Damage, Destruction or Condemnation (a) In the event of damage to or destruction of any portion of the Project resulting from fire or other casualty during the Term, or in the event any portion of the District is condemned or taken for any public or quasi-public use or title thereto is found to be deficient during the Term, the net proceeds of any insurance relating to such damage or destruction, the net proceeds of such condemnation or taking or the net proceeds of any realization on title insurance shall be paid into, and used in accordance with a construction escrow agreement reasonably satisfactory to the City and Developer ("Casualty Escrow").
(b) If, at any time during the Term, the Project or any part thereof shall be damaged or destroyed by a casualty (the "Damaged Facilities"), Developer, at its sole cost and expense, shall commence and thereafter proceed as promptly as possible to repair, restore and replace the Damaged Facilities as nearly as possible to their condition immediately prior to the casualty and shall be entitled to draw upon the Casualty Escrow for payment of said costs.
(c) If at any time during the Term, title to the whole or substantially all of the Project which has previously been conveyed to Developer shall be taken in condemnation proceedings or by right of eminent domain, Developer, at its sole discretion, may terminate this Agreement as of the date of such taking. For purposes of this Section 6.07(c), "substantially all of the District" shall be deemed to have been taken if the City and Developer, each acting reasonably and in good faith, determine that the untaken portion of the District, including the parking improvements, cannot be practically and economically used by Developer for the purposes and at the times contemplated by this Agreement.
(d) In the event of condemnation of less than the whole or substantially all of the District which has previously been conveyed to Developer during the Term, Developer, at its sole cost and expense, shall commence and thereafter proceed as promptly as possible to repair, restore and replace the remaining part of the Project, as nearly as possible, to its former condition, and shall be entitled to draw upon the Casualty Escrow for payment of said costs.
(e) Nothing in this section will require the Developer to expend funds in excess of the Casualty Escrow for the repair, restoration and/or replacement of the Damaged Facilities.
DAMAGE OR DESTRUCTION OF PREMISES If the Premises are damaged by fire or other casualty, but are not rendered untenantable for Tenant’s business, either in whole or in part, Landlord shall cause such damage to be repaired without unreasonable delay and the Annual Rent shall not xxxxx. If by reason of such casualty the Premises are rendered untenantable for Tenant’s business, either in whole or in part, Landlord shall cause the damage to the physical structure of the Building (excluding any tenant improvements or alterations therein) to be repaired or replaced without unreasonable delay, and, in the interim, the Annual Rent shall be proportionately reduced as to such portion of the Premises as is rendered untenantable, however, Tenant must vacate the portion of the Premises deemed untenantable during the period of Landlord’s repairs for such abatement of Annual Rent to be effective. Any such abatement of rent shall not create an extension of the Term. Provided, however, if by reason of such casualty, the Premises are rendered untenantable in some material portion, and Landlord, in its commercially reasonable estimation, determines that the amount of time required to repair the damage using due diligence is in excess of two hundred ten (210) days (as measured from the date of casualty), then Landlord shall provide written notice thereof to Tenant, to be given to Tenant within seventy-five (75) days following the date of such casualty, and either party shall then have the right to terminate this Lease by giving written notice of termination within thirty (30) days after the date of said notice from Landlord. In such event, the Annual Rent shall (i) xxxxx as of the date of such casualty in proportion to the part of the Premises rendered untenantable, and (ii) xxxxx entirely as of the effective date of the termination of this Lease. Notwithstanding the foregoing, in the event the casualty giving rise to an election to terminate is caused by the negligence, misconduct or acts or omissions of Tenant or Tenant’s Invitees, Tenant shall have no right to terminate this Lease. Notwithstanding the other provisions of this Section, in the event there should be a casualty loss to the Premises during the last two (2) Lease Years of the Term, Landlord may, at its option, terminate this Lease by giving written notice to Tenant within thirty (30) days after the date of the casualty and the Annual Rent shall xxxxx as of the date of such notice. Except as provided herein, Landlord shall have no obligation to rebuild or repair in case of fire or other casualty, and no termination under this Section shall affect any rights of Landlord or Tenant hereunder arising from the prior defaults of the other party. Tenant shall give Landlord immediate notice of any fire or other casualty in the Premises. Notwithstanding anything contained in this Section to the contrary, in no event shall Landlord be required to expend more funds in connection with the repair or restoration of the Premises than the amount received by Landlord from the proceeds of any insurance policies maintained by Landlord.
Condemnation or Casualty Seller agrees to give Purchaser prompt written notice of any fire or other casualty occurring to all or any portion of the improvements at the Real Property and/or Personalty between the date hereof and the date of closing. If prior to the closing, there shall occur:
(i) damage to the improvements at the Property caused by fire or other casualty which would cost 5% of the Purchase Price of the Property or more to repair based on the estimate of a reputable third party contractor chosen by Seller; or
(ii) the taking or condemnation of all or any portion of the Real Property and/or the improvements as aforesaid as would materially interfere with the use thereof; then, if any of such events set forth in (i) or (ii) above occurs, Buyer or Seller, at its option, may terminate its obligations under this Agreement by written notice given to the other within seven (7) days after Buyer has received the notice referred to above or at the closing, whichever is earlier. If Buyer or Seller does not elect to terminate its obligations as aforesaid, the closing shall take place as provided herein without an abatement of the purchase price (except that Buyer shall be allowed a credit for any deductible under Seller's insurance) and there shall be assigned to the Buyer at closing, all interest of the Seller in and to any insurance proceeds or condemnation awards which may be payable to Seller on account of such occurrence. If, prior to the closing, there shall occur:
(i) damage to the Property caused by fire or other casualty which would cost less than 5% of the Purchase Price of the Property based on the estimate of a reputable third party contractor chosen by Seller to which Buyer has no reasonable objection; or
(ii) the taking or condemnation of all or any portion of the said Real Property and/or improvements as aforesaid which is not material to the use, thereof; then, if any of such events set forth in (i) or (ii) above occurs, Buyer shall have no right to terminate its obligations under this Agreement, but there shall be assigned to Buyer at closing all interest of Seller in and to any insurance proceeds or condemnation awards which may be payable to Seller on account of any such occurrence, and in addition, Buyer shall be allowed a credit for any deductible under Seller's insurance policy. Seller shall be responsible for maintaining fire and extended coverage insurance prior to closing as is currently in place.
Casualty or Condemnation If, prior to the Closing, the Improvements or any material portion thereof (having a replacement cost equal to or in excess of $100,000 are damaged or destroyed by fire or casualty, or are taken by eminent domain by any governmental entity, and Seller is unable to restore such damage or destruction prior to the Closing Date in the case of a casualty, then Buyer shall have the option, exercisable by written notice given to Seller at or prior to the Closing, to terminate this Agreement, whereupon all obligations of all parties hereto shall cease, the Deposit shall be returned to Buyer, and this Agreement shall be void and without recourse to the parties hereto except for provisions which are expressly stated to survive such termination. If Buyer does not elect to terminate this Agreement as aforesaid or if such damage or destruction or taking has a replacement cost or is in an amount of less than $100,000, Buyer shall proceed with the consummation of the Closing (to the extent then otherwise obligated to do so) without reduction or offset of the Purchase Price, and in such case, unless the Seller shall have previously restored the Real Property to its condition prior to the occurrence of any such damage or destruction, Seller shall pay over or assign to Buyer all amounts received or due from, and all claims against, any insurance company or governmental entity as a result of such destruction or taking, and Seller shall pay the applicable deductible amount under the insurance maintained by Seller. In the event of any such casualty or condemnation, Seller agrees to (a) provide Buyer with copies of all written communications between Seller or the Partnership and their insurance carriers or the applicable governmental authorities, as applicable, the subject matter of which is the adjustment of insurance proceeds or condemnation awards, and (b) allow Buyer to review and make comments to any proposed settlement arrangement proposed to be entered into by Seller or the Partnership with any such third party; provided, that after the Inspection Period, if Buyer has not terminated this Agreement, Seller shall not enter into any settlement arrangement concerning casualty or condemnation in excess of $50,000 without obtaining the prior written consent of Buyer, which consent may be granted or withheld in Buyer’s sole discretion.
Repair Concessionaire shall, prior to the commencement of the Concession Operation under this Agreement, provide to Department a type-written concession equipment maintenance plan for the State-owned equipment located on the Concession Premises, together with a schedule for preventative maintenance and a report on maintenance completion and equipment condition. Failure to comply with this preventative maintenance schedule shall result in Concessionaire being responsible for all repairs and/or replacement of equipment. The review and Department inspection of the Concession Premises and its equipment will be conducted during routine inspection of the Concession Premises and as a part of the Mandatory Compliance and Performance Evaluation Meetings.
Damage or Destruction Condemnation (a) In the event the Assigned Space or the improvements thereon are damaged by any casualty which is required to be insured against by Permittee pursuant to this Permit, then Permittee shall, in accordance with all applicable requirements of this Permit (including without limitation Section 1(2) above), repair such damage (and replace any Trade Equipment damaged by such casualty) as soon as reasonable possible, at its own cost, and this Permit shall continue in full force and effect, with no abatement in the Rent payable by Permittee to Port under Paragraph E of this Permit.
(b) In the event the Assigned Space or the improvements thereon are damaged by any casualty which is not required to be insured against by Permittee pursuant to the provisions of this Permit, then Port may, at Port’s option, either (i) repair such damage as soon as reasonably possible at Port’s expense, in which event this Permit shall continue in full force and effect, and there shall be no abatement in the Rent payable by Permittee to Port under Paragraph E of this Permit, or (ii) give written notice to Permittee within sixty (60) days after the date of occurrence of such damage of Port’s intention to terminate this Permit, in which event such termination shall be effective as of the date of the occurrence of such damage; provided, however, that notwithstanding the foregoing: (x) If such damage was caused by the act or omission of Permittee or any principal, affiliate, contractor, employee, agent, licensee or invitee of Permittee, then Permittee shall, in accordance with all applicable provisions of this Permit (including without limitation Section 1(2) above), repair such damage promptly and at its sole cost and expense, this Permit shall remain in full force and effect, and there shall be no abatement in the Rent payable by Permittee to Port under Paragraph E above; and (y) If such damage is not covered by subsection (b)(ii)(x) above, and if such damage occurred during the last twelve months of the Term, then either party shall have the right, by written notice given to the other within sixty (60) days after the date of occurrence of such damage, to terminate this Permit as of the date of such damage, in which event all proceeds of the insurance against casualty that Permittee was required to maintain pursuant to this Permit shall be paid to Port.
(c) If the Assigned Space is damaged or destroyed by casualty, Permittee shall have no claim against Port for any damage suffered by reason of any such damage or destruction, or for any required repair or restoration. Port and Permittee hereby waive the provisions of California Civil Code Sections 1932 and 1933, and of any other statutes which relate to the termination of a Permit when leased property is destroyed and agree that any such event shall be governed by the terms of this Permit.
(a) If the whole of the Assigned Space should be taken by any public or quasi-public authority under the power or threat of eminent domain, then, in such event, on the earlier of the date title to the Assigned Space vests in such public or quasi-public authority, or the date on which said public or quasi-public agency takes possession of the Assigned Space, this Permit shall terminate with respect to Port’s and Permittee’s future obligations hereunder, but said termination shall not affect Port’s and Permittee’s rights to any compensation or damages for, on the account of, or arising out of such taking. For any period of time prior to termination during which Permittee (involuntarily on account of such taking or any proceedings related thereto) does not have full use of the Assigned Space, the monthly Rent due hereunder shall be equitably reduced. In the event of such a taking, the Port shall be entitled to receive all sums in the award of damages and compensation arising by reason of such taking except that an amount therefrom equal to the fair market value of Permittee’s leasehold interest in the Assigned Space (as of the date of valuation of the taking) shall be paid to Permittee.
(b) If a substantial portion of the Assigned Space should be taken so as to impair materially the use of the Assigned Space as contemplated by the Permit, then on the earlier of the date title to such portion of the Assigned Space vests in such public or quasi-public agency, or the date on which such public or quasi-public agency takes possession of such portion of the Assigned Space and Permittee no longer has full possession of such portion, this Permit shall terminate with respect to Port’s and Permittee’s future obligations hereunder, but said termination shall not affect Port’s or Permittee’s rights to any compensation or damages for, on account of, or arising out of such taking. For any period of time prior to termination during which Permittee (involuntarily on account of such taking or any proceedings related thereto) does not have full use of the Assigned Space, the monthly Rent due hereunder shall be equitably reduced. In the event of such a substantial taking, the award of damages and compensation arising by reason of such taking shall be distributed in the same manner as the last sentence of Section 37(2)(a) above.
(c) If a taking shall occur which does not result in termination of this Permit as provided in the previous subsections of this Section 37(2), but which requires the portion of the Assigned Space not so taken to be reconstructed and restored so as to be constituted an architecturally complete unit suitable for use by Permittee, all compensation and damages payable for or on account of such taking shall be payable to Permittee, and shall be held in a separate account approved in writing by Port in trust by Permittee to be used by Permittee in accordance with all applicable requirements of this Permit (including without limitation Section 1(2) above) solely to reconstruct and restore the portion of the Assigned Space not so taken to an architecturally complete unit suitable for use by Permittee; and the monthly Rent payable by Permittee hereunder shall be equitably reduced during the time Permittee does not have full use of the Assigned Space as a result of such taking to account for the reduced economic value to Permittee, if any, occasioned by reason of such taking. The balance of any compensation and damages remaining after the reconstruction and restoration contemplated by this subsection shall be distributed in the same manner as distribution of damages and compensation for a total taking under the last sentence of Section 37(2)(a) above. In the event of a taking covered by this subsection (c), Port shall send to Permittee an amendment to this Permit showing the deletion of that portion of the Assigned Space that was the subject of this taking, and this Permit shall be deemed amended thereby.
(d) If a taking shall occur which does not result in a termination of this Permit as provided in the previous subsections of this Section 37(2), and which does not require any portion of the Assigned Space not so taken to be reconstructed and restored so as to constitute an architecturally complete unit suitable for use by Permittee, the proceeds shall be distributed in accordance with the last sentence of Section 37(2)(a) above. Permittee, however, shall be entitled to an equitable reduction in the monthly Rent.
(e) No taking of Permittee’s leasehold estate in the Assigned Space or any part thereof without a taking of the fee shall terminate or give Permittee the right to surrender this Permit, nor excuse the taker of such leasehold estate, including any successor in interest thereto, from full performance of the covenants for the payment of the Rent and other charges or any other obligations hereunder capable of performance by the taker of such leasehold estate, including any successor in interest thereto, after any such taking, but in such case, all compensation and damages payable for or on account of such taking shall be payable to and be the sole property of Port. During any period of time that Permittee is not in possession of the Assigned Space, or any portion thereof, as a result of the taking of any portion of its leasehold estate hereunder, but only during such period of time, (1) Permittee shall not be obligated to pay or in any way be liable for the payment of any Rent or to perform any of the other obligations or covenants otherwise to be performed by it hereunder with respect to, but only with respect to the portion of the Assigned Space affected by such taking, (2) the Port shall look solely to the taker of such leasehold interest, including the successors in interest thereto and any party then in possession of all or such portion of the Assigned Space affected by such taking for the payment of the Rent and the performance of the other obligations and covenants hereunder with respect to such portion of the Assigned Space, and (3) as between Port and Permittee, Port shall not forfeit or terminate this Permit for breach by the taker of such leasehold interest, including its successors in interest thereto and any party then in possession, of any obligation or covenant hereunder, including the obligation to pay the Rent. Any taking that is the subject of this subsection (e) shall not extend the Term of this Permit.
(f) In the event of any taking of any portion of the Assigned Space, Permittee shall be entitled to receive all compensation and damages arising from such taking and payable for or on account of the Permittee’s Trade Equipment located on the portion of the Assigned Space so taken, except for those trade fixtures and equipment that pursuant to this Permit are to remain with the Assigned Space on surrender.
(g) Except as otherwise expressly provided in this Section 37(2), no taking shall reduce or xxxxx Permittee’s obligation to pay the Rent during the Term of this Permit. Where Section 37(2) expressly provides for a reduction in the Rent payable by Permittee, if the parties cannot agree on the amount of such reduction, the same shall be determined by Arbitration. Such arbitration shall be conducted in accordance with the Commercial Arbitration Rules of the American Arbitration Association. The arbitrators shall have no power to modify any of the provisions of this Permit and their jurisdiction is limited accordingly. Each party hereby consents to the entry of judgment by any court having jurisdiction in accordance with the arbitration decision. No change in the Arbitration Rules which would deprive a party of the rights to be represented by counsel, to present evidence or to cross-examine witnesses presented by the other party shall be effective in any arbitration proceeding arising out of this Permit. Any arbitration provided for herein shall be conducted in the Port’s offices in Alameda County, California. Disputes under this Permit shall be subject to Arbitration only to the extent expressly provided for in this subsection (h).
(h) Permittee acknowledges the Port’s reserved power upon payment of just compensation to exercise its power of eminent domain as to the leasehold estate created hereunder; provided, however, that the foregoing acknowledgment shall not be deemed or construed to prejudice or waive any rights of Permittee to challenge or object to any attempt by the Port so to exercise such power.
Damage, Destruction and Condemnation (a) Seller will bear the risk of loss for any damage, destruction, or condemnation that may occur prior to Closing. If any portion of the Property is damaged or destroyed prior to Closing, Purchaser may elect to terminate this Agreement, unless prior to Closing all that damage has been repaired and the Improvements restored or replaced to their condition prior to the damage. If any material portion of the Property is condemned or taken prior to Closing, Purchaser may elect to terminate this Agreement.
(b) Purchaser's election under this Section with respect to any condemnation or taking will be exercised by written notice to Seller within twenty (20) days after written notice from Seller of the condemnation or taking. Purchaser's election under this Section with respect to any damage or destruction not repaired prior to Closing will be exercised by written notice to seller within twenty (20) days of the later to occur of:
(i) written notice from Seller of the damage or destruction and Seller's inability to repair and restore prior to Closing; or
(ii) written notice from Seller's insurance carrier regarding the estimated cost of repair, replacement, or reconstruction and the portion of the repair, replacement, or reconstruction for which insurance proceeds will be made available. The Closing Date will be extended as necessary to give Purchaser time to make the election.
(c) If Purchaser elects to terminate this Agreement under this Section, neither party will have any further rights, duties, or obligations. If Purchaser does not elect to terminate this Agreement, this Agreement will remain in full force and the purchase contemplated in this Agreement, less any interest taken by condemnation, will be effected, and at the Closing, Seller will pay the Purchaser the amount of any deductible under Seller's insurance policy and will assign, transfer, and set over to Purchaser all of Seller's right, title, and interest to any condemnation awards or insurance proceeds that have been or that may later be made for the taking or destruction.
Repairs If this Lease is not terminated as provided above, it shall continue in full force and effect, and Landlord shall promptly and diligently, subject to reasonable delays for insurance adjustment, and subject to all other terms of this Article, restore the Premises, the Common Areas and the portions of the Project serving the Premises and Tenant shall assign to Landlord all insurance proceeds payable to Tenant as to any Alterations; provided that if the cost of the restoration of any Alterations by Landlord exceeds the amount of Tenant’s insurance proceeds therefor, as assigned by Tenant to Landlord, such excess shall be paid by Tenant to Landlord prior to Landlord’s restoration thereof. Such restoration shall be to substantially the same condition of such items as prior to the casualty, except for modifications (a) required by Law; (b) required by the holder of a mortgage on the Building, or the lessor of a ground or underlying lease with respect to the Property; or (c) to the Common Areas reasonably deemed desirable by Landlord, and which are consistent with the character of the Project. No such modifications shall materially impair access to the Premises and any Common Areas serving the Premises. Tenant shall be responsible, at its sole cost and expense, for the repair, restoration, and replacement of Tenant’s Property. Landlord shall not be liable for any loss of business, inconvenience, or annoyance arising from any casualty or any repair or restoration of any portion of the Premises, the Building, or the Project as a result of any damage from any casualty. All work by Tenant shall be subject to the terms and conditions of Article 11.
Construction of the Tenant Improvements 3.1 The Leased Premises consists of two existing, contiguous spaces which were previously leased to other tenants. Tenant is taking the Leased Premises in its “as is” condition, subject to modifications as shown on the Plans (as hereafter defined) to be prepared by Tenant (“Tenant Improvements”). The Landlord shall provide all necessary labor and materials and perform all the work required to complete the Tenant Improvements in order to ready the same for Tenant’s occupancy. Tenant’s designated representative for all work pertaining to the Tenant Improvements shall be Xxxx Xxxxxxxx or such other person as is designated in writing by Tenant (“Representative”). The Landlord shall supervise and direct the work on the Tenant Improvements using Landlord’s best skill and attention, and Landlord shall be solely responsible for all construction means, methods, techniques, sequences and procedures and for coordinating all portions of the work on the Tenant Improvements. Landlord warrants to the Tenant that all materials and equipment incorporated in the Tenant Improvements will be new unless otherwise specified, and that all work on the Tenant Improvements will be of good quality, free from known faults and defects, and in substantial conformity with the Plans.
(a) Landlord shall complete the Tenant Improvements in a good and workmanlike manner and in substantial accordance with plans and specifications (“Plans”) to be prepared by Tenant’s architect, CUH2A. The Plans shall be provided to Landlord on or before September 1, 2003 and shall be in sufficient detail to permit Landlord to apply for a building permit for the Tenant Improvements (which Landlord shall promptly do), and to prepare a construction budget for the construction of the Tenant Improvements (“Construction Budget”). In the event Tenant does not deliver the Plans to Landlord by the date set forth above, such failure shall not delay the date for commencement of the rent, which shall be presumed to be the projected Commencement Date set forth in paragraph 2. The Construction Budget shall set forth the lump sum amount payable by Tenant to Landlord for the construction of the Tenant Improvements, which amount shall include Landlord’s standard xxxx-up for general conditions, overhead and profit, which total in the aggregate 20%. The only exception to the lump sum amount shall be the actual fees charged by the Township of South Brunswick for construction permits in connection with the Tenant Improvements, which sums shall be paid by Tenant as set forth hereafter. Landlord shall submit the Construction Budget to Tenant for its approval. Tenant shall give written notice to Landlord within five business days of receipt, as to whether or not the Construction Budget is acceptable. If Tenant does not accept the Construction Budget during such five business day period, then the parties agree to negotiate in good faith to reach an agreement on the Construction Budget. Landlord shall not be obligated to order any equipment or commence work until Tenant has approved the Construction Budget. A complete set of the agreed upon Plans, and the agreed upon Construction Budget, shall be initialed by and distributed to Landlord and Tenant.
(b) Neither the Construction Budget nor the Plans shall be changed or altered in any way except by change order approved in writing by Landlord and Tenant (“Change Order”). All Change Orders shall be valid and binding upon Landlord and Tenant only if authorized by written Change Order signed by Landlord and Tenant’s Representative prior to commencement of the work on the Tenant Improvements reflected thereby. The cost or credit to the Tenant due to any Change Order shall be determined per the terms of such Change Order. In the event the Change Order increases the cost set forth in the Construction Budget, then Landlord shall submit an invoice to Tenant and Tenant shall pay the invoice upon completion of work or upon the ordering of any equipment, whichever is applicable. The Landlord shall have the right to substitute for the materials and equipment required by the Plans, materials and equipment of equal quality and standard, provided said substitutions conform with applicable building codes and are the subject of a Change Order. Each and every Change Order shall state whether the change will entail a delay in the date of Substantial Completion. Any Change Order requested by Tenant which results in a delay to the date of Substantial Completion shall not delay the date for the commencement of the payment of rent.
(a) The Landlord may secure and advance payment for the construction permits and for all other permits and governmental fees, licenses and inspections necessary for the proper execution and completion of the Tenant Improvements. Tenant shall pay such amounts to Landlord not later than 10 business days after receipt of an invoice therefore Landlord shall not, however, be responsible for securing any environmental or operating permits or certifications which are required in order for Tenant to actually conduct its business.
(b) Tenant shall be responsible for providing Landlord with, and bearing the cost of sufficient copies of the Plans, and sufficient copies of any revisions made to the Plans, in order to obtain the permits and efficiently manage the construction of the Tenant Improvements. In the event any Change Orders are required during construction, Tenant shall be responsible for all costs related to the preparation and reproduction of plans therefore, unless the Change Order was solely initiated by Landlord, in which case Landlord shall be responsible for such costs. After construction is complete, Tenant shall be responsible for all costs related to the reproduction of “as built” Plans. In all instances where Plans are required, Tenant shall provide Landlord with a reproducible set. Landlord will also be provided with a current plot file containing the Plans at no cost to Landlord. Tenant agrees to have its Architect execute Exhibit “A” affirming Landlord’s right to the Plans.
(a) Tenant shall pay Landlord directly for the construction costs of Tenant Improvements in accordance with the schedule attached hereto as Exhibit “B”. The only exception to Tenant’s responsibility to pay for all construction costs shall be for the work necessary to upgrade the existing HVAC reheat system currently in the space previously occupied by Biomira, Inc. (currently known as 0000 Xxxxxxxx Xxxxxxxxx), which cost is estimated to be $150,000 and will he divided equally between the parties. In the event Tenant fails to pay to Landlord any sum set forth on Exhibit “B” when it is due, Landlord shall not be obligated to commence or continue work on the Tenant Improvements. Such failure to pay shall constitute a default under this Lease, but shall not delay the Commencement Date of this Lease, which shall be presumed to be the projected Commencement Date set forth in paragraph 2; or any of Tenant’s obligations hereunder including, without limitation, Tenant’s obligation to pay all Rent. In the event that Tenant fails to pay to Landlord, upon Substantial Completion of the Tenant Improvements, a sum equal to the remaining balance then due, such failure shall constitute a default under this Lease; and Tenant shall not be permitted to occupy the Leased Premises; and Tenant shall commence payment of all Rent; and Landlord shall be entitled to all rights and remedies available hereunder, at law or in equity, which rights shall be cumulative. All sums so owing to Landlord shall constitute Additional Rent and shall be subject to the imposition of late charges as provided in this Lease.
(b) Apart from extensions of time for delays and extensions of the date for the payment of rent, no payment or allowance of any kind shall be claimed by Tenant, or made to the Landlord as compensation for damages on account of any delay from any cause in the completion of the Tenant Improvements, whether such delay be avoidable or unavoidable, anything in this Agreement inconsistent herewith or to the contrary notwithstanding.
3.5 Tenant shall be responsible for the design and installation of its own phone, data and communication systems which systems shall be installed in a manner not to interfere with Landlord’s construction efforts. During construction of Tenant Improvements, a representative of Tenant shall inspect the site no less frequently than once a week and verify and agree that the work in progress has been completed in a manner acceptable to Tenant.
3.6 The Tenant Improvements shall be commenced upon issuance of the building permit by governmental entities having jurisdiction therefor and, subject to authorized adjustments, Substantial Completion is estimated to be achieved on or about January 15, 2004. As used herein the term “Substantial Completion” shall mean that the Leased Premises have been built and completed in substantial conformity with the Plans, and a temporary or permanent certificate of occupancy or a temporary or permanent certificate of acceptance (“CO/CA”) has been issued permitting Tenant to use and occupy the Leased Premises, even though minor details, adjustments or punch list items which shall not materially impair Tenant’s use and enjoyment of the Leased Premises may not have been finally completed, but which work Landlord agrees shall be diligently pursued to final completion. Tenant shall allow Landlord and its contractors to enter the Leased Premises during normal working hours after issuance of the CO/CA to complete remaining minor work or punch list items, provided Landlord gives advance notice and makes reasonable efforts not to interfere with Tenant’s operations. It is agreed that for the purpose of this Lease, wherever and whenever the term Substantial Completion is used, it shall not include items of maintenance, service, punch list, or guarantee. If the date of Substantial Completion occurs on a day other than the first day of a month, rent from such day until the first day of the following month shall be prorated (at a rate of 1/30th of the monthly rent per day). During said period of partial monthly occupancy, all other terms and conditions of this Lease shall apply.
Insurance; Damage to or Destruction of Collateral (a) The Credit Parties shall, at their sole cost and expense, maintain the policies of insurance described on Disclosure Schedule 3.18 as in effect on the date hereof or otherwise in form and amounts and with deductibles as is customary for similarly situated businesses and with insurers reasonably acceptable to Agent. Agent and the Lenders confirm that the form, amounts and insurers described on Disclosure Schedule 3.18 are acceptable as of the Closing Date, and shall continue to be acceptable to Agent until not less than 30 days' prior written notice by Agent to Borrower to the contrary. Such policies of insurance (or the loss payable and additional insured endorsements delivered to Agent) shall contain provisions pursuant to which the insurer agrees to provide 30 days prior written notice to Agent in the event of any non-renewal, cancellation or amendment of any such insurance policy. If any Credit Party at any time or times hereafter shall fail to obtain or maintain any of the policies of insurance required above, or to pay all premiums relating thereto, Agent may at any time or times thereafter obtain and maintain such policies of insurance and pay such premiums and take any other action with respect thereto that Agent deems advisable. Agent shall have no obligation to obtain insurance for any Credit Party or pay any premiums therefor. By doing so, Agent shall not be deemed to have waived any Default or Event of Default arising from any Credit Party's failure to maintain such insurance or pay any premiums therefor. All sums so disbursed, including reasonable attorneys' fees, court costs and other charges related thereto, shall be payable on demand by Borrower to Agent and shall be additional Obligations hereunder secured by the Collateral.
(b) Agent reserves the right at any time (but not to be exercised more than once per Fiscal Year) upon (i) any material change in any Credit Party's risk profile (including any change in the product mix maintained by any Credit Party or any laws affecting the potential liability of such Credit Party), as determined by Agent in its commercially reasonable judgment, and (ii) not less than 30 days' prior written notice to Borrower, to require additional forms and limits of insurance to, in Agent's commercially reasonable judgment, adequately protect both Agent's and Lender's interests in all or any portion of the Collateral and to ensure that each Credit Party is protected by insurance in amounts and with coverage customary for its industry. If reasonably requested by Agent, each Credit Party shall deliver to Agent from time to time a report of a reputable insurance broker, reasonably satisfactory to Agent, with respect to its insurance policies.
(c) Each Credit Party shall deliver to Agent, in form and substance reasonably satisfactory to Agent, endorsements to (i) all "All Risk" and business interruption insurance naming Agent, on behalf of itself and Lenders, as lender loss payee or mortgagee (as the case may be), and (ii) all general liability and other liability policies naming Agent, on behalf of itself and Lenders, as additional insured. Each Credit Party irrevocably makes, constitutes and appoints Agent (and all officers, employees or agents designated by Agent), so long as any Event of Default has occurred and is continuing or the anticipated insurance proceeds exceed $1,000,000, as such Credit Party's true and lawful agent and attorney-in-fact for the purpose of making, settling and adjusting claims under such "All Risk" policies of insurance, endorsing the name of such Credit Party on any check or other item of payment for the proceeds of such "All Risk" policies of insurance and for making all determinations and decisions with respect to such "All Risk" policies of insurance. Agent shall have no duty to exercise any rights or powers granted to it pursuant to the foregoing power-of-attorney. Borrower shall promptly notify Agent of any loss, damage, or destruction to the Collateral in
(i) Borrower shall request a Revolving Credit Advance be made to Borrower in the amount requested to be released; (ii) so long as the conditions set forth in Section 2.2 have been met, Lenders shall make such Revolving Credit Advance; and (iii) in the case of insurance proceeds applied against the Revolving Loan, the Reserve established with respect to such insurance proceeds shall be reduced by the amount of such Revolving Credit Advance. To the extent not used to replace, repair, restore or rebuild the Collateral, such insurance proceeds shall be applied in accordance with Section 1.3(c).
