Reasonable Support of the Authority. The Parties agree that the Authority shall assist the Concessionaire with all reasonable support to the Concessionaire required for fulfilment of all obligations specified in Article 11.
Reasonable Support of the Authority Sample Clauses
Related to Reasonable Support of the Authority
Obligations of the Authority (i) The Authority shall, at its own cost and expense, undertake, comply with and perform all its obligations set out in this Agreement or arising hereunder. (ii) The Authority shall be responsible for the correctness of the Scope of the Project, Project Facilities, Specifications and Standards and the criteria for testing of the completed Works. (iii) The Authority shall, upon submission of the Performance Security as per the RFP by the Contractor, shall provide to the Contractor: (a) No less than 90% (ninety per cent) of the required Right of Way of the Construction Zone of total length of the Project Highway within a period of 30 (thirty) days from the date of this Agreement, which shall be in contiguous stretches of length not less than 1( One) kilometre. (b) approval of the general arrangement drawings (the “GAD”) from railway authorities to enable the Contractor to construct road over- bridges/ under- bridges at level crossings on the Project Highway in accordance with the Specifications and Standards, and subject to the terms and conditions specified in such approval, within a period of 60 (sixty) days from the Appointed Date, and reimbursement of all the costs and expenses paid by the Contractor to the railway authorities for and in respect of the road over- bridges/ under bridges; and7 (c) all environmental clearances as required under Clause 4.3.8 (iv) Delay in providing the Right of Way or approval of GAD by railway authorities, as the case may be, in accordance with the provisions of Clause 3.1 (iii) shall entitle the Contractor to Damages in a sum calculated in accordance with the provisions of Clause 8.3 of this Agreement and Time Extension in accordance with the provisions of Clause 10.5 of this Agreement. For the avoidance of doubt, the Parties agree that the Damages for delay in approval of GAD by the railway authorities for a particular road over-bridge/ under-bridge shall be deemed to be equal to the Damages payable under the provisions of Clause 8.3 for delay in providing Right of Way for a length of 2 (two) kilometre for each such road over-bridge/ under-bridge.
Power and Authority; Due Authorization; Execution and Delivery The execution and delivery by such Seller Party of this Agreement and each other Transaction Document to which it is a party, and the performance of its obligations hereunder and thereunder and, in the case of Seller, Seller’s use of the proceeds of Purchases made hereunder, are within its powers and authority, corporate or otherwise, and have been duly authorized by all necessary action, corporate or otherwise, on its part. This Agreement and each other Transaction Document to which such Seller Party is a party has been duly executed and delivered by such Seller Party.
The Authority As to the Authority, the following section shall survive discharge: Section 2.3 (right to conduct audit).
Decision of the Arbitrator The decision of the arbitrator shall be final, binding, and enforceable on the Parties. The arbitrator shall have the power to dispose of a grievance by any arrangement deemed just and equitable. However, the arbitrator shall not have the power to change this Agreement by altering, modifying, or amending any provision.
Power of the Authority to undertake works (i) In the event the Parties are unable to agree to the proposed Change of Scope Orders in accordance with Clause 13.2, the Authority may, after giving notice to the Contractor and considering its reply thereto, award such Works or services to any person or agency on the basis of open competitive bidding. It is also agreed that the Contractor shall provide assistance and cooperation to the person or agency who undertakes the works or services hereunder. The Contractor shall not be responsible for rectification of any Defects, but the Contractor shall carry out maintenance of such works after completion of Defect Liability Period of work by other person or agency during the remaining period of this agreement without any extra payment. (ii) The Works undertaken in accordance with this Clause 13.5 shall conform to the Specifications and Standards and shall be carried out in a manner that minimises the disruption in operation of the Project Highway. The provisions of this Agreement, insofar as they relate to Works and Tests, shall apply mutatis mutandis to the Works carried out under this Clause 13.5.
Representations of the Adviser The Adviser represents, warrants and further covenants as follows:
Indemnification of the Agent The Company agrees to indemnify and hold harmless the Agent, its officers and employees, and each person, if any, who controls the Agent within the meaning of the Securities Act or the Exchange Act against any loss, claim, damage, liability or expense, as incurred, to which the Agent or such officer, employee or controlling person may become subject, under the Securities Act, the Exchange Act, other federal or state statutory law or regulation, or the laws or regulations of foreign jurisdictions where Shares have been offered or sold or at common law or otherwise (including in settlement of any litigation), insofar as such loss, claim, damage, liability or expense (or actions in respect thereof as contemplated below) arises out of or is based upon (i) any untrue statement or alleged untrue statement of a material fact contained in the Registration Statement, or any amendment thereto, including any information deemed to be a part thereof pursuant to Rule 430B under the Securities Act, or the omission or alleged omission therefrom of a material fact required to be stated therein or necessary to make the statements therein not misleading; or (ii) any untrue statement or alleged untrue statement of a material fact contained in any Free Writing Prospectus that the Company has used, referred to or filed, or is required to file, pursuant to Rule 433(d) of the Securities Act or the Prospectus (or any amendment or supplement thereto), or the omission or alleged omission therefrom of a material fact necessary in order to make the statements therein, in the light of the circumstances under which they were made, not misleading and to reimburse the Agent and each such officer, employee and controlling person for any and all expenses (including the fees and disbursements of counsel chosen by the Agent) as such expenses are reasonably incurred by the Agent or such officer, employee or controlling person in connection with investigating, defending, settling, compromising or paying any such loss, claim, damage, liability, expense or action; provided, however, that the foregoing indemnity agreement shall not apply to any loss, claim, damage, liability or expense to the extent, but only to the extent, arising out of or based upon any untrue statement or alleged untrue statement or omission or alleged omission made in reliance upon and in conformity with written information furnished to the Company by the Agent expressly for use in the Registration Statement, any such Free Writing Prospectus or the Prospectus (or any amendment or supplement thereto), it being understood and agreed that the only such information furnished by the Agent to the Company consists of the information described in subsection (b) below. The indemnity agreement set forth in this Section 6(a) shall be in addition to any liabilities that the Company may otherwise have.
Instructions of the Company The Company shall have the right, by one or more instruments in writing executed and delivered to the Collateral Agent, the Custodial Agent or the Securities Intermediary, as the case may be, to direct the time, method and place of conducting any proceeding for the realization of any right or remedy available to the Collateral Agent, or of exercising any power conferred on the Collateral Agent, the Custodial Agent or the Securities Intermediary, as the case may be, or to direct the taking or refraining from taking of any action authorized by this Agreement; provided, however, that (i) such direction shall not conflict with the provisions of any law or of this Agreement and (ii) the Collateral Agent, the Custodial Agent and the Securities Intermediary shall be adequately indemnified as provided herein. Nothing in this Section 8.2 shall impair the right of the Collateral Agent in its discretion to take any action or omit to take any action which it deems proper and which is not inconsistent with such direction.
Power and Authority; Due Authorization The Servicer has all necessary power and authority to (i) execute and deliver this Agreement and the other Transaction Documents to which it is a party and (ii) perform its obligations under this Agreement and the other Transaction Documents to which it is a party and the execution, delivery and performance of, and the consummation of the transactions provided for in, this Agreement and the other Transaction Documents to which it is a party have been duly authorized by the Servicer by all necessary action.
Jurisdiction of the Arbitrator The arbitrator shall have no power to alter, add to, subtract from the terms of this Agreement. The arbitrator's decision will be based upon the specific provisions of this Agreement. This arbitration provision shall be for grievances only.
