described in Exhibit B (Statement of Work and Misc. Documents) attached hereto and incorporated herein by reference (collectively “Services”). All Services shall be subject to, and performed in accordance with, this Contract, the exhibits attached hereto and incorporated herein by reference, and all applicable local, state and federal laws, rules and regulations.
Change in Scope of Work Any change in the scope of the Work, method of performance, nature of materials or price thereof, or any other matter materially affecting the performance or nature of the Work shall not be paid for or accepted unless such change, addition, or deletion is approved in advance and in writing by a valid change order executed by the District. Contractor specifically understands, acknowledges, and agrees that the District shall have the right to request any alterations, deviations, reductions, or additions to the Project or Work, and the cost thereof shall be added to or deducted from the amount of the Contract Price by fair and reasonable valuations. Contractor also agrees to provide the District with all information requested to substantiate the cost of the change order and to inform the District whether the Work will be done by the Contractor or a subcontractor. In addition to any other information requested, Contractor shall submit, prior to approval of the change order, its request for a time extension (if any), as well as all information necessary to substantiate its belief that such change will delay the completion of the Work. If Contractor fails to submit its request for a time extension or the necessary supporting information, it shall be deemed to have waived its right to request such extension.
Level of Service Complex case management with a provider focus is appropriate for members who either choose not to be actively involved or are unable to actively participate in their health care. Complex case management targets members with two (2) or more disease states who need assistance with care coordination, making preventive care appointments, or accessing care to address the members’ chronic health conditions or members who have had an inpatient hospital stay in the last ninety (90) days or members with high dollar claims of over fifty thousand dollars (>$50,000) in six (6) months. The focus is on working with the providers to meet the needs of the individual through communication with the PMP (if applicable), other providers, and the member’s natural support system. The goal is to help members gain optimum health or improved functional capability, in the right setting and in a cost-effective manner. Complex case management with provider focus is the active coordination by the Contractor of care and services between providers while navigating the extensive systems and resources required for the member. It involves comprehensive assessment, determination of available benefits, development and implementation of a complex case management plan directed at the chronic health conditions. At a minimum, the Contractor must provide complex case management services for members discharged from an inpatient psychiatric, drug overdose, or substance abuse hospitalization, for no fewer than ninety (90) calendar days following that inpatient hospitalization discharge. The Contractor must also provide complex case management services for any member at risk for inpatient psychiatric or substance abuse re -hospitalization. Care managers must contact members during an inpatient hospitalization or as soon as practicable upon receiving notification of a member’s inpatient behavioral health hospitalization. The care manager must work with the hospital discharge planner, provider case manager and/or natural supports (i.e. family) to ensure that an outpatient follow-up appointment is scheduled to occur no later than seven (7) calendar days following the inpatient behavioral health hospitalization discharge and transportation is not a barrier to attending the appointment. Complex case management with provider focus includes all of the services and benefits from disease management and care management. In addition,
SCOPE OF SERVICES/CASE HANDLING A. Upon execution by GPM, attorneys are retained to provide legal services for the purpose of seeking damages and other relief in the Litigation. Client provides authorization to seek appointment as Lead Plaintiff in the class action, while the Attorneys will seek to be appointed Class Counsel. If this occurs, the Litigation will be prosecuted as a class action. B. If you obtain access to non-public information during the pendency of the Litigation, you must not engage in transactions in securities. C. Attorneys are authorized to prosecute the Litigation. The appointed Lead Plaintiffs will monitor, review and participate with counsel in the prosecution of the Litigation. The Attorneys shall consult with the appointed Lead Plaintiffs concerning all major substantive matters related to the Litigation, including, but not limited to, the complaint, dispositive motions and settlement. Because of potential differences of opinion between Clients concerning, among other things, strategy, goals and objectives of the Litigation, the Attorneys shall consult with the appointed Lead Plaintiffs as to the courses of action to pursue. The Client agrees to abide by the decisions of the appointed Lead Plaintiffs, which shall be final and binding on all Clients. D. GPM is given the authority to opt the Client out of any class action proceeding relating to the claims authorized herein and/or pursue the Client claim individually in a group action, if the Client is not appointed Lead Plaintiff and GPM is not appointed Class Counsel. E. The Attorneys shall provide sufficient resources, including attorney time and capital for payment of costs and expenses, to vigorously prosecute the Litigation. F. Any recovery from defendants that the Attorneys are responsible for will be divided among class members based on the recognized loss by each class member as calculated by a damage allocation plan which will be prepared by a financial expert or consultant, provided to the appointed Lead Plaintiffs, be subject to the Court's approval and will account for such factors as size of securities ownership, date of purchase, date of sale and continued holdings, if any. Under the rules governing class action litigation, while the Lead Plaintiffs recover according to the same formula as other class members, the Court may approve, upon application therefore, reimbursement of the Lead Plaintiffs’ reasonable costs and expenses directly related to the representation of the class. Examples are lost wages and travel expenses associated with testifying in the action.
Removal of Contractor Employee All employees of the Engineer assigned to this contract shall have such knowledge and experience as will enable them to perform the duties assigned to them. The State may instruct the Engineer to remove any employee from association with work authorized in this contract if, in the sole opinion of the State, the work of that employee does not comply with the terms of this contract or if the conduct of that employee becomes detrimental to the work.
COMMERCIAL REUSE OF SERVICES The member or user herein agrees not to replicate, duplicate, copy, trade, sell, resell nor exploit for any commercial reason any part, use of, or access to 's sites.
Supply of Services 7.1 Supplier shall provide the Services to Purchaser in accordance with the Order in all material respects using reasonable care and skill. 7.2 Supplier shall use reasonable endeavours to meet any performance dates for the Services specified in the Order but any dates shall be estimates only and time shall not be of the essence for the performance of the Services. 7.3 Supplier shall have the right to make any changes to the Services which are necessary to comply with any applicable law or safety requirements or which do not materially affect the nature or quality of the Services. 7.4 Purchaser shall: (a) ensure that the terms of Order are complete and (if submitted by Purchaser) the service specification are complete and accurate; (b) co-operate with Supplier in all matters relating to the Services; (c) provide Supplier, its employees, agents, consultants and subcontractors with access to Purchaser’s premises, machinery and other facilities as reasonably required by Supplier to provide the Services; and (d) provide Supplier with such information and materials as Supplier may reasonably require to supply the Services, and ensure that such information is accurate in all material respects. 7.5 If Supplier’s performance of any of its obligations in respect of the Services is prevented or delayed by an any act or omission by Purchaser or failure by Purchaser to performs its obligations (“Purchaser Default”) Supplier shall without limiting its other rights or remedies have the right to suspend performance of the Services until Purchaser remedied Purchaser Default and relieves Supplier from its obligations to the extent the Customer Default prevents or delays Supplier’s performance. Purchaser shall indemnify Supplier against all liabilities costs, losses and expenses which Supplier may incur by reason of Purchaser Default. 7.6 Where the Services consist of any experimental or developmental work, the results supplied or recommendations made under the Services are given in good faith within the limitations of the data available, but no warranty, expressed or implied, is given as to the ability of Supplier to achieve a specific outcome, nor the accuracy of results obtained. 7.7 Any claims by Purchaser which is based on defect in the Services shall be notified to Supplier within twenty-one (21) days of the services being performed and promptly after discovery of defect or failure. The sole and exclusive remedy of Purchaser for such defect hereunder shall be the re-performance or re- fund, at Supplier’s option, of any defective or non-conforming Services.