Manufacturer’s Warranties If a Lease Vehicle is covered by a Manufacturer’s warranty, the Lessee, during the Vehicle Term for such Lease Vehicle, shall have the right to make any claims under such warranty that the Lessor could make.
PERFORMANCE/ WARRANTIES Supplier warrants and undertakes that the Deliverables will be free from defects in material and workmanship and will conform to any specifications or requirements in the Agreement or agreed upon by the Parties in writing. Supplier warrants that if any Deliverable(s) fails to meet any such specifications or requirements or is otherwise nonconforming, Supplier will, at its own cost and expense and within 10 days of its receipt of written notice of such failure, either correct such deficiency or provide a plan acceptable to Accenture for correcting such deficiency. If such deficiency is not corrected within such 10-day period or a corrective plan is not accepted by Accenture, Accenture will have the option to require Supplier to: (i) provide a full refund; or (ii) promptly replace or reperform the Deliverable(s) at no charge. All Deliverables will be subject to an inspection and acceptance by Accenture, even if the Parties have not set forth any specifications or requirements regarding the Deliverables in the Agreement.
Product and Service Warranties 21- SECTION 3.30
Product Warranties Except as set forth in Schedule 3.15, (a) there are no warranties express or implied, written or oral, with respect to the Business and (b) there are no pending or threatened claims with respect to any such warranty, and Seller has no liability with respect to any such warranty, whether known or unknown, absolute, accrued, contingent or otherwise and whether due or to become due.
SUPPLIER’S WARRANTIES 16.1 The Supplier represents, warrants and undertakes to the Authority that:
16.1.1 the Supplier has the full right, power and authority to enter into and perform this Agreement and to grant all of the Authority Rights to the Authority and for the Authority to use and exploit the same as contemplated in this Agreement;
16.1.2 all information, representations, warranties and other matters of fact contained in the Supplier’s tender submission as part of the competitive tender process referred to in the recitals to this Agreement are true, complete and accurate in all respects and the Supplier agrees to be bound by the obligations and statements made in such tender submission as if the same were set out in this Agreement, save where there is any inconsistency between the terms of this Agreement and such tender submission the terms of this Agreement shall prevail;
16.1.3 save in respect of any Third Party Content, no Deliverable has and no Deliverable will have been broadcast, released or otherwise exploited in any Broadcast Media anywhere in the world prior to the relevant Delivery Date;
16.1.4 there is no contract or arrangement to which the Supplier is a party and the Supplier will not enter into any contract or arrangement and there is and will be no other encumbrance or restriction which could in any way interfere with or inhibit the full exercise or exploitation of any and all of the Authority Rights by the Authority;
16.1.5 the Supplier has paid and shall promptly pay all sums due to any person who is or may be entitled to any payment in respect of services or facilities rendered or goods supplied or rights granted in connection with the Deliverables or on the exercise by the Authority of any of the Authority Rights or in respect of any tax, duty, levy, national insurance or any similar payment in connection with the Deliverables required to be made by the Supplier;
16.1.6 the Supplier will have, by and as at the relevant Delivery Date, obtained all necessary consents, grants, clearances and rights (including any rights in musical compositions contained within the Deliverables (if any) which are controlled by the Performing Right Society or its affiliated bodies) to enable it to produce and deliver the Deliverables and to grant to and enable the Authority to exercise the Authority Rights free from any liens, claims and encumbrances;
16.1.7 to the extent any musical compositions are contained in the Deliverables:
16.1.7.1 all recording synchronisation and dubbing licences have been obtained and licence fees have been paid; and
16.1.7.2 the performing rights in such compositions shall throughout the Term be controlled (i) by the Performing Right Society or its affiliated bodies; or (ii) by the Supplier; or (iii) are in the public domain, in all cases to the extent required for the purposes of the Authority's full exercise of its rights as contemplated by this Agreement;
16.1.8 no claim or litigation is pending or threatened in respect of the Deliverables or any the Authority Rights;
16.1.9 the Deliverables will be produced in accordance with all Laws (including with respect to health and safety);
16.1.10 the Deliverables will be free from all Viruses;
16.1.11 the Deliverables will not contain anything which is in contravention of the Codes and Guidelines or any Laws or which is obscene, blasphemous, seditious, racially inflammatory, defamatory or which infringes the rights of any person, including rights of copyright or trade marks or service marks, privacy, publicity or confidentiality or any other civil or common law or statutory right whatsoever or breaches any contract or is in contempt of court;
16.1.12 the Supplier has not entered and will not enter into any co-production, co-financing, pre-sale or other arrangement or agreement which involves the surrender by the Supplier of any control of the Deliverables;
16.1.13 all information, records and data provided to the Authority and with respect to the Deliverables and the production process will be accurate in all respects, full and up to date;
16.1.14 the Supplier is not insolvent nor unable to pay its debts as they fall due and no steps have been taken with a view to the winding-up or administration of the Supplier or the making of any composition or arrangement with any creditors of the Supplier; and
16.1.15 the Supplier will not at any time do or say anything which is or may be considered by the Authority (acting reasonably) to be detrimental or prejudicial to or to affect adversely the name, image, reputation or business of the Authority or otherwise to bring the Authority or any member of the Authority Group into disrepute.
16.2 The Supplier's warranties shall be deemed repeated on each Delivery Date (or, if any Deliverables are delivered to the Authority after the scheduled Delivery Date and the Authority has not exercised any right under this Agreement to treat such delay as an Event of Default under clause 27.1, within ten Working Days of the date of actual delivery) and on every occasion when the Authority exercises its Authority Rights.
Minimum Condition and Warranty Requirements for TIPS Sales All goods quoted or sold through a TIPS Sale shall be new unless clearly stated otherwise in writing. All new goods and services shall include the applicable manufacturers minimum standard warranty unless otherwise agreed to in the Supplemental Agreement.
Performance Warranty Contractor shall warrant all work under this Contract, taking necessary steps and precautions to perform the work to County’s satisfaction. Contractor shall be responsible for the professional quality, technical assurance, timely completion and coordination of all documentation and other goods/services furnished by the Contractor under this Contract. Contractor shall perform all work diligently, carefully, and in a good and workmanlike manner; shall furnish all necessary labor, supervision, machinery, equipment, materials, and supplies, shall at its sole expense obtain and maintain all permits and licenses required by public authorities, including those of County required in its governmental capacity, in connection with performance of the work. If permitted to subcontract, Contractor shall be fully responsible for all work performed by subcontractors.
Service Warranties Contractor warrants that: (i) the Services will be rendered with promptness and diligence and will be executed in a workmanlike manner, in accordance with the practices and professional standards used in well-managed operations performing services similar to the Services; and (ii) Contractor will perform the Services in the most cost-effective manner consistent with the required level of quality and performance. Contractor warrants that each Deliverable will conform to and perform in accordance with the requirements of this Agreement and all applicable specifications and documentation. For each such Deliverable, the foregoing warranty shall commence for such Deliverable upon the JBE’s acceptance of such Deliverable, and shall continue for a period of one (1) year following acceptance. In the event any Deliverable does not to conform to the foregoing warranty, Contractor shall promptly correct all nonconformities to the satisfaction of the JBE.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Manufacturer Warranties Prior to the transfer to the Interconnected Transmission Owner of title to the Transmission Owner Interconnection Facilities built by the Interconnection Customer, the Interconnection Customer shall produce documentation satisfactory to the Interconnected Transmission Owner evidencing the transfer to the Interconnected Transmission Owner of all manufacturer warranties for equipment and/or materials purchased by the Interconnection Customer for use and/or installation as part of the Transmission Owner Interconnection Facilities built by the Interconnection Customer.
