Performance Security 47.1 Within twenty-one (21) days of the receipt of Letter of Acceptance from the Procuring Entity, the successful Tenderer, if required, shall furnish the Performance Security in accordance with the GCC 18, using for that purpose the Performance Security Form included in Section X, Contract Forms. If the Performance Security furnished by the successful Tenderer is in the form of a bond, it shall be issued by a bonding or insurance company that has been determined by the successful Tenderer to be acceptable to the Procuring Entity. A foreign institution providing a bond shall have a correspondent financial institution located in Kenya, unless the Procuring Entity has agreed in writing that a correspondent financial institution is not required. 47.2 Failure of the successful Tenderer to submit the above-mentioned Performance Security or sign the Contract shall constitute sufficient grounds for the annulment of the award and forfeiture of the Tender Security. In that event the Procuring Entity may award the Contract to the Tenderer offering the next lowest Evaluated Tender. 47.3 Performance security shall not be required for a contract, if so specified in the TDS.
Appropriation of Performance Security (i) Upon occurrence of a Contractor’s Default, the Authority shall, without prejudice to its other rights and remedies hereunder or in law, be entitled to encash and appropriate the relevant amounts from the Performance Security as Damages for such Contractor’s Default. (ii) Upon such encashment and appropriation from the Performance Security, the Contractor shall, within 30 (thirty) days thereof, replenish, in case of partial appropriation, to its original level the Performance Security, and in case of appropriation of the entire Performance Security provide a fresh Performance Security, as the case may be, and the Contractor shall, within the time so granted, replenish or furnish fresh Performance Security as aforesaid failing which the Authority shall be entitled to terminate the Agreement in accordance with Article 23. Upon replenishment or furnishing of a fresh Performance Security, as the case may be, as aforesaid, the Contractor shall be entitled to an additional Cure Period of 30 (thirty) days for remedying the Contractor’s Default, and in the event of the Contractor not curing its default within such Cure Period, the Authority shall be entitled to encash and appropriate such Performance Security as Damages, and to terminate this Agreement in accordance with Article 23.
The Performance Improvement Process (a) The Performance Improvement Process will focus on the risks of non- performance and problem-solving. It may include one or more of the following actions: (1) a requirement that the HSP develop and implement an improvement plan that is acceptable to the LHIN; (2) the conduct of a Review; (3) a revision and amendment of the HSP’s obligations; and (4) an in-year, or year end, adjustment to the Funding, among other possible means of responding to the Performance Factor or improving performance. (b) Any performance improvement process begun under a prior service accountability agreement that was not completed under the prior agreement will continue under this Agreement. Any performance improvement required by a LHIN under a prior service accountability agreement will be deemed to be a requirement of this Agreement until fulfilled or waived by the LHIN.
Release of Performance Security (i) The Authority shall return the Performance Security to the Contractor within 60 (sixty) days of the expiry of the Maintenance Period or the Defects Liability Period, whichever is later, under this Agreement. Notwithstanding the aforesaid, the Parties agree that the Authority shall not be obliged to release the Performance Security until all Defects identified during the Defects Liability Period have been rectified. (ii) The Authority shall return the Additional Performance Security to the Contractor within 28 (twenty eight) days from the date of issue of Completion Certificate under Article 12 of this Agreement. (iii) The Authority shall be liable to pay interest @ 9% (nine per cent) per annum for any delay in the return of Performance Security and Additional Performance Security, if any, beyond the period prescribed above for the period of delay.
Payment of Services For courses taught at a High School facility utilizing High School teachers who are qualified by the Dallas College using Southern Association of Colleges and Schools Commission on Colleges (SACSCOC) standards to teach college level courses, Dallas College shall pay as follows:
System for Award Management (XXX) Requirement Alongside a signed copy of this Agreement, Grantee will provide Florida Housing with a XXX.xxx proof of registration and Commercial and Government Entity (CAGE) number. Grantee will continue to maintain an active XXX registration with current information at all times during which it has an active award under this Agreement.
Excuse for Nonperformance or Delayed Performance Except with respect to defaults of subcontractors, Contractor/Vendor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by Contractor/Vendor to make progress in the prosecution of the work hereunder which endangers such performance) if Contractor/Vendor has notified the Commission or designee within 15 days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes or other labor disputes; freight embargoes; or unusually severe weather. If the failure to perform is caused by the failure of a subcontractor to perform or to make progress, and if such failure arises out of causes similar to those set forth above, Contractor/Vendor shall not be deemed to be in default, unless the services to be furnished by the subcontractor were reasonably obtainable from other sources in sufficient time to permit Contractor to meet the contract requirements. Upon request of Contractor, the Commission or designee shall ascertain the facts and extent of such failure, and, if such officer determines that any failure to perform was occasioned by any one or more of the excusable causes, and that, but for the excusable cause, Contractor’s progress and performance would have met the terms of the contract, the delivery schedule shall be revised accordingly, subject to the rights of the State under the clause entitled (in fixed-price contracts, “Termination for Convenience,” in cost-reimbursement contracts, “Termination”). (As used in this Paragraph of this clause, the term “subcontractor” means subcontractor at any tier).
Performance Bond Unless otherwise prohibited by law, the Department may require the Contractor to furnish, without additional cost to the Department, a performance bond or irrevocable letter of credit or other form of security for the satisfactory performance of work hereunder. The Department shall determine the type and amount of security.
Monitoring of Contract Performance The Contractor shall comply with the monitoring arrangements set out in the Monitoring Requirements Schedule including, but not limited to, providing such data and information as the Contractor may be required to produce under the Contract.
Performance of Services The Contractor is responsible for fully meeting all obligations set forth in the Contract and for providing Product in accordance with the Contract or any Authorized User Agreement.
