Development Plans Shipper has provided Gatherer with a report attached hereto as Exhibit D (the “Current Development Plan”) describing in detail, as of January 1, 2017, the planned development, drilling, and production activities to take place with respect to Dedicated Production for the applicable Development Period. The information contained in the TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN REQUESTED. THE REDACTED MATERIAL HAS BEEN FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH TWO ASTERISKS (**). Current Development Plan is broken out on a Subsystem-by-Subsystem basis and, with respect to the first three Years covered by the Current Development Plan, on a Quarter-by-Quarter basis, and with respect to the remaining Years covered by the Current Development Plan, on a Year-by-Year basis. The Current Development Plan attached hereto has been approved by the Parties.
(a) From time to time during each Year of the Term, the Parties shall meet to discuss the planned development, drilling, and production activities that Shipper expects to take place with respect to Dedicated Production for the then-applicable Development Period. Shipper and Gatherer shall each make their respective representatives available to participate in such meetings and discussions. No later than August 1 of each such Year, Shipper shall provide (or cause to be provided) to Gatherer a proposed update of the then-currently agreed Development Plan, prepared on the same basis as the Current Development Plan and describing in detail the planned development, drilling, and production activities to take place with respect to Dedicated Production for the then-applicable Development Period (any such update, an “Updated Development Plan” and, together with the Current Development Plan, each, a “Development Plan”). Notwithstanding anything herein to the contrary, in no event shall Gatherer be required to agree to any Updated Development Plan and corresponding updated Gathering System Plan that contains a Committed Build-Out that (i) has a corresponding Target Completion Date that occurs after the end of the Initial Term, and (ii) Gatherer, in its sole discretion, does not wish to approve.
(b) Each proposed Development Plan shall include information as to the following, in each case, broken out on a Subsystem-by-Subsystem basis and, with respect to the first three Years covered by such Development Plan, on a Quarter-by-Quarter basis, and, with respect to the remaining Years covered by such Development Plan, on a Year-by-Year basis:
(i) all Xxxxx that, as of the date such Development Plan was delivered, are currently in existence and (A) the production therefrom is being delivered into the Gathering System, or (B) are awaiting connection to the Gathering System;
(ii) the Xxxxx that are expected to be drilled during the time period covered by such Development Plan (each such Well reflected in such Development Plan, a “Planned Well”), and the estimated timing of the drilling of such Planned Xxxxx;
(iii) forward-looking production estimates for the applicable time period covered by such Development Plan for all Shipper Gas (A) that Shipper reasonably and in good faith believes will become owned or Controlled by Shipper during the time period covered by such Development Plan, and/or (B) that will be produced from (I) in the aggregate, all Xxxxx then-existing and (II) in the aggregate, any Planned Xxxxx included in such Development Plan (such collective estimates described in subsections (A) and (B), both with respect to a particular Quarter and an entire Year, the “Dedicated Production Estimates”); TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN REQUESTED. THE REDACTED MATERIAL HAS BEEN FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH TWO ASTERISKS (**).
(iv) forward-looking estimates for the applicable time period covered by such Development Plan of the aggregate volumes of those Shipper Injected Liquids that Shipper intends to Tender to the Injection Points hereunder to receive the System Services (such estimates, both with respect to a particular Quarter and an entire Year, the “System Liquids Estimates” and, together with the Dedicated Production Estimates, the “System Production Estimates”);
(v) (A) each new receipt point (including the location thereof) proposed by Shipper with respect to the System Production Estimate reflected in such Development Plan (each such receipt point, including those located at the site of a Planned Well, a “Planned Receipt Point”), (B) each Receipt Point at which Shipper expects to Tender Shipper Gas and/or Shipper Injected Liquids reflected in such Development Plan into the Gathering System, and (C) the estimated portion of the System Production Estimate contained in such Development Plan that Shipper expects to Tender at each such Receipt Point and Planned Receipt Point;
(vi) the earliest date on which each Planned Well included in the Development Plan is estimated to be completed and producing, which date shall not be earlier than three Months after the January 1st that is immediately subsequent to the date that the Development Plan that initially reflected such Planned Well was delivered to Gatherer hereunder;
(vii) the anticipated characteristics of the production from the Xxxxx and Planned Xxxxx reflected in such Development Plan (including liquids content and gas and liquids composition) and the projected production volumes and production pressures applicable thereto; provided that Shipper may utilize the existing and historical production information from similarly situated Xxxxx;
(viii) (A) each new delivery point (including the location thereof) proposed by Shipper with respect to the System Production Estimate reflected in such Development Plan (each such delivery point, a “Planned Delivery Point”), (B) each Delivery Point at which Shipper expects Shipper Gas produced from the Xxxxx and Planned Xxxxx reflected in such Development Plan to be redelivered to Shipper, (C) each Delivery Point at which Shipper expects any Drip Liquids allocated to Shipper in accordance with this Agreement and/or Shipper Injected Liquids to be redelivered to Shipper, and (D) the estimated portion of the System Production Estimate contained in such Development Plan that Shipper expects to be redelivered to Shipper at each such Delivery Point and Planned Delivery Point;
(ix) any (A) proposed revision to the then-existing Dedicated Area and/or any then-existing Dedicated Contract and/or (B) any new contract that Shipper proposes to be a Dedicated Contract; and
(x) other information reasonably requested by Gatherer that is relevant to the design, construction, and operation of the Gathering System, including (A) any Subsystem Extension proposed by Shipper, (B) the relevant Receipt Point, Planned Receipt Point, Delivery Point and Planned Delivery Point facilities applicable to such TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN REQUESTED. THE REDACTED MATERIAL HAS BEEN FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH TWO ASTERISKS (**). Development Plan, and (C) any treating, processing, or liquids handling facilities proposed by Shipper that may be required for any Shipper Gas and/or Shipper Injected Liquids to meet applicable Downstream Facility specifications at the Delivery Points.
Marketing Plans Contractor and the Exchange recognize that Enrollees and other health care consumers benefit from efforts relating to outreach activities designed to increase heath awareness and encourage enrollment. The parties shall share marketing plans on an annual basis and with respect to periodic updates of material changes. The marketing plans of each of the Exchange and Contractor shall include proposed marketing approaches and channels and shall provide samples of any planned marketing materials and related collateral as well as planned, and when completed, expenses for the marketing budget. The Contractor shall include this information for both the Exchange and the outside individual market. The Exchange shall treat all marketing information provided under this Section as confidential information and the obligation of the Exchange to maintain confidentiality of this information shall survive termination or expiration of this Agreement.
Development Plan document specifying the work program, schedule, and relevant investments required for the Development and the Production of a Discovery or set of Discoveries of Oil and Gas in the Concession Area, including its abandonment.
Commercialization Plan (a) Not later than three [***] after submission of Regulatory Filings for each Product in each country of the Territory, Licensee will provide to the JCC for review its initial Commercialization Plan for each Product for each country in the Territory. Such initial Commercialization Plan will describe Licensee’s plans for activities to be conducted for such Product for such country. Each Commercialization Plan shall include the details of obligations to be performed by Licensee to achieve the specific activities that are applicable to the stage of [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential treatment has been requested with respect to the omitted portions. Commercialization (e.g., pre-launch, launch planning, launch, or post-launch) of the applicable Product during the time period covered by such Commercialization Plan and subsequent time periods.
(b) Prior to the First Commercial Sale for such Product in such country, Licensee will provide to the JCC for review an updated Commercialization Plan for such Product for such country. Such updated Commercialization Plan will include, but not be limited to, Licensee’s updated plans for activities to be conducted for such Product for such country prior to launch as well as activities to be conducted in connection with such launch.
(c) Promptly after each anniversary of the First Commercial Sale of such Product during the Term, Licensee will provide to the JCC for review updated Commercialization Plans for such Product for such country. Such further updated Commercialization Plan will include, but not be limited to, Licensee’s plans for Commercialization activities for such Product and such country for the twelve (12) month period following the date of delivery of such Commercialization Plan. No Commercialization Plan may be implemented by Licensee if [***]. Each Commercialization Plan shall be consistent with and shall not contradict the terms of this Agreement [***], and in the event of any inconsistency between the Commercialization Plan and this Agreement, the terms of this Agreement shall prevail. Notwithstanding the foregoing, if a [***], Licensee shall [***] and shall promptly [***].
Professional Development Plan Professional Development Plan (PDP) refers to plans developed by faculty members addressing the criteria contained in Article 22 and Appendix G.
Manufacturing and Marketing Rights The Company has not granted rights to manufacture, produce, assemble, license, market, or sell its products to any other person and is not bound by any agreement that affects the Company's exclusive right to develop, manufacture, assemble, distribute, market, or sell its products.
Project Plans The Contractor: must carry out the Contractor's Activities in accordance with, and otherwise implement, the Project Plans; and for the purposes of subparagraph (i), must: prepare Project Plans based, where applicable, on the draft Project Plans lodged by the Contractor in its tender for the Contractor's Activities, and otherwise in accordance with the requirements of the Contract and submit them to the Contract Administrator so as to ensure that there is no delay or disruption to the Contractor's Activities and in any event no later than the number of days specified in the Contract Particulars after the Award Date for each Project Plan; not commence any of the Contractor's Activities to which any Project Plan applies, unless the Contract Administrator has had the number of days specified in the Contract Particulars for each Project Plan to review the Project Plan and has not rejected the Project Plan; if any Project Plan is rejected, submit an amended Project Plan to the Contract Administrator; in any event, finalise each Project Plan so as to ensure that there is no delay or disruption to the Contractor's Activities and in any event in accordance with the requirements of the Contract to the satisfaction of the Contract Administrator; after each Project Plan has been finalised: regularly review, update and amend each Project Plan in accordance with the process set out in each Project Plan (and otherwise at least on each anniversary of the Award Date); update or amend a Project Plan on request of the Contract Administrator; and continue to correct any defects in or omissions from a Project Plan (whether identified by the Contract Administrator or the Contractor), and submit an updated or amended Project Plan to the Contract Administrator, after which: the Contractor must continue to comply with the requirements of the then current Project Plan until the process in subparagraph (ii) has been completed in respect of the updated or amended Project Plan; and subsubparagraphs B - E will apply (to the extent applicable); and document and maintain detailed records of all: reviews, updates, amendments and submissions of each Project Plan; audits or other monitoring of each Project Plan; and training and awareness programs and communications provided to Contractor and subcontractor personnel in respect of each Project Plan (including each updated or amended Project Plan). The Contractor will not be relieved from compliance with any of its obligations under the Contract or otherwise at law or in equity as a result of: the implementation of, and compliance with, the requirements of any Project Plan; any direction by the Contract Administrator concerning a Project Plan or the Contractor's compliance or non-compliance with a Project Plan; any audit or other monitoring by the Contract Administrator or anyone else acting on behalf of the Commonwealth of the Contractor's compliance with a Project Plan; or any failure by the Contract Administrator, or anyone else acting on behalf of the Commonwealth, to detect any defect in or omission from a Project Plan including where any such failure arises from any negligence on the part of the Contract Administrator or other person.
Marketing Plan The MCOP shall submit an annual marketing plan to ODM including all planned activities for promoting membership in or increasing awareness of the MCOP. The marketing plan submission shall include an attestation by the MCOP that the plan is accurate and is not intended to mislead, confuse, or defraud the eligible individuals or ODM.
Joint Commercialization Committee As of the Effective Date, the Parties have established a joint commercialization committee (the “Joint Commercialization Committee” or the “JCC”), composed of up to [ * ] representatives of each Party, to monitor and discuss the Commercialization of Products at the operational level. Each JCC representative shall have knowledge and expertise in the commercialization of products similar to Products. The JCC shall in particular:
(a) review and recommend the Commercialization Plans and related activities with respect to the Commercialization of Products in the Collaborator Territory, and report to the JEC on all significant Commercialization activities in the Collaborator Territory;
(b) provide a forum for and facilitate communications and coordination between the Parties with respect to the Commercialization of Products in the Collaborator Territory and the Exelixis Territory;
(c) on an annual basis, discuss and establish Collaborator’s Minimum Commercial Performance thresholds pursuant to Section 6.3(b) and propose recommendation to JEC; [ * ] = Certain confidential information contained in this document, marked by brackets, has been omitted and filed separately with the Securities and Exchange Commission pursuant to Rule 24b-2 of the Securities Exchange Act of 1934, as amended.
(d) review the status of material Product manufacturing and supply activities and strategies associated with Commercialization;
(e) review and discuss the major findings of Collaborator’s market research with respect to any Product in the Collaborator Territory, if any;
(f) review and oversee the branding and product positioning strategy for Products in the Collaborator Territory and evaluate Collaborator’s brand strategy for the Product in the Collaborator Territory for consistency with the then-current global brand strategy for the Product;
(g) discuss Product list price and status of reimbursement in the Collaborator Territory; and
(h) perform such other functions as may be appropriate to further the purposes of this Agreement with respect to the Commercialization of Products, including endeavoring to resolve any disputes between the Parties arising from the deliberations of the JCC, or as otherwise directed by the JEC.
Professional Development Program (a) The parties agree to continue a Professional Development Program for the maintenance and development of the faculty members' professional competence and effectiveness. It is agreed that maintenance of currency of subject knowledge, the improvement of performance of faculty duties, and the maintenance and improvement of professional competence, including instructional skills, are the primary professional development activities of faculty members.
(b) Information collected as part of this program shall be the sole property of the faculty member. This information or any judgments arising from this program shall not be used to determine non-renewal or termination of a faculty member's contract, suspension or dismissal of a faculty member, denial of advancement on the salary scale, nor affect any other administrative decisions pertaining to the promotion or employment status of the faculty member.
(c) A joint advisory committee consisting of three regular faculty members who shall be elected by and are P.D. Committee Chairpersons and three administrators shall make recommendations for the operation, financing and management of the Professional Development Program.
