Recovery of Overpayments On occasion a payment will be made to You when You are not covered, for a service that is not Covered, or which is more than is proper. When this happens We will explain the problem to You and You must return the amount of the overpayment to Us within 60 days after receiving notification from Us. However, We shall not initiate overpayment recovery efforts more than 24 months after the original payment was made unless We have a reasonable belief of fraud or other intentional misconduct.
Recovery of Sums Due Wherever any sum of money is recoverable from or payable by the Contractor, the Authority may deduct that sum from any sum due, or which at any later time may become due to the Contractor under the Contract or under any other agreement with the Authority.
Recovery of Funds The right of the RECIPIENT to retain monies received as reimbursement payments is contingent upon satisfactory performance of this Agreement and completion of the work described in the Scope of Work. All payments to the RECIPIENT are subject to approval and audit by ECOLOGY, and any unauthorized expenditure(s) or unallowable cost charged to this Agreement shall be refunded to ECOLOGY by the RECIPIENT. RECIPIENT shall refund to ECOLOGY the full amount of any erroneous payment or overpayment under this Agreement. RECIPIENT shall refund by check payable to ECOLOGY the amount of any such reduction of payments or repayments within thirty (30) days of a written notice. Interest will accrue at the rate of twelve percent (12%) per year from the time ECOLOGY demands repayment of funds. Any property acquired under this Agreement, at the option of ECOLOGY, may become ECOLOGY's property and the RECIPIENT's liability to repay monies will be reduced by an amount reflecting the fair value of such property.
Recovery of Costs If any legal action or other proceeding is brought for the enforcement of this Agreement, or because of an alleged dispute, breach, default or misrepresentation in connection with any of the provisions of this Agreement, the successful or prevailing party shall be entitled to recover reasonable attorneys’ fees and other costs incurred in that action or proceeding (and any additional proceeding for the enforcement of a judgment) in addition to any other relief to which it or they may be entitled.
Recovery of Schedule Delays If the Design Professional determines that the Project is one week or more behind schedule, per the approved Overall Project Schedule, the Design Professional shall so notify the Contractor in writing. Within seven days of the date of the Design Professional's notice, the Contractor shall deliver to the Design Professional and Owner a written plan explaining how the Contractor intends to bring the Project back on schedule. The Contractor's plan must provide sufficient detail to allow the Design Professional and Owner to determine the proposal's feasibility.
C3 Recovery of Sums Due C3.1 Wherever under the Contract any sum of money is recoverable from or payable by the Contractor to the Authority (including any sum which the Contractor is liable to pay to the Authority in respect of any breach of the Contract), the Authority may unilaterally deduct that sum from any sum then due, or which at any later time may become due to the Contractor from the Authority under the Contract or under any other agreement or contract with the Authority or the Crown.
Settlements The indemnifying party under this Section 9 shall not be liable for any settlement of any proceeding effected without its written consent, but if settled with such consent or if there be a final judgment for the plaintiff, the indemnifying party agrees to indemnify the indemnified party against any loss, claim, damage, liability or expense by reason of such settlement or judgment. Notwithstanding the foregoing sentence, if at any time an indemnified party shall have requested an indemnifying party to reimburse the indemnified party for fees and expenses of counsel as contemplated by Section 9(c) hereof, the indemnifying party shall be liable for any settlement of any proceeding effected without its written consent if (i) such settlement is entered into more than 30 days after receipt by such indemnifying party of the aforesaid request and (ii) such indemnifying party shall not have reimbursed the indemnified party in accordance with such request prior to the date of such settlement. No indemnifying party shall, without the prior written consent of the indemnified party, effect any settlement, compromise or consent to the entry of judgment in any pending or threatened action, suit or proceeding in respect of which any indemnified party is or could have been a party and indemnity was or could have been sought hereunder by such indemnified party, unless such settlement, compromise or consent includes an unconditional release of such indemnified party from all liability on claims that are the subject matter of such action, suit or proceeding and does not include an admission of fault or culpability or a failure to act by or on behalf of such indemnified party.
Recovery Each Protected Person shall use its reasonable efforts to pursue other third-party sources of indemnification in respect of any Liabilities for which it or any Protected Person may require indemnification in accordance with this Section 4. If any Protected Person recovers any amounts in respect of any Liabilities from insurance coverage or any third-party source, then such Protected Person shall, to the extent that such recovery is duplicative, reimburse the Issuer for any amounts previously paid to it by the Issuer in respect of such Liabilities.
Arbitration Fees and Costs If your claim seeks more than $75,000 in the aggregate, the payment of the AAA’s fees and costs will be governed by the AAA rules. If your claims seek less than $75,000 in the aggregate, the payment of the AAA’s fees and costs will be our responsibility. However, if the arbitrator finds that your Dispute was frivolous or brought for an improper purpose (as measured by the standards set forth in Federal Rule of Civil Procedure 11(b)), the payment of the AAA’s fees and costs shall be governed by the AAA Rules and you shall reimburse us for all fees and costs that were your obligation to pay under the AAA Rules. You may hire an attorney to represent you in arbitration. You are responsible for your attorneys’ fees and additional costs and may only recover your attorneys’ fees and costs in the arbitration to the extent that you could in court if the arbitration is decided in your favor. Notwithstanding anything in this Arbitration Provision to the contrary, we will pay all fees and costs that it is required by law to pay.
Settlement and Recovery of Funding for Prior Years (a) The HSP acknowledges that settlement and recovery of Funding can occur up to 7 years after the provision of Funding.
