Arbitration Rules (a) The arbitration shall be conducted in accordance with this Employment Agreement, using as appropriate the AAA Employment Dispute Resolution Rules in effect on the date hereof. The arbitrator shall not be bound by the rules of evidence or of civil procedure, but rather may consider such writings and oral presentations as reasonable business people would use in the conduct of their day-to-day affairs, and may require both Parties to submit some or all of their respective cases by written declaration or such other manner of presentation as the arbitrator may determine to be appropriate. The Parties agree to limit live testimony and cross-examination to the extent necessary to ensure a fair hearing on material issues.
(b) The arbitrator shall take such steps as may be necessary to hold a private hearing within 120 days of the initial request for arbitration and to conclude the hearing within two days; and the arbitrator’s written decision shall be made not later than 14 calendar days after the hearing. The Parties agree that they have included these time limits in order to expedite the proceeding, but they are not jurisdictional, and the arbitrator may for good cause allow reasonable extensions or delays, which shall not affect the validity of the award. Both written discovery and depositions shall be allowed. The extent of such discovery will be determined by the Parties and any disagreements concerning the scope and extent of discovery shall be resolved by the arbitrator. The written decision shall contain a brief statement of the claim(s) determined and the award made on each claim. In making the decision and award, the arbitrator shall apply applicable substantive law. The arbitrator may award injunctive relief or any other remedy available from a judge, including consolidation of this arbitration with any other involving common issues of law or fact which may promote judicial economy, and may award attorneys’ fees and costs to the prevailing Party, but shall not have the power to award punitive or exemplary damages. The Parties specifically state that the agreement to limit damages was agreed to by the Parties after negotiations.
Place of Arbitration; Rules All arbitration will be conducted in Massachusetts unless we agree otherwise in writing in a specific case. All arbitration will be conducted before a single arbitrator in accordance with the rules of the American Arbitration Association.
Mediation Procedure The Chairman shall promptly advise the parties of a scheduled Mediation Hearing date. Unless a party requests an expedited procedure, or unless all parties to the proceeding agree to one or more extensions of time, the Mediation Hearing set forth below shall be completed within forty (40) days of BCBSA's receipt of the Complaint. The selected mediators, unless the parties otherwise agree, shall adhere to the following procedure:
i. Each party must be represented by its CEO or other representative who has been delegated full authority to resolve the dispute. However, parties may send additional representatives as they see fit.
ii. By no later than five (5) days prior to the date designated for the Mediation Hearing, each party shall supply and serve a list of all persons who will be attending the Mediation Hearing, and indicate who will have the authority to resolve the dispute.
iii. Each party will be given one-half hour to present its case, beginning with the complaining party (or parties), followed by the other party or parties. The parties are free to structure their presentations as they see fit, using oral statements or direct examination of witnesses. However, neither cross- examination nor questioning of opposing representatives will be permitted. At the close of each presentation, the selected mediators will be given an opportunity to ask questions of the presenters and witnesses. All parties must be present throughout the Mediation Hearing. The selected mediators may extend the time allowed for each party's presentation at the Mediation Hearing. The selected mediators may meet in executive session, outside the presence of the parties, or may meet with the parties separately, to discuss the controversy.
iv. After the close of the presentations, the parties will attempt to negotiate a settlement of the dispute. If the parties desire, the selected mediators, or any one or more of the selected mediators, will sit in on the negotiations.
v. After the close of the presentations, the selected mediators may meet privately to agree upon a recommendation for resolution of the dispute which would be submitted to the parties for their consideration and approval. If the parties have previously agreed to be bound by the results of this procedure, this recommendation shall be binding upon the parties.
vi. The purpose of the Mediation Hearing is to assist the parties to settle their grievances short of mandatory dispute resolution. As a result, the Mediation Hearing has been designed to be as informal as possible. Rules of evidence shall not apply. There will be no transcript of the proceedings, and no party may make a tape recording of the Mediation Hearing.
vii. In order to facilitate a free and open discussion, the Mediation proceeding shall remain confidential. A "Stipulation to Confidentiality" which prohibits future use of settlement offers, all position papers or other statements furnished to the selected mediators, and decisions or recommendations in any Mediation proceeding shall be executed by each party.
viii. Upon request of the selected mediators, or one of the parties, BCBSA staff may also submit documentation at any time during the proceedings.
Rules and Procedures The Benefit Society By-Laws will be amended to provide for a 6th Director with three Directors appointed by the Unions and three Directors appointed by the Corporation.
Notification Procedure Each such notice shall be deemed to have been delivered: (i) when presented personally to the GOB, (ii) when transmitted by facsimile, or (iii) five (5) Days after being deposited in a regularly maintained receptacle for the postal service in Bangladesh, postage prepaid, registered or certified, return receipt requested, addressed to the GOB, at the address indicated in Section 17 of the Implementation Agreement (or such other address as the GOB may have specified by written notice delivered in accordance therewith). Any notice given by facsimile under this Section 7.5 shall be confirmed in writing delivered personally or sent by prepaid post, but failure to so confirm shall not void or invalidate the original notice if it is in fact received by the GOB.
Model Rules of Procedure The procedure before the Panel shall be conducted in accordance with the Model Rules of Procedure set out in Annex 12 (Model Rules of Procedure). Exceptionally, the disputing Parties may agree on different rules to be applied by the Panel. 2. The Model Rules of Procedure are necessary for the good development of all the steps in this Chapter. In addition, these rules shall regulate the development of the procedure, pursuant to the following principles: (a) the procedures shall ensure the right to at least one hearing before the Panel, as well as the opportunity for each disputing Party to provide initial and rebuttal written submissions, and allow the use of any technological means to ensure its authenticity; and (b) the hearings before the Panel, the deliberations, as well as all the submissions and communications submitted during the hearings, shall be confidential.
Arbitration Procedures In the event that the teacher and the School Board are unable to resolve any grievance, the grievance may be submitted to arbitration as defined herein:
1. Request: A request to submit a grievance to arbitration must be in writing signed by the aggrieved party, and such request must be filed in the office of the superintendent within ten (10) days following the decision in Level III of the grievance procedure.
External Arbitration Procedures Any arbitration initiated under this Agreement shall be conducted before a single neutral arbitrator appointed by the Parties. If the Parties fail to agree upon a single arbitrator within ten
Notification Procedures To address non-compliance, the receiving Competent Authority would notify the providing Competent Authority pursuant to Article 5 of the IGA. The notification procedures would differ depending upon whether the receiving Competent Authority seeks to address administrative or other minor errors or significant non-compliance.
Referral Procedures For Local Unions now having a job referral system as contained in their Collective Bargaining Agreement, the Contractor agrees to utilize such system and it shall be used exclusively by such Contractor, except as it may be modified by this Article. Referrals shall not be affected by obligations of Union membership or the lack thereof. Where airport security clearance requirements apply to work to be performed, the Contractor shall inform the Union’s hiring hall dispatcher of those requirements when requesting workers. For those Local Unions having a Book system as part of their Collective Bargaining Agreement, such system will be honored in regards to lay-off of workers from covered projects.
Section 2. In the event that Local Unions are unable to fill any request for employees within the time specified by the local CBAs the Contractor may employ applicants from any other available source. The Contractor shall inform the Union of the name and social security number of any applicants hired from other sources and shall refer the applicant to the Local Union for dispatch to the Covered Project prior to the commencement of work, and make trust fund contributions for every hour worked.
Section 3. There shall be no discrimination against any employee or applicant for employment because of his/her membership or non-membership in the Union or based upon race, creed, color, sex, age or national origin, or any other legally protected class of such employee or applicant.
Section 4. No employee covered by this PLA shall be required to join any Union as a condition of being employed on the Covered Project; provided, however, that an employee who is a member of the referring Union at the time of the referral shall maintain that membership while employed under the PLA. All employees shall, however, be required to comply with the union security provision of the applicable Collective Bargaining Agreement, for the period during which they are performing on-site work, except as modified by this PLA. The Contractor agrees to deduct union dues or representation fees, whichever is applicable, from the pay of any employee who executes a voluntary authorization for such deductions and to remit the dues to the Union or Council. Initiation fees shall be waived for those employees who are not members of any signatory Union when they begin work on this Covered Project. The dues obligations of such employees shall be confined to that portion of union membership dues directly related to representation of workers in collective bargaining, and in enforcement of the Unions’ collective bargaining agreements. Nothing in this Section is intended to eliminate or affect the right of any employee to join the Union or the right of any union to collect full dues from its member.
Section 5. The Parties agree that where a Contractor is not party to a current Collective Bargaining Agreement with the Union having jurisdiction over the affected work, the Contractor may request by name, and the Local will honor, referral of up to a maximum of five (5) persons per each contractor (“core” employees), provided that the Contractor first demonstrate that those persons possess the following qualifications:
(1) Any license required by state or federal law for the Project work to be performed;
(2) Have worked a total of at least one thousand two hundred (1,200) hours in the construction craft during the prior two (2) years;
(3) Were on the Contractor’s active payroll for at least sixty (60) out of the ninety (90) calendar days prior to the contract award;
(4) Have the ability to perform the work safely. The Contractor may elect to hire its first “core” employee to be a xxxxxxx. After the Contractor hires his first core employee, the Union will refer to such Contractor one journeyman employee from the hiring hall out-of-work list for the affected trade or craft, then refer one of such Contractor’s “core” employees as a journeyman, and shall alternate one core employee and one employee from the out-of-work list, until such Contractor’s crew requirements are met or until such Contractor has hired five (5) “core” employees, whichever occurs first. Thereafter, all additional employees in the affected trade or craft shall be hired exclusively from the hiring hall out-of-work list(s). For the duration of the Contractor’s work the ratio of “core” employees to hiring hall referrals shall be maintained and when the Contractor’s workforce is reduced, employees shall be reduced in the same ratio as was applied in the initial hiring. All employees, core and union, shall be dispatched from the appropriate union. Trust benefits shall be paid on all employees, core and union.
Section 6. Upon referral or dispatch from a Union, “turnaround” or refusal of any worker by the Contractors, requires written explanation from the Contractor that shall be communicated through the Prime Contractor to the Port and affected Union within 48 hours.
Section 7. Individual seniority will not be recognized or applied to employees working on the Project. This provision will not interfere with or supersede the use by individual Contractors of “call lists” maintained by such Contractor pursuant to addenda to the local Collective Bargaining Agreement between such Contractor and a Union signatory to this PLA.
Section 8. The selection of craft foremen and/or general foremen and the number of such foremen and/or general foremen required shall be entirely the responsibility of the Contractor. Craft foremen shall be designated working foremen at the request of the Contractor. Craft workers covered by this PLA will, in the normal day- to-day operations, take their direction and supervision from their xxxxxxx.
