Quality of work and elimination of defects Sample Clauses

Quality of work and elimination of defects. 4.6.1. The General contractor ensures that the quality of construction and finishing materials, equipment, components, structures and networks, supplied or accepted by the Building owner, as well as the quality of the work meet the requirements of design documentation, State Standards and technical regulations applicable on the territory where the work is carried out in accordance with the Contract. 4.6.2. If a representative of the Building owner is not satisfied with a process and quality of the work and used construction materials, or in case of violations of applicable construction rules, regulations and design requirements; or in case when he reveals any violations in registration of operations and work process by the General contractor, he is authorized to register his claims and comments in a log and to give directions in order to eliminate violations committed by the General contractor, and to indicate the term to eliminate such violations. 4.6.3. If the General contractor admits claims and remarks made by a representative of the Building owner, the general contractor shall immediately take action to eliminate the defects as soon as possible. 4.6.4. If the General contractor does not admit claims and remarks made by a representative of the Building owner, the General contractor may send objections to the Building owner. The Parties shall make efforts to resolve disputes through negotiations, and if the result of such negotiations is negative, the Parties shall create a conciliation committee with assistance of independent experts. The decision of the committee shall be terminal and must be executed by the Parties. Payment of services of attracted experts shall be covered by the Party in fault. 4.6.5. Additional tests and examinations, undertaken by the Building owner or by third parties on behalf of the Building owner, shall be paid by the Building owner, if such tests and examinations confirm the quality of the work performed. If any defects were revealed in the work accepted by the Building owner, the General contractor shall correct defects and pay for the tests and examinations at his own expense.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs

Related to Quality of work and elimination of defects

  • Quality of Work Consultant agrees that all Services performed under this Agreement will conform to the specifications of the College, be free from errors and be of professional quality according to applicable industry standards. Upon notice by the College, Consultant will promptly correct any defects without charge to the College.

  • Suspension of Work and Termination 15.01 Owner May Suspend Work A. At any time and without cause, Owner may suspend the Work or any portion thereof for a period of not more than 60 consecutive days by written notice to Contractor and Engineer. Such notice will fix the date on which Work will be resumed. Contractor shall resume the Work on the date so fixed. Contractor shall be entitled to an adjustment in the Contract Price or an extension of the Contract Times, or both, directly attributable to any such suspension.

  • Quality of Services (a) The Consultant shall be responsible for the professional quality, technical accuracy, and the coordination of all designs, drawings, specifications, and other services furnished pursuant to this Agreement. (b) To that end, the Consultant shall correct or shall revise, without additional compensation, any errors or omissions in its work product or shall make such revisions as are necessary as the result of the failure of the Consultant to provide an accurate, more efficient, and properly constructable product in its designs, drawings, specifications, or other services. (c) The County's review/approval/acceptance of or payment for the services required by this Agreement shall NOT be construed to operate as a waiver of any rights or of any cause of action arising out of the performance of this Agreement. Additionally, the Consultant shall be and remain liable to the County in accordance with applicable law for all damages to the County caused by the Consultant's negligent performance of any of the services furnished under this Agreement. (d) The rights and remedies of the County provided for under this Agreement are in addition to any other rights and remedies otherwise provided by law.

  • CORRECTION OF WORK 13.2.1 The Contractor shall be responsible for correcting all Work which the Architect has found to be defective or which fails to conform to the Contract Documents whether observed be- fore or after Substantial Completion and whether or not fabricated, installed or completed. The Contractor shall bear all costs of correcting such rejected Work, including compensation for the Architect's and the State’s additional services made necessary thereby. 13.2.2 If, within one year after the Date of Substantial Completion of the Work or designated portion thereof or within one year after acceptance by the State of designated equipment or within such longer period of time as may be prescribed by law or by the terms of any applicable special warranty required by the Contract Documents, any of the Work is found to be defective or not in accordance with the Contract Documents, the Contractor shall correct it promptly after receipt of a written notice from the State to do so unless the State has previously given the Contractor a written acceptance of such condition. This obligation shall survive termination of the Contract. The State shall give such notice promptly after discovery of the condition. 13.2.3 The Contractor shall remove from the site all portions of the Work which are defective or non-conforming and which have not been corrected under Subparagraphs 4.5.1, 13.2.1 and 13.2.4 If the Contractor fails to correct defective or nonconforming Work as provided in Subparagraphs 4.5.1, 13.2.1 and 13.2.2, the State may correct it in accordance with Paragraph 13.2.5 If the Contractor does not proceed with the correction of such defective or non- conforming Work within a reasonable time fixed by written notice from the Architect, the State may remove it and may store the materials or equipment at the expense of the Contractor. If the Contractor does not pay the cost of such removal and storage within ten days thereafter, the State may upon ten additional days written notice sell such Work at auction or at private sale and shall account for the net proceeds thereof, after deducting all the costs that should have been borne by the Contractor, including compensation for the Architect's and the State’s additional services and expenses made necessary thereby. If such proceeds of sale do not cover all costs which the Contractor should have borne, the difference shall be charged to the Contractor and an appropriate Change Order shall be issued. If the payments then or thereafter due the Contractor are not sufficient to cover such amount, the Contractor shall pay the difference to the State. 13.2.6 The Contractor shall bear the cost of making good all work of the State or separate contractors destroyed or damaged by such correction or removal. 13.2.7 Nothing contained in this Paragraph 13.2 shall be construed to establish a period of limitation with respect to any other obligation which the Contractor might have under the

  • QUALITY OF GOODS 5.1 Voip Unlimited warrants that on delivery, the Goods shall: (a) conform in all material respects with the Goods Specification; (b) be free from material defects in design, material and workmanship; (c) be of satisfactory quality (within the meaning of the Sale of Goods Act 1979); and (d) be fit for any purpose held out by Voip Unlimited. 5.2 Subject to clause 5.3, if: (a) the Customer gives notice in writing within a reasonable time of discovery that some or all of the Goods do not comply with the warranty set out in clause 5.1; (b) Voip Unlimited is given a reasonable opportunity of examining such Goods; and (c) the Customer (if asked to do so by Voip Unlimited) returns such Goods to Voip Unlimited's place of business at Voip Unlimited's cost, Voip Unlimited shall, at its option, repair or replace the defective Goods, or refund the price of the defective Goods in full. 5.3 Voip Unlimited shall not be liable for the Goods' failure to comply with the warranty in clause 5.1 if: (a) the Customer makes any further use of such Goods after giving a notice in accordance with clause 5.2; (b) the defect arises because the Customer failed to follow Voip Unlimited's oral or written instructions as to the storage, installation, commissioning, use or maintenance of the Goods or (if there are none) good trade practice; (c) the defect arises as a result of Voip Unlimited following any drawing, design or Goods Specification supplied by the Customer; (d) the Customer alters or repairs such Goods without the written consent of Voip Unlimited; (e) the defect arises as a result of fair wear and tear, wilful damage, negligence, or abnormal working conditions; (f) the Goods differ from the Goods Specification as a result of changes made to ensure they comply with applicable statutory or regulatory standards. 5.4 Except as provided in this clause 5, Voip Unlimited shall have no liability to the Customer in respect of the Goods' failure to comply with the warranty set out in clause 5.1. 5.5 The terms of these Conditions shall apply to any repaired or replacement Goods supplied by Voip Unlimited under clause 5.2.

  • Rejection of Work Using the Notice of Non-Conforming Work procedures outlined in the General Conditions, the Design Professional shall reject work that does not comply with the requirements of the Contract Documents or that does not comply with the applicable laws and codes. The Design Professional shall have authority to order testing of the Work, as is provided in the Contract Documents or as otherwise required in its judgment, whether such work is fabricated, installed, or completed.

  • Location of Work The Executive shall be based in the United States in West Orange, New Jersey. However, the Executive agrees to undertake whatever domestic and worldwide travel is required by the Company. The Executive shall not be required or permitted to relocate without the mutual, written consent of the Executive and the Company.

  • Quality Specifications SANMINA-SCI shall comply with the quality specifications set forth in its Quality Manual, incorporated by reference herein, a copy of which is available from SANMINA-SCI upon request.

  • Inspection of Work It is FIRST PARTY's obligation to make the work product available for CITY's inspections and periodic reviews upon request by CITY.

  • Quality of Service Contractor shall perform its services with care, skill, and diligence, in accordance with the applicable professional standards currently recognized by such profession, and shall be responsible for the professional quality, technical accuracy, completeness, and coordination of all reports, designs, drawings, plans, information, specifications, and/or other items and services furnished under this Agreement. Contractor shall, without additional compensation, correct or revise any errors or deficiencies immediately upon discovery in its reports, drawings, specifications, designs, and/or other related items or services.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!