Landlord’s Approval Tenant shall not make, or allow to be made, any alterations, physical additions, improvements or partitions, including without limitation the attachment of any fixtures or equipment, in, about or to the Premises (“Alterations”) without obtaining the prior written consent of Landlord, which consent shall not be unreasonably withheld, conditioned or delayed with respect to proposed Alterations which: (i) comply with all Applicable Laws; (ii) are, in Landlord’s opinion, compatible with the Building or the Project and the Base Building Systems , and will not cause the Building or Project or Base Building Systems to be required to be modified to comply with any Applicable Laws (including, without limitation, the Americans With Disabilities Act); and (iii) will not unreasonably interfere with or materially disturb the use and occupancy of any other portion of the Building or Project by any other tenant or its invitees. Specifically, but without limiting the generality of the foregoing, Landlord shall have the right to approve all plans and specifications for the proposed Alterations, construction means and methods, all appropriate permits and licenses, any contractor or subcontractor to be employed on the work of Alterations, and the time for performance of such work, and may impose reasonable rules and regulations for contractors and subcontractors performing such work. Landlord may, in its sole discretion, specify engineers, general contractors, subcontractors, and architects to perform work affecting the Base Building Systems. Tenant shall also supply to Landlord any documents and information reasonably requested by Landlord in connection with Landlord’s consideration of a request for approval hereunder. No review or consent by Landlord of or to any proposed Alteration or additional work shall constitute a waiver of Tenant’s obligations under this Paragraph 12, nor constitute any warranty or representation that the same complies with all Applicable Laws, for which Tenant shall at all times be solely responsible. Tenant shall reimburse Landlord for all out-of-pocket, reasonable costs which Landlord may incur in connection with granting approval to Tenant for any such Alterations, including any costs or expenses which Landlord may incur in electing to have outside architects and engineers review said plans and specifications. Tenant shall also pay to Landlord a fee for its review of plans and its management and supervision of the progress of the work in an amount equal to three percent (3%) of the cost of any Alterations (other than for Minor Alterations). The Tenant Improvements constructed pursuant to the Tenant Improvement Agreement shall not be deemed to be Alterations hereunder.
Landlord Approval (Check one)
Approval of Plans and Specifications The Plans and Specifications will conform to the requirements and conditions set out by applicable law or any effective restrictive covenant, and to all governmental authorities which exercise jurisdiction over the Leased Premises or the construction thereon.
Landlord’s Consent to Alterations Tenant may not make any improvements, alterations, additions or changes to the Premises (collectively, the “Alterations”) without first procuring the prior written consent of Landlord to such Alterations, which consent shall be requested by Tenant not less than fifteen (15) days prior to the commencement thereof, and which consent shall not be unreasonably withheld, conditioned or delayed by Landlord; provided, however, Landlord may withhold its consent in its sole and absolute discretion with respect to any Alterations which may adversely affect the structural components of the Building or the Systems and Equipment in more than a de minimis manner (e.g., the mere tying into Systems shall not be subject to the sole discretion standard) or which can be seen from outside the Building. Tenant shall pay (i) for Alterations performed by Tenant, Landlord’s reasonable third-party costs incurred in connection with reviewing such Alterations, and (ii) for Alterations for which Tenant has engaged Landlord to supervise and Landlord’s contractors to perform, a supervision fee of two and one-half percent (2.5%) of the total cost of such Alteration (for the avoidance of doubt, the foregoing supervisory fee shall not be due or payable in connection with the Tenant Improvements and the Vivarium improvements and no supervisory fee shall be due or payable in connection with any capital improvements performed by Landlord). Notwithstanding the foregoing, no Landlord approval shall be required (provided advance notice shall be provided to Landlord) for (a) installation, removal or realignment of furniture systems not involving any modifications to the structure or connections (other than by ordinary plugs or jacks) to the Systems, (b) Alterations which could not reasonably be expected to affect the structural components of the Building or the Systems and Equipment and which cost less than $150,000 for any one (1) job and no more than $300,000 in the aggregate in any calendar year during the Lease Term (excluding any costs for painting, carpeting, and similar purely cosmetic work), (c) Alterations which do not require a building permit, and (d) merely cosmetic work (such as painting and carpeting). The construction of the initial improvements to the Premises shall be governed by the terms of the Tenant Work Letter and not the terms of this Article 8.
Plans and Specifications Tenant shall be solely responsible for the preparation of the final architectural, electrical and mechanical construction drawings, plans and specifications (called “plans”) necessary for Tenant to construct the Premises for Tenant’s occupancy, which plans shall be subject to approval by Landlord’s architect and engineers and shall comply with their reasonable requirements to avoid aesthetic or other conflicts with the design and function of the balance of the Building. Landlord’s approval is solely given for the benefit of Landlord, and neither Tenant nor any third party shall have the right to rely upon Landlord’s approval of Tenant’s plans for any purpose whatsoever other than that Landlord does not object thereto under this Lease. Landlord’s architects and engineers shall respond (with approval or disapproval) to any plan submission by Tenant within 8 business days after Landlord’s receipt thereof. If Landlord fails to respond to any such submission within such 8 business day period, which failure continues for more than 2 business days after Tenant gives Landlord a written notice (the “Deemed Approved Notice”) advising Landlord that such plan submission shall be deemed approved within 2 business days of Landlord’s receipt of the Deemed Approved Notice, then such plan submission shall be deemed approved hereunder. The Deemed Approved Notice shall, in order to be effective, contain on the first page thereof, in a font at least twice as large as the font of any other text contained in such notice, a legend substantially as follows: “FAILURE TO RESPOND TO THIS NOTICE WITHIN TWO (2) BUSINESS DAYS AFTER RECEIPT HEREOF SHALL CONSTITUTE LANDLORD’S APPROVAL OF SUBMITTED PLANS.” In the event Landlord’s architect’s or engineers’ approval of Tenant’s plans is withheld or conditioned, Landlord shall send prompt written notification thereof to Tenant and include a reasonably detailed statement identifying the reasons for such refusal or condition, and Tenant shall promptly have the plans revised by its architect to incorporate all reasonable objections and conditions presented by Landlord and shall resubmit such plans to Landlord. Landlord’s architects and engineers shall respond (with approval or disapproval) to any plan re-submission by Tenant within 8 business days after Landlord’s receipt thereof. Such process shall be followed until the plans shall have been approved by Landlord’s architect and engineers without unreasonable objection or condition. Without limiting the foregoing, Tenant shall be responsible for all elements of the design of Tenant’s plans (including, without limitation, compliance with law, functionality of design, the structural integrity of the design, the configuration of the Premises and the placement of Tenant’s furniture, appliances and equipment), and Landlord’s approval of Tenant’s plans shall in no event relieve Tenant of the responsibility for such design. Tenant agrees it shall be solely responsible for the timely preparation and submission of all such plans and for all elements of the design of such plans and for all costs related thereto. (The word “architect” as used in this Section 3.2 shall include an interior designer or space planner.) Tenant shall reimburse Landlord Landlord’s reasonable out-of-pocket expense incurred in connection with the review of Tenant’s plans.
Drawings and Specifications 9.1 A complete list of all Drawings that form a part of the Contract Documents are to be found as an index on the Drawings themselves, and/or may be provided to Developer and/or in the Table of Contents.
9.2 Materials or Work described in words that so applied have a well-known technical or trade meaning shall be deemed to refer to recognized standards, unless noted otherwise.
9.3 Trade Name or Trade Term It is not the intention of the Contract Documents to go into detailed descriptions of any materials and/or methods commonly known to the trade under “trade name” or “trade term.” The mere mention or notation of “trade name” or “trade term” shall be considered a sufficient notice to Developer that it will be required to complete the work so named, complete, finished, and operable, with all its appurtenances, according to the best practices of the trade.
9.4 The naming of any material and/or equipment shall mean furnishing and installing of same, including all incidental and accessory items thereto and/or labor therefor, as per best practices of the trade(s) involved, unless specifically noted otherwise.
9.5 Contract Documents are complementary, and what is called for by one shall be binding as if called for by all. As such, Drawings and Specifications are intended to be fully cooperative and to agree. However, if Developer observes that Drawings and Specifications are in conflict with the Contract Documents, Developer shall promptly notify District and Architect in writing, and any necessary changes shall be made as provided in the Contract Documents.
9.6 Figured dimensions shall be followed in preference to scaled dimensions, and Developer shall make all additional measurements necessary for the work and shall be responsible for their accuracy. Before ordering any material or doing any work, each Developer shall verify all measurements at the building and shall be responsible for the correctness of same.
9.7 Should any question arise concerning the intent or meaning of the Contract Documents, including the Plans and Specifications, the question shall be submitted to the District for interpretation. If a conflict exists in the Contract Documents, these Construction Provisions shall control over the Facilities Lease, which shall control over the Site Lease, which shall control over Division 1 Documents, which shall control over Division 2 through Division 49 documents, which shall control over figured dimensions, which shall control over large-scale drawings, which shall control over small-scale drawings. In no case shall a document calling for lower quality and/or quantity of material or workmanship control. However, in the case of discrepancy or ambiguity solely between and among the Drawings and Specifications, the discrepancy or ambiguity shall be resolved in favor of the interpretation that will provide District with the functionally complete and operable Project described in the Drawings and Specifications.
9.8 Drawings and Specifications are intended to comply with all laws, ordinances, rules, and regulations of constituted authorities having jurisdiction, and where referred to in the Contract Documents, the laws, ordinances, rules, and regulations shall be considered as a part of the Contract Documents within the limits specified.
9.9 As required by Section 4-317(c), Part 1, Title 24, CCR: “Should any existing conditions such as deterioration or non-complying construction be discovered which is not covered by the DSA-approved documents wherein the finished work will not comply with Title 24, California Code of Regulations, a construction change document, or a separate set of plans and specifications, detailing and specifying the required repair work shall be submitted to and approved by DSA before proceeding with the repair work.”
Tenant Improvements Landlord shall cause the Core and Shell Contractor or another Contractor designated by Landlord and approved by Tenant, such consent not to be unreasonably withheld or delayed (“TI Contractor”, and together with Core and Shell Contractor, “Contractor”) to commence and thereafter diligently prosecute the construction of the tenant improvements in the Premises pursuant to the Work Letter (the “Tenant Improvements”); provided, however, that before performing the Tenant Improvements, Landlord shall prepare in good faith an estimated budget for the construction of the Tenant Improvements and deliver such budget to Tenant for Tenant’s written approval prior the start of construction (the “Budget”). Landlord and Tenant shall work together cooperatively and in good faith to achieve a mutually acceptable Budget. Landlord shall update the Budget for Tenant’s review and approval at reasonable intervals and shall notify Tenant in writing if the Budget is likely to be exceeded. If there is an indication that the Budget is likely to be exceeded, Landlord and Tenant shall work together cooperatively, if required by Tenant, to modify the scope of the Tenant Improvements to bring the same in line with a budget reasonably acceptable to Tenant. The Tenant Improvements shall be performed in a workmanlike manner and shall substantially conform with Applicable Laws and the Approved TI Plans (as defined in the Work Letter). Tenant shall pay all TI Costs, except that Landlord shall pay for TI Costs that do not exceed the TI Allowance. The “TI Allowance” shall mean (a) One Hundred Twenty Five Dollars ($125.00) per rentable square foot of the Premises (the “Initial TI Allowance”), together with (b) the Additional Allowance. The “TI Costs” shall mean all Tenant Core and Shell Costs (as defined in the Work Letter) and all costs and expenses of performing the TI Work, including without limitation the hard and soft costs of (i) construction, (ii) the Construction Management Fee (as such term is defined in the Work Letter) and any Project or construction management fees paid by Tenant to an unaffiliated third party (such fees not to exceed three percent (3%) of the TI Allowance), (iii) space planning, design, architect, engineering, data and phone cabling and other related services, (iv) costs and expenses for labor, material, equipment, data and phone cabling and fixtures (including, without limitation, any of the Attached Property (as defined in Section 18.5), (v) building permits and other taxes, fees, charges and levies by governmental and quasi-governmental agencies for permits or for inspections of the Tenant Improvements, and (vi) the Warm Shell Costs. In no event shall the TI Allowance be used for: (w) the purchase of any furniture, personal property or other non-building system equipment, (x) costs resulting from a Tenant Delay, (y) costs resulting from any default by Tenant of its obligations under this Lease, or (z) costs that are recoverable or reasonably recoverable by Tenant from a third party (e.g., insurers, warrantors, or tortfeasors). In the event the estimated total TI Costs (as set forth in the Budget) exceed the TI Allowance, Tenant shall deposit with Landlord such overage (the “TI Allowance Excess”), within five (5) business days of receiving the Budget (the “TI Deposit”). In the event Landlord determines the estimate of the TI Costs set forth in the Budget underestimates the amount of TI Costs so that the TI Deposit will not be sufficient to cover the TI Allowance Excess, then Landlord shall communicate the same to Tenant and, if required by Tenant, the parties shall discuss revisions to the Budget and Tenant may make a TI Tenant Change Order Request to reduce TI Costs, and unless the TI Costs are reduced to be within the Budget and previously paid TI Deposit, Tenant shall promptly pay the additional amount to Landlord, and such additional amount shall be added to the TI Deposit. If the sum of the TI Allowance plus the TI Deposit is not sufficient to cover the TI Costs, Tenant shall reimburse Landlord the difference between (a) the TI Costs and (b) the sum of the TI Allowance and the TI Deposit. However, Landlord shall be solely responsible for any costs related to the Tenant Improvements to the extent the same result from Landlord’s gross negligence, intentional misconduct or breach of Lease. Landlord and Tenant shall work together cooperatively at no cost or risk to Landlord to maximize Tenant’s ability, to the extent reasonably possible, to obtain the benefit of any applicable research and development tax credits with respect to the Tenant Improvements.
New Project Approval Consultant and District recognize that Consultant’s Services may include working on various projects for District. Consultant shall obtain the approval of District prior to the commencement of a new project.
Landlord’s Consent Landlord shall not unreasonably withhold or delay its consent to any proposed Transfer of the Subject Space to the Transferee on the terms specified in the Transfer Notice. Without limitation as to other reasonable grounds for withholding consent, the parties hereby agree that it shall be reasonable under this Lease and under any applicable law for Landlord to withhold consent to any proposed Transfer where one or more of the following apply:
14.2.1 The Transferee is of a character or reputation or engaged in a business which is not consistent with the quality of the Building or the Project;
14.2.2 The Transferee is either a governmental agency or instrumentality thereof;
14.2.3 The Transferee is not a party of reasonable financial worth and/or financial stability in light of the responsibilities to be undertaken in connection with the Transfer on the date consent is requested; or
14.2.4 The proposed Transfer would cause a violation of another lease for space in the Project, or would give an occupant of the Project a right to cancel its lease. If Landlord consents to any Transfer pursuant to the terms of this Section 14.2 (and does not exercise any recapture rights Landlord may have under Section 14.4 of this Lease), Tenant may within six (6) months after Landlord’s consent, but not later than the expiration of said six-month period, enter into such Transfer of the Premises or portion thereof, upon substantially the same terms and conditions as are set forth in the Transfer Notice furnished by Tenant to Landlord pursuant to Section 14.1 of this Lease, provided that if there are any changes in the terms and conditions from those specified in the Transfer Notice such that Landlord would initially have been entitled to refuse its consent to such Transfer under this Section 14.2, Tenant shall again submit the Transfer to Landlord for its approval and other action under this Article 14 (including Landlord’s right of recapture, if any, under Section 14.4 of this Lease). Notwithstanding anything to the contrary in this Lease, if Tenant or any proposed Transferee claims that Landlord has unreasonably withheld or delayed its consent under Section 14.2 or otherwise has breached or acted unreasonably under this Article 14, their sole remedies shall be a suit for contract damages (other than damages for injury to, or interference with, Tenant’s business including, without limitation, loss of profits, however occurring) or declaratory judgment and an injunction for the relief sought, and Tenant hereby waives all other remedies, including, without limitation, any right at law or equity to terminate this Lease, on its own behalf and, to the extent permitted under all applicable laws, on behalf of the proposed Transferee.
Tenant Alterations Tenant will not make or allow to be made any alterations in or to the Premises without first obtaining the written consent of Landlord, which consent may be granted or withheld in Landlord’s sole discretion; provided, however that such Landlord consent shall not be required for changes that are not to the exterior, or are not to the structure, or are not to Buildings systems, or which are merely cosmetic in nature. All Tenant alterations will be accomplished in a good and workmanlike manner at Tenant’s sole expense, in conformity with all Applicable Laws by a licensed and bonded contractor approved in advance by Landlord, such approval of contractor not to be unreasonably withheld or delayed. All contractors performing alterations in the Premises shall carry workers’ compensation insurance, commercial general liability insurance, automobile insurance and excess liability insurance in amounts reasonably acceptable to Landlord and shall deliver a certificate of insurance evidencing such coverages to Landlord prior to commencing work in the Premises. Upon completion of any such work, Tenant shall provide Landlord with “as built” plans, copies of all construction contracts, and proof of payment for all labor and materials. All alterations or improvements, shall remain with the Premises upon Lease termination or expiration and will be surrendered to Landlord along with the Premises at such time and will be deemed owned by Landlord at all times from and after and upon completion thereof (but rights to the use of same and Tenant’s obligations to keep in good order, condition and repair and maintain same, as a part of the Premises, shall remain with Tenant pursuant to this Lease during the term of this Lease). Tenant will have no authority or power, express or implied, to create or cause any construction lien or mechanics’ or materialmen’s lien or claim of any kind against the Premises, the Property or any portion thereof. Landlord’s interest in the Premises is not and shall not be subject to any liens as a result of Tenant’s use or occupancy of the Premises including specifically, without limitation, for improvements made by Tenant, and all such liens are expressly prohibited. Tenant will promptly cause any such liens or claims to be released by payment, bonding or otherwise within thirty (30) days after request by Landlord, and will indemnify Landlord against losses arising out of any such claim including, without limitation, legal fees and court costs. Landlord has the right, but not the obligation, to discharge any such lien. Any amount paid by Landlord for such purpose and Landlord’s related reasonable attorneys’ fees shall be paid by Tenant to Landlord upon demand and shall accrue interest from the date paid by Landlord until Landlord is reimbursed therefor at the highest rate permitted by Law. NOTICE IS HEREBY GIVEN THAT LANDLORD WILL NOT BE LIABLE FOR ANY LABOR, SERVICES OR MATERIAL FURNISHED OR TO BE FURNISHED TO TENANT, OR TO ANYONE HOLDING THE PREMISES THROUGH OR UNDER TENANT, AND THAT NO MECHANICS’ OR OTHER LIENS FOR ANY SUCH LABOR, SERVICES OR MATERIALS WILL ATTACH TO OR AFFECT THE INTEREST OF LANDLORD IN THE PREMISES. TENANT WILL DISCLOSE THE FOREGOING PROVISIONS TO ANY CONTRACTOR ENGAGED BY TENANT PROVIDING LABOR, SERVICES OR MATERIAL TO THE PREMISES.
