Obligations of the data exporter The data exporter agrees and warrants:
(a) that the processing, including the transfer itself, of the personal data has been and will continue to be carried out in accordance with the relevant provisions of the applicable data protection law (and, where applicable, has been notified to the relevant authorities of the Member State where the data exporter is established) and does not violate the relevant provisions of that State;
(b) that it has instructed and throughout the duration of the personal data processing services will instruct the data importer to process the personal data transferred only on the data exporter's behalf and in accordance with the applicable data protection law and the Clauses;
(c) that the data importer will provide sufficient guarantees in respect of the technical and organisational security measures specified in Appendix 2 to this contract;
(d) that after assessment of the requirements of the applicable data protection law, the security measures are appropriate to protect personal data against accidental or unlawful destruction or accidental loss, alteration, unauthorised disclosure or access, in particular where the processing involves the transmission of data over a network, and against all other unlawful forms of processing, and that these measures ensure a level of security appropriate to the risks presented by the processing and the nature of the data to be protected having regard to the state of the art and the cost of their implementation;
(e) that it will ensure compliance with the security measures;
(f) that, if the transfer involves special categories of data, the data subject has been informed or will be informed before, or as soon as possible after, the transfer that its data could be transmitted to a third country not providing adequate protection within the meaning of Directive 95/46/EC;
(g) to forward any notification received from the data importer or any subprocessor pursuant to Clause 5(b) and Clause 8(3) to the data protection supervisory authority if the data exporter decides to continue the transfer or to lift the suspension;
(h) to make available to the data subjects upon request a copy of the Clauses, with the exception of Appendix 2, and a summary description of the security measures, as well as a copy of any contract for subprocessing services which has to be made in accordance with the Clauses, unless the Clauses or the contract contain commercial information, in which case it may remove such commercial information;
(i) that, in the event of subprocessing, the processing activity is carried out in accordance with Clause 11 by a subprocessor providing at least the same level of protection for the personal data and the rights of data subject as the data importer under the Clauses; and
(j) that it will ensure compliance with Clause 4(a) to (i). The data importer agrees and warrants:
(a) to process the personal data only on behalf of the data exporter and in compliance with its instructions and the Clauses; if it cannot provide such compliance for whatever reasons, it agrees to inform promptly the data exporter of its inability to comply, in which case the data exporter is entitled to suspend the transfer of data and/or terminate the contract;
(b) that it has no reason to believe that the legislation applicable to it prevents it from fulfilling the instructions received from the data exporter and its obligations under the contract and that in the event of a change in this legislation which is likely to have a substantial adverse effect on the warranties and obligations provided by the Clauses, it will promptly notify the change to the data exporter as soon as it is aware, in which case the data exporter is entitled to suspend the transfer of data and/or terminate the contract;
(c) that it has implemented the technical and organisational security measures specified in Appendix 2 before processing the personal data transferred;
(d) that it will promptly notify the data exporter about:
(i) any legally binding request for disclosure of the personal data by a law enforcement authority unless otherwise prohibited, such as a prohibition under criminal law to preserve the confidentiality of a law enforcement investigation,
(ii) any accidental or unauthorised access, and
(iii) any request received directly from the data subjects without responding to that request, unless it has been otherwise authorised to do so;
(e) to deal promptly and properly with all inquiries from the data exporter relating to its processing of the personal data subject to the transfer and to abide by the advice of the supervisory authority with regard to the processing of the data transferred;
(f) at the request of the data exporter to submit its data processing facilities for audit of the processing activities covered by the Clauses which shall be carried out by the data exporter or an inspection body composed of independent members and in possession of the required professional qualifications bound by a duty of confidentiality, selected by the data exporter, where applicable, in agreement with the supervisory authority;
(g) to make available to the data subject upon request a copy of the Clauses, or any existing contract for subprocessing, unless the Clauses or contract contain commercial information, in which case it may remove such commercial information, with the exception of Appendix 2 which shall be replaced by a summary description of the security measures in those cases where the data subject is unable to obtain a copy from the data exporter;
(h) that, in the event of subprocessing, it has previously informed the data exporter and obtained its prior written consent;
(i) that the processing services by the subprocessor will be carried out in accordance with Clause 11;
(j) to send promptly a copy of any subprocessor agreement it concludes under the Clauses to the data exporter.
Obligations of the Licensee 5.1.1. The Licensee’s Responsibilities and Duties shall include the following, in addition to and without prejudice to other obligations under this Agreement:
a. to obtain due permits, necessary approvals, clearances and sanctions from Maha-Metro and all other competent authorities for all activities or infrastructure facilities including interior decoration, power, water supply, drainage & sewerage, telecommunication, etc.;
b. to comply and observe at all times with all Applicable Permits, approvals and Applicable Laws in the performance of its obligations under this Agreement including those being performed by any of its contractors;
c. to develop, operate and maintain the Licensed Area at all times in conformity with this Agreement;
d. to furnish Maha-Metro with the “As built” Drawings of the Licensed Space(s) within the Moratorium Period;
e. to ensure that no structural damage is caused to the existing buildings and other permanent structures at the station as a result of his activities or any of its agents, contractors etc.;
f. to take all reasonable steps to protect the environment (both on and off the property business space) and to limit damage and nuisance to people and property resulting from construction and operations, within guidelines specified as per Applicable Laws and Applicable Permits;
g. to duly supervise, monitor and control the activities of contractors, agents, etc., if any, under their respective License Agreements as may be necessary;
h. to take all responsible precautions for the prevention of accidents on or about the property business space and provide all reasonable assistance and emergency medical aid to accident victims;
i. not to permit any person, claiming through or under the Licensee, to create or place any encumbrance or security interest over whole or any part of the Licensed premises and/or other installed assets, or on any rights of the Licensee therein or under this Agreement, save and except as expressly permitted in this Agreement;
j. to keep the Licensed Space free from all unnecessary obstruction during execution of works and store the equipment or surplus materials, dispose of such equipment or surplus materials in a manner that causes least inconvenience to the Xxxxx Xxxxxxx, metro commuters or Maha-Metro’s activities.
k. at all times, to afford access to the Licensed Property Business Space to the authorised representatives of Maha-Metro, other persons duly authorised by any Governmental Agency having jurisdiction over the business of Licensed Property Business Space, to inspect the Licensed Property Business Space and to investigate any matter within their authority and upon reasonable notice; and
l. use non-combustable material in the allotted space for creation/erection/installation of any kind of furniture, fixtures and or partitions within the space. Use of combustable material within the property business space shall not be permitted under any circumstances.
m. to comply with the divestment requirements and hand over the Licensed Property Business Space to Maha-Metro upon Termination of the Agreement;
5.1.2. The Licensee shall be solely and primarily responsible to Maha-Metro for observance of all the provisions of this License Agreement on behalf of its employees and representatives and agents and any person acting under or for and on behalf of the Licensee, contractor (s) appointed for the Licensed Space as fully as if they were the acts or defaults of the Licensee, its agents or employees.
Obligations of the Concessionaire 5.1.1 Subject to and on the terms and conditions of this Agreement, the Concessionaire shall, at its own cost and expense, procure finance for and undertake the design, engineering, procurement, construction, operation and maintenance of the Project and observe, fulfil, comply with and perform all its obligations set out in this Agreement or arising hereunder.
5.1.2 The Concessionaire shall comply with all Applicable Laws and Applicable Permits (including renewals as required) in the performance of its obligations under this Agreement.
5.1.3 Subject to the provisions of Clauses 5.1.1 and 5.1.2, the Concessionaire shall discharge its obligations in accordance with Good Industry Practice and as a reasonable and prudent person.
5.1.4 The Concessionaire shall, at its own cost and expense, in addition to and not in derogation of its obligations elsewhere set out in this Agreement carry out the following but not be limited to:
(a) make, or cause to be made, necessary applications to the relevant Government Instrumentalities with such particulars and details as may be required for obtaining Applicable Permits (other than those set forth in Clause 4.1.3), and obtain and keep in force and effect such Applicable Permits in conformity with the Applicable Laws;
(b) procure, as required, the appropriate proprietary rights, licences, agreements and permissions for materials, methods, processes and systems used or incorporated into the Project;
(c) perform and fulfil its obligations under the Financing Agreements;
(d) make reasonable efforts to maintain harmony and good industrial relations among the personnel employed by it or its Contractors in connection with the performance of its obligations under this Agreement;
(e) make reasonable efforts to facilitate the acquisition of land required for the purposes of the Agreement;
(f) ensure and procure that its Contractors comply with all Applicable Permits and Applicable Laws in the performance by them of any of the Concessionaire's obligations under this Agreement;
(g) not do or omit to do any act, deed or thing which may in any manner be violative of any of the provisions of this Agreement;
(h) support, cooperate with and facilitate the Authority in the implementation and operation of the Project in accordance with the provisions of this Agreement;
(i) modify/demolish the existing structures on the Site at its own cost and consequences. The Concessionaire shall ensure that the demolition and construction of the existing structures is also in compliance with the prevailing building bye laws, zoning regulations as prescribed by H&UPD, GoUP, other appropriate authority or any regulatory authority (ASI, TTZ, NGT etc.). XXX policy of GoI and GoUP shall be admissible as and where applicable. The Concessionaire shall be responsible for safe and hassle-free disposal of the scrap from the Site;
(j) (deleted)
(k) transfer the Bus Terminal and the Commercial Complex to the Authority upon Termination of this Agreement, in accordance with the provisions thereof.
(l) develop a centralized covered Bus Terminal with adequate number of bus bays along with RCC yard area, passenger movement spaces, furniture fixtures, electrical fittings, utilities and other related requirements;
(m) {where Bus Terminal and workshops/ depots are adjoining, the development of workshops unit with necessary structural provisions and RCC yard, furniture fixtures, electrical fittings with minimum 6 meters of working/ maintenance shed height with no access from and/ to commercial areas as a mandatory requirement. However, Authority shall take separate electricity connection for the workshop area and shall pay for the electricity usage in it}1;
(n) construct and maintain public amenities like ablution units etc.;
(o) all the passenger amenities, Workshop facilities as well as UPSRTC staff facilities shall be maintained hygienic, neat and clean during the concession period;
(p) accesses either through staircases, overbridges or underpasses for movement of pedestrians from one platform to the other in a safe and fully secured manner;
(q) a dedicated office for UPSRTC staff with a sufficient usable area along with change rooms and toilets as per the specifications of UPSRTC shall be made available unconditionally and free of cost for the entire concession period on ground and first floors only of the Bus Terminal;
(r) all the facilities for plumbing, internal electrification and all the other allied works to render the office functional (partitions excluded);
(s) facility for parking adequate number of 4 wheelers, 3 Wheelers and 2 wheelers of passengers and commercial area users. The parking facility for Bus Terminal and for the Commercial Complex shall be segregated. (Refer prevailing Government of Housing and Urban Planning department circulars/ G.O’s); 1 This provision to be used only for Sites where workshops are adjoining the Bus Terminal
(t) all the other allied facilities for fire protection, accesses in the form of ramps, protective railings, ventilation system etc.;
(u) day to day operation and management of the Project as per this Agreement; and
(v) bear the expenses of electricity and water in the Bus Terminal during the Concession Period of Bus Terminal, except electricity and water charges for Authority’s office, workshop, drivers or staff dormitory and electric bus charging which shall be borne by the Authority.
Obligations of Licensee 2.1 Licensee is responsible for the quality and safety of its products.
2.2 Licensee shall use all reasonable efforts and diligence to exploit the Invention and to proceed with the development, manufacture and sale of Licensed Product and to use commercially reasonable efforts to develop markets for the Licensed Product.
2.3 Licensee will represent the Licensed Product fairly in comparison with competitive products from other suppliers.
2.4 Licensee shall not, on behalf of University, make any representations or give any warranties or guarantees in respect of the Proprietary IPR not expressly authorised in writing by University, provided that such authorization shall not be unreasonably delayed or withheld by University.
2.5 Licensee shall not market the Licensed Product under the name of University, and not in any way create any impression that University is the seller of the Licensed Product.
2.6 Licensee shall take all such steps as are reasonably necessary to protect Intellectual Property Rights in the Invention.
2.7 Licensee shall promptly inform University upon becoming aware of any illegal or unauthorised use of the Invention or any infringement of the Prospective Patent or Proprietary IPR and Intellectual Property Rights therein.
2.8 Licensee shall comply with all laws, regulations and governmental obligations that may from time to time be applicable to the making, use or sale of the Licensed Product in each part of the Territory.
2.9 As between Licensee and University and without limiting any responsibility of an Affiliate or Sub-Licensee, Licensee shall be solely responsible for any claims arising or alleged to arise from loss or injury to persons or property caused or suffered in the course of or as a consequence of the use of the Invention by Licensee, Affiliates and Sub-Licensees or the supply and sale of the Licensed Product by Licensee, Affiliates and Sub-Licensees except where such loss or injury are caused by the gross negligence or wilful misconduct of University.
2.10 Except as expressly set forth under this Agreement, Licensee shall use its best endeavours to keep the Invention confidential and not to reveal to any third party any confidential information of University regarding the Invention until after a non-disclosure agreement has been signed, provided that no such obligation shall apply to any information that has been publicly disclosed through no breach of this Agreement by Licensee, including by publication of the Inventions by the applicable governmental agency, was in the possession of Licensee prior to disclosure by University, is obtained by Licensee from a third party, or is independently developed by Licensee.
2.11 To the extent prohibited by applicable law, Licensee shall not carry out any illegal, deceptive, or unethical practices, whether or not they are to the disparagement of the Invention, Licensed Product or University, or, subject to the foregoing in this Section 2.11, any other practices which may be detrimental to the Invention, Licensed Product, University or to the public interest.
Statutory Obligations Nothing in this Agreement shall be construed to modify, eliminate or detract from the statutory responsibilities and obligations of the Employer except that the exercise of its rights in the furtherance of such statutory obligations shall not be in conflict with the provisions of this Agreement.
Obligations of Management Each officer and key employee of the Company is currently devoting substantially all of his or her business time to the conduct of the business of the Company. The Company is not aware that any officer or key employee of the Company is planning to work less than full time at the Company in the future. No officer or key employee is currently working or, to the Company’s knowledge, plans to work for a competitive enterprise, whether or not such officer or key employee is or will be compensated by such enterprise.
Obligations of DOE a. In express reliance on the covenants and representations in this Compromise Agreement and to avoid further expenditure of public resources, XXX agrees to accept Respondent’s payment pursuant to section III.2.a in full satisfaction of the penalty authorized by the Act.
x. XXX agrees to issue promptly an Adopting Order adopting this Agreement.
x. XXX agrees to terminate this enforcement action with prejudice upon Respondent’s completion of its Obligations in accordance with section III.2, above. If Respondent fails to complete its Obligations in accordance with section III.2, above, DOE may notify Respondent that the Agreement is null and void and may seek the maximum penalty in accordance with 10 C.F.R. § 429.120.
Statutory Obligations and Regulations D1 Prevention of Corruption 19 D2 Prevention of Fraud 20 D3 Discrimination 21 D4 The Contracts (Rights of Third Parties) Act 1999 21 D5 Environmental Requirements 21 D6 Health and Safety 21
Obligations of the Contractor (i) Subject to and on the terms and conditions of this Agreement, the Contractor shall undertake the survey, investigation, design, engineering, procurement, construction, and maintenance of the Project Highway and observe, fulfil, comply with and perform all its obligations set out in this Agreement or arising hereunder.
(ii) The Contractor shall comply with all Applicable Laws and Applicable Permits (including renewals as required) in the performance of its obligations under this Agreement.
(iii) Subject to the provisions of Clauses 4.1 (i) and 4.1 (ii), the Contractor shall discharge its obligations in accordance with Good Industry Practice and as a reasonable and prudent person.
(iv) The Contractor shall remedy any and all loss, defects, or damage to the Project Highway from the Appointed Date until the end of the Construction Period at the Contractor’s cost, save and except to the extent that any such loss, defect, or damage shall have arisen from any wilful default or neglect of the Authority.
(v) The Contractor shall remedy any and all loss, defect or damage to the Project Highway during the Defects Liability Period at the Contractor’s cost to the extent that such loss, defect or damage shall have arisen out of the reasons specified in Clause 17.3.
(vi) The Contractor shall remedy any and all loss or damage to the Project Highway during the Maintenance Period at the Contractor’s cost, including those stated in Clause 14.1 (ii), save and except to the extent that any such loss or damage shall have arisen on account of any wilful default or neglect of the Authority or on account of a Force Majeure Event.
(vii) The Contractor shall, at its own cost and expense, in addition to and not in derogation of its obligations elsewhere set out in this Agreement:
(a) make, or cause to be made, necessary applications to the relevant Government Instrumentalities with such particulars and details as may be required for obtaining Applicable Permits set forth in Schedule-F and obtain and keep in force and effect such Applicable Permits in conformity with the Applicable Laws;
(b) procure, as required, the appropriate proprietary rights, licences, agreements and permissions for Materials, methods, processes and systems used or incorporated into the Project Highway;
(c) make reasonable efforts to maintain harmony and good industrial relations among the personnel employed byit or its Sub-contractors in connection with the performance of its obligations under this Agreement;
(d) ensure and procure that its Sub-contractors comply with all Applicable Permits and Applicable Laws in the performance by them of any of the Contractor’s obligations under this Agreement;
(e) not do or omit to do any act, deed or thing which may in any manner violate any provisions of this Agreement;
(f) support, cooperate with and facilitate the Authority in the implementation and operation of the Project in accordance with the provisions of this Agreement;
(g) ensure that the Contractor and its Sub-contractors comply with the safety and welfare measures for labour in accordance with the Applicable Laws and Good Industry Practice;
(h) keep, on Site, a copy of this Agreement, publications named in this Agreement, the Drawings, Documents relating to the Project, and Change of Scope orders and other communications given under this Agreement. The Authority’s Engineer and its authorised personnel shall have the right of access to all these documents at all reasonable times;
(i) cooperate with other contractors employed by the Authority and personnel of any public authority; and
(j) not interfere unnecessarily or improperly with the convenience of the public, or the access to and use and occupation of all roads and footpaths, irrespective of whether they are public or in the possession of the Authority or of others.
(viii) The Contractor shall undertake all necessary superintendence to plan, arrange, direct, manage, inspect and test the Works. The Contractor shall provide all necessary superintendence of the Works for the proper fulfilling of the Contractor's obligations under the Agreement. Such superintendence shall be given by competent person having adequate knowledge of the operations to be carried out (including the methods and techniques required, the hazards likely to be encountered and methods of preventing accidents) for the satisfactory and safe execution of the Works.
(ix) The Contractor shall obtain and maintain a project related bank account operational at site where all transactions related to the payment of work will be done. The Contractor shall submit a monthly account statement and a detailed report on utilization of funds transferred to this project related bank account to Authority’s Engineer. Notwithstanding anything contrary to this agreement, the authority, in the interest and to ensure timely completion of the work, reserves the right to audit such bank accounts to ensure that there is no diversion of funds from this project specific account to any other project being implemented by the Contractor.
(x) The Contractor shall provide the documents of the Contractor specified in the Agreement, and all Contractors' personnel; Goods, consumables and other things and services, whether of a temporary or permanent nature, required in and for the execution, completion of Works and remedying defects.
(xi) The Contractor shall perform the Works in conformity with the Project requirements and other requirements and standards prescribed under or pursuant to the Agreement.
(xii) The Contractor shall carry out such work incidental and contingent to the original Scope of the Project to comply with Good Industry Practices.
(xiii) The Contractor shall maintain required staff and necessary Contractor’s equipment and materials within the reach of the Site during the Defects Liability Period so that any defects arising are promptly attended.
Obligations of the Parties Clause 8
