Relocation or Removals of Power Modules Sample Clauses

Relocation or Removals of Power Modules. In the event that a Customer Agreement permits the applicable Customer to require the relocation or removal of power modules, Owner may, upon request made by such Customer pursuant to the provisions of the applicable Customer Agreement, require Provider to relocate or remove power modules pursuant to this Section 2.06. (a) In the event that one or more power modules are to be relocated pursuant to this Section 2.06, Provider shall promptly perform all actions necessary for the removal of such power modules from the original Site(s) and the transportation to, and reinstallation and resumption of operations of, such power modules at the relocation Site(s) determined in accordance with the applicable Customer Agreement. Provider shall bear all costs associated with such relocation unless the applicable Customer is required to bear such costs pursuant to the terms of the applicable Customer Agreement, in which case (i) Provider and Owner shall cooperate in good faith to prepare appropriate documentation of such costs, (ii) Owner shall cause the relevant Project Company to use all commercially reasonable efforts to obtain payment from the applicable Customer as permitted under the applicable Customer Agreement, and (iii) Owner will promptly remit to Provider all payments obtained from the applicable Customer in respect of such costs associated with the relocation of the applicable power modules; and (b) In the event that one or more power modules are to be removed pursuant to this Section 2.06, Provider will promptly remove such power modules from the applicable Facility(ies), and the Parties will cooperate in good faith to identify one or more Facilities in the Portfolio at which to redeploy such power modules, either as additional power modules installed in then-empty power module cabinets or to replace operating power modules nearing the end of their useful life. In identifying such Facilities, the Parties will consider (among other things) (i) the availability of empty power module cabinets, (ii) wiring or other equipment limitations, and (iii) any restrictions or limitations imposed by Legal Requirements, the Customer Agreements, and the applicable Interconnection Agreements. Until a power module is redeployed pursuant to the terms of this Section 2.06(b), Provider shall be responsible for the handling, shipping and storage of such power module, and shall bear all risk of loss with respect thereto during such period. Provider shall bear all costs associate...
Sample 1
AutoNDA by SimpleDocs

Related to Relocation or Removals of Power Modules

  • Provision and Removal of Equipment B2.1 The Contractor shall provide all the Equipment necessary for the supply of the Services.

  • Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract. a. The contractor shall notify all potential subcontractors and suppliers and lessors of their EEO obligations under this contract. b. The contractor will use good faith efforts to ensure subcontractor compliance with their EEO obligations.

  • Use of Interconnection Facilities by Third Parties 6551 Error! Hyperlink reference not valid.9.9.1 Purpose of Interconnection Facilities. 6551

  • Modification of the Small Generating Facility The Interconnection Customer must receive written authorization from the NYISO and Connecting Transmission Owner before making any change to the Small Generating Facility that may have a material impact on the safety or reliability of the New York State Transmission System or the Distribution System. Such authorization shall not be unreasonably withheld. Modifications shall be done in accordance with Good Utility Practice. If the Interconnection Customer makes such modification without the prior written authorization of the NYISO and Connecting Transmission Owner, the Connecting Transmission Owner shall have the right to temporarily disconnect the Small Generating Facility. If disconnected, the Small Generating Facility will not be reconnected until the unauthorized modifications are authorized or removed.

  • Resignation or Removal of the Owner Trustee The Owner Trustee may at any time resign and be discharged from the trusts hereby created by giving written notice thereof to the Seller, the Administrator, the Servicer, the Indenture Trustee and the Residual Interestholder. Upon receiving such notice of resignation, the Seller and the Administrator, acting jointly, shall promptly appoint a successor Owner Trustee which satisfies the eligibility requirements set forth in Section 10.1 by written instrument, in duplicate, one copy of which instrument shall be delivered to the resigning Owner Trustee and one copy to the successor Owner Trustee. If no successor Owner Trustee shall have been so appointed and have accepted appointment within 30 days after the giving of such notice of resignation, the resigning Owner Trustee may petition any court of competent jurisdiction for the appointment of a successor Owner Trustee; provided, however, that such right to appoint or to petition for the appointment of any such successor shall in no event relieve the resigning Owner Trustee from any obligations otherwise imposed on it under the Transaction Documents until such successor has in fact assumed such appointment. If at any time the Owner Trustee shall cease to be eligible in accordance with the provisions of Section 10.1 and shall fail to resign after written request therefor by the Seller or the Administrator, or if at any time the Owner Trustee shall be legally unable to act, or shall be adjudged bankrupt or insolvent, or a receiver of the Owner Trustee or of its property shall be appointed, or any public officer shall take charge or control of the Owner Trustee or of its property or affairs for the purpose of rehabilitation, conservation or liquidation, then the Seller or the Administrator may remove the Owner Trustee. If the Seller or the Administrator shall remove the Owner Trustee under the authority of the immediately preceding sentence, the Seller and the Administrator, acting jointly, shall promptly appoint a successor Owner Trustee by written instrument, in duplicate, one copy of which instrument shall be delivered to the outgoing Owner Trustee so removed and one copy to the successor Owner Trustee and shall pay all fees owed to the outgoing Owner Trustee. Any resignation or removal of the Owner Trustee and appointment of a successor Owner Trustee pursuant to any of the provisions of this Section shall not become effective until acceptance of appointment by the successor Owner Trustee pursuant to Section 10.3 and payment of all fees and expenses owed to the outgoing Owner Trustee. The Seller shall provide (or shall cause to be provided) notice of such resignation or removal of the Owner Trustee to each of the Rating Agencies.

  • Cost Responsibility for Interconnection Facilities and Distribution Upgrades 4.1 Interconnection Facilities 4.2 Distribution Upgrades

  • Testing of Metering Equipment Connecting Transmission Owner shall inspect and test all of its Metering Equipment upon installation and at least once every two (2) years thereafter. If requested to do so by NYISO or Developer, Connecting Transmission Owner shall, at Developer’s expense, inspect or test Metering Equipment more frequently than every two (2) years. Connecting Transmission Owner shall give reasonable notice of the time when any inspection or test shall take place, and Developer and NYISO may have representatives present at the test or inspection. If at any time Metering Equipment is found to be inaccurate or defective, it shall be adjusted, repaired or replaced at Developer’s expense, in order to provide accurate metering, unless the inaccuracy or defect is due to Connecting Transmission Owner’s failure to maintain, then Connecting Transmission Owner shall pay. If Metering Equipment fails to register, or if the measurement made by Metering Equipment during a test varies by more than two percent from the measurement made by the standard meter used in the test, Connecting Transmission Owner shall adjust the measurements by correcting all measurements for the period during which Metering Equipment was in error by using Developer’s check meters, if installed. If no such check meters are installed or if the period cannot be reasonably ascertained, the adjustment shall be for the period immediately preceding the test of the Metering Equipment equal to one-half the time from the date of the last previous test of the Metering Equipment. The NYISO shall reserve the right to review all associated metering equipment installation on the Developer’s or Connecting Transmission Owner’s property at any time.

  • Communications Equipment (a) Subject to the provisions of this Section 3.5, Tenant shall have the non-exclusive right, at its sole cost and expense and for Tenant’s use, to install, maintain and operate upon the roof of the Building one (1) or a reasonable and necessary additional number of transmitters and/or receiver antennas or dishes approved by Landlord, which approval shall not be unreasonably withheld or delayed (collectively, the “Communications Equipment”) for use by Tenant in the conduct of its business; provided that such Communications Equipment may not materially compromise the aesthetics or appearance of the Building nor shall Landlord be required to incur any expense in accommodating the Communications Equipment. The Communications Equipment must be (i) designed, installed and operated in compliance with all Legal Requirements, and (ii) installed and operated so as not to adversely affect or impact structural, mechanical, electrical, elevator, or other systems serving the Building or customary telephone service for the Building and so as not to cause injury to persons or property, and without limitation of the foregoing, so as not to void or impair any applicable roof warranty. Upon the expiration or termination of this Lease, Tenant shall remove the Communications Equipment and repair any damage to the Building caused by the installation, maintenance, use or removal of the Communications Equipment. (b) Landlord hereby grants to Tenant the right to install (at Tenant’s sole cost and expense) any additional equipment required to operate the Communications Equipment and to connect the Communications Equipment to Tenant’s other machinery and equipment located in the Leased Premises (e.g., conduits and cables) in the shafts, ducts, chases and utility closets located in the core of the building (“Additional Equipment”), which Additional Equipment shall be deemed a part of the Communications Equipment for all purposes of this Section 3.5; provided that (i) the use of such space in the Building core by Tenant (except customary chases for cabling) may not materially adversely affect the marketability of the remaining space on any floor of the Building, and (ii) to the extent any such Additional Equipment occupies space (other than space in customary chases for the Building) that would have otherwise been Net Rentable Area on a floor of the Building, such space shall be included within the Net Rentable Area of the Leased Premises and Tenant shall be obligated to pay Annual Basic Rent and Additional Rent with respect to such space as if such space was included in the Leased Premises. Tenant’s use of such space in the Building core shall be subject to the provisions of this Lease relating to Tenant’s use of Common Areas of the Building. (c) Subject to the Building Rules and other reasonable rules relating to Building security and safety that may be promulgated by Landlord pertaining to access by tenants to the roof of the Building and provided Tenant does not unreasonably disturb any other tenants of the Building, Tenant and Tenant’s contractors shall have reasonable access to the Communications Equipment and the Additional Equipment for purposes of operating, servicing, repairing or otherwise maintaining said equipment. (d) Nothing contained in this Section 3.5 shall be deemed to prohibit or restrict any other individual or entity, including Landlord or any other tenant of the Building, from installing communications equipment on the roof of the Building or to use the roof for any other purpose. (e) In connection with its installation, repair, maintenance and removal of any Communications Equipment and Additional Equipment, Tenant, at Tenant’s sole cost and expense, shall comply with all applicable Building Rules and Legal Requirements and repair any damage to the Building caused by such installation, repair, maintenance or removal. In the event that the placement of Tenant’s Communications Equipment or Additional Equipment interferes with Landlord’s performance of any repair or maintenance to the Common Areas, including the roofs of the Buildings, any costs incurred by Landlord to temporarily or permanently relocate and reinstall Tenant’s Communications Equipment or Additional Equipment shall be included in the cost of such repair or maintenance as a Operating Expense. (f) Tenant’s Communications Equipment and Additional Equipment existing as of the Commencement Date are hereby deemed to be approved by Landlord. Any changes to the existing Communications Equipment and/or Additional Equipment by Tenant shall first be approved by Landlord, which approval will not be unreasonably withheld or delayed. (g) If Landlord shall place on the roof of any Building communications equipment of its own, or shall grant to any third party the right to locate and maintain any such equipment, all such equipment shall be located, designed and operated so as not to interfere with signals to and from Tenant’s Communications Equipment and Additional Equipment, the installation of which, in accordance with this Section 3.5, predates the installation of such other equipment. Similarly, any Communications Equipment and Additional Equipment hereafter installed by Tenant shall be located and designed so as not to interfere with signals to and from such other equipment belonging to Landlord or to third parties, that may have previously been installed. The party responsible for the communications equipment which interferes with equipment previously installed by others shall be required, at its or their expense, to take all measures necessary to eliminate the source of interference caused by such party’s equipment.

  • Installation of Equipment You represent that there are no legal, contractual or similar restrictions on the installation of the Equipment in the location(s) you have authorized. It is your responsibility to ensure compliance with all applicable building codes, zoning ordinances, homeowners’ association rules, covenants, conditions, and restrictions related to the Service, to pay any fees or other charges, and to obtain any permits or authorizations necessary for the installation or use of the Service (collectively "Legal Requirements"). You are solely responsible for any fines or similar charges for violation of any applicable Legal Requirements. You acknowledge and agree that Viasat or its designated service provider will be required to access your premises and computer to install and maintain the Equipment, including, without limitation, the antenna and its components. Standard Equipment installations performed by Viasat-authorized installers include: (i) installation of the antenna to an outside wall or sloped roof; (ii) travel to and from your Service location within 50 miles of the installer’s office; (iii) cable routed through one exterior wall and one interior wall or floor; (iv) connection of the antenna to the modem using up to 150 feet of cable; (v) connection of the modem to one computer using up to 7 feet of cable; and (vi) required mounting and cabling hardware. Any different or additional installation services or hardware are non-standard and may result in additional charges to be agreed upon between you and the installer. All installations include attaching the Equipment to your computer, installing software on your computer and configuring your computer to optimize the performance of the Internet Service. You confirm that you have reviewed the installation plan and agreed to any associated charges. If you approved a roof mount, you acknowledge the potential risks associated with this type of installation (including, without limitation, with respect to any warranty that applies to your roof or roof membrane). By signing this Agreement, scheduling one or more service or installation visits, and permitting us or our service provider to enter your home, you are authorizing Viasat and its service provider to perform all of the above actions. You are responsible for backing up the data on your computer and we highly recommend that you do so prior to permitting access to us or one of our designated service providers. NEITHER VIASAT NOR ITS SERVICE PROVIDER SHALL HAVE ANY LIABILITY WHATSOEVER FOR ANY LOSSES RESULTING FROM THE EQUIPMENT OR ANY INSTALLATION, REPAIR OR OTHER SERVICES ASSOCIATED WITH THE EQUIPMENT, INCLUDING WITHOUT LIMITATION, DAMAGE TO YOUR PREMISES OR LOSS OF SOFTWARE, DATA OR OTHER INFORMATION FROM YOUR COMPUTER. This limitation does not apply to any damages arising from the gross negligence or willful misconduct of us or one of our designated service providers. Time frames for installation, if any, are not guaranteed and may vary depending on the types of services requested and other factors.

  • Removal of Equipment Subject, always, to the other terms and provisions of this Fee Agreement, the Company and any Sponsor Affiliates shall be entitled to remove and dispose of components of the Project from the Project in its sole discretion with the result that said components shall no longer be considered a part of the Project and, to the extent such constitute Economic Development Property, shall no longer be subject to the terms of this Fee Agreement. Economic Development Property is disposed of only when it is scrapped or sold or removed from the Project. If it is removed from the Project, it is subject to ad valorem property taxes to the extent the Property remains in the State and is otherwise subject to ad valorem property taxes.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!