Remediation of Pennsylvania Real Estate Sample Clauses

Remediation of Pennsylvania Real Estate. The Company and Subsidiaries shall remediate the Pennsylvania Real Estate in accordance with all applicable Pennsylvania requirements. The Company and Subsidiaries shall either (1) obtain closure from the Pennsylvania Department of Environmental Protection (“PADEP”) prior to Closing or (2) establish an escrow account to fund this remediation in an amount equal to $300,000, to be released upon closure approval from the PADEP. The remediation of the Pennsylvania Real Estate shall not rely upon any deed restrictions or other limitations on the property use, other than a restriction on excavation of soils underlying the building adjacent to the former tank location or immediately adjacent to the building only to the extent that excavation of such soil would undermine the structural stability of the building or the adjacent railroad siding owned and controlled by Sellers as shown on the map attached hereto as Exhibit G, and will not result in any ongoing obligation related to the property other than the maintenance of a slab or parking in these areas or other than a prohibition on excavation in the area of the railroad siding as provided in this section or in any expense for Purchaser other than the routine filing of documents regarding such maintenance. In all events, any such deed restriction on the excavation of soils shall be as narrowly tailored as practicable to those areas of contamination and with respect to the railroad siding, Purchaser shall have the option, in its sole and absolute discretion, of requiring Sellers to excavate the contaminated soil in lieu of accepting a deed restriction provided Purchaser is willing to accept the interference with its operations at the Pennsylvania Real Estate.
Sample 1
AutoNDA by SimpleDocs

Related to Remediation of Pennsylvania Real Estate

  • Construction Plans Tenant shall prepare final plans and specifications for the Tenant Improvements that (a) are consistent with and are logical evolutions of the Approved Schematic Plans and (b) incorporate any other Tenant-requested (and Landlord-approved) Changes (as defined below). As soon as such final plans and specifications ("Construction Plans") are completed, Tenant shall deliver the same to Landlord for Landlord's approval, which approval shall not be unreasonably withheld, conditioned or delayed. All such Construction Plans shall be submitted by Tenant to Landlord in electronic .pdf, CADD and full-size hard copy formats, and shall be approved or disapproved by Landlord within ten (10) business days after delivery to Landlord. Landlord's failure to respond within such ten (10) business day period shall be deemed approval by Landlord. If the Construction Plans are disapproved by Landlord, then Landlord shall notify Tenant in writing of its objections to such Construction Plans, and the parties shall confer and negotiate in good faith to reach agreement on the Construction Plans. Promptly after the Construction Plans are approved by Landlord and Tenant, two (2) copies of such Construction Plans shall be initialed and dated by Landlord and Tenant, and Tenant shall promptly submit such Construction Plans to all appropriate Governmental Authorities for approval. The Construction Plans so approved, and all change orders approved (to the extent required) by Landlord, are referred to herein as the "Approved Plans."

  • Personnel, Office Space, and Facilities of Manager The Manager at its own expense shall furnish or provide and pay the cost of such office space, office equipment, office personnel, and office services as the Manager requires in the performance of its investment advisory and other obligations under this Agreement.

  • Environmental, Health and Safety Matters (a) Comply in all material respects with all applicable Environmental Laws, including, without limitation, obtaining and complying with and maintaining any and all licenses, approvals, notifications, registrations or permits required by applicable Environmental Laws. For purposes of this Section 5.12(a), material noncompliance by the Company, any of its Subsidiaries or any tenant or subtenant, with any applicable Environmental Law shall be deemed not to constitute a breach of this covenant provided that, upon learning of any actual or suspected material noncompliance, the Company and the relevant Subsidiaries shall promptly undertake all reasonable efforts to achieve material compliance (or contest in good faith by appropriate proceedings the alleged violation or applicable Environmental Law at issue and (to the extent required by GAAP) provide on the books of the Company or any of its Subsidiaries, as the case may be, reserves in accordance with GAAP with respect thereto), and provided further that, in any case, such noncompliance, and any other noncompliance with applicable Environmental Law, individually or in the aggregate, could not reasonably be expected to have a Material Adverse Effect. (b) Promptly comply in all material respects with all lawful orders and directives of all Governmental Authorities regarding applicable Environmental Laws, except to the extent that the validity thereof is currently being contested in good faith by appropriate proceedings and (to the extent required by GAAP) reserves in accordance with GAAP with respect thereto have been provided on the books of the Company or any of its Subsidiaries, as the case may be. (c) Defend, indemnify and hold harmless the Administrative Agent and the Lenders, and their respective parents, subsidiaries, affiliates, employees, agents, officers and directors, from and against any claims, demands, penalties, fines, liabilities, settlements, damages, costs and expenses of whatever kind or nature, known or unknown, contingent or otherwise, arising out of, or in any way relating to the violation of, noncompliance with or liability under any Environmental Laws applicable to the Company or any of its Subsidiaries or any of their respective operations or properties, or any orders, requirements or demands of Governmental Authorities related thereto, including, without limitation, attorney’s and consultant’s fees, investigation and laboratory fees, response costs, court costs and litigation expenses, except to the extent that any of the foregoing arise out of the gross negligence or willful misconduct of (or, as determined pursuant to a claim initiated by the Company, breach in bad faith of its express obligations under the applicable Loan Documents by) the party seeking indemnification therefor, in each case, as determined by a final non-appealable judgment by a court of competent jurisdiction. This indemnity shall continue in full force and effect regardless of the termination of this Agreement.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • OFFICE OF MANAGEMENT AND BUDGET (OMB) AUDIT REQUIREMENTS The parties shall comply with the requirements of the Single Audit Act of 1984, P.L. 98-502, ensuring that the single audit report includes the coverage stipulated in 2 CFR 200.

  • Environmental and Safety Matters (a) The Company and its Subsidiaries have at all times complied in all material respects with all applicable Environmental and Safety Requirements, which compliance has included obtaining and complying in all material respects at all times with all material permits, licenses and other authorizations required pursuant to Environmental and Safety Requirements for the occupation of their facilities and the operation of their respective businesses. (b) Except as set forth in Section 4.27(b) of the Disclosure Schedule, since February 19, 2008, neither the Company nor any of its Subsidiaries has received any notice, report, order, or directive regarding any, and is not subject to any litigation, proceedings or order regarding any, actual or alleged violation of Environmental and Safety Requirements, or any liability or potential liability arising under Environmental and Safety Requirements, in effect prior to and as of the date of the applicable Closing, relating to the business, the Owned Real Property or Leased Real Property. (c) Except as set forth in Section 4.27(c) of the Disclosure Schedule, neither the Company nor any of its Subsidiaries has treated, stored, disposed of, arranged for or permitted the disposal of, transported, handled, released, or exposed any Person to, any substance (including without limitation any hazardous substance), owned or operated any property or facility which is or has been contaminated by any substance, so as to give rise to any current or future liabilities under any Environmental and Safety Requirements in effect at the time of such treatment, storage, disposal, transportation, handling, release or exposure. (d) Except as set forth in Section 4.27(d) of the Disclosure Schedule, neither the Company nor any of its Subsidiaries has assumed, undertaken, or provided any indemnity with respect to, any liability of any other Person relating to Environmental and Safety Requirements. (e) The Company has furnished to Investor true and correct copies of all environmental audits, reports, assessments and all other documents materially bearing on environmental, health or safety liabilities relating to the past or current operations or facilities of the Company and all of its Subsidiaries, in each case which are in its possession or under its reasonable control.

  • Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract. a. The contractor shall notify all potential subcontractors and suppliers and lessors of their EEO obligations under this contract. b. The contractor will use good faith efforts to ensure subcontractor compliance with their EEO obligations.

  • Cooperation on forestry matters and environmental protection 1. The aims of cooperation on forestry matters and environmental protection will be, but not limited to, as follows: (a) establishing bilateral cooperation relations in the forestry sector; (b) developing a training program and studies for sustainable management of forests; (c) improving the rehabilitation and sustainable management of forest with the aim of increasing carbon sinks and reduce the impact of climate change in the Asia-Pacific region; (d) cooperating on the execution of national projects, aimed at: improving the management of forest plantations for its transformation for industrial purposes and environmental protection; (e) elaborating studies on sustainable use of timber; (f) developing new technologies for the transformation and processing of timber and non-timber species; and (g) improving cooperation in agro-forestry technologies. 2. To achieve the objectives of the Article 149 (Objectives), the Parties may focus, as a means of cooperation and negotiations on concluding a bilateral agreement on forestry cooperation between the two Parties. Such collaboration will be as follows: (a) exchanges on science and technology as well as policies and laws relating the sustainable use of forest resources; (b) cooperation in training programs, internships, exchange of experts and projects advisory; (c) advice and technical assistance to public institutions and organizations of the Parties on sustainable use of forest resources and environmental protection; (d) facilitating forest policy dialogue and technical cooperation under the Network of Sustainable Forest Management and Forest Rehabilitation in Asia- Pacific Region, initiated at the 15th Asia Pacific Economic Cooperation (APEC) Meeting; (e) encouraging joint studies, working visits, exchange of experiences, among others; and (f) others activities mutually agreed.

  • Compliance with Federal and State Work Authorization and Immigration Laws The Contractor and all subcontractors, suppliers and consultants must comply with all federal and state work authorization and immigration laws, and must certify compliance using the form set forth in Section 7 (“Georgia Security and Immigration Compliance Act Affidavits”). The required certificates must be filed with the Owner and copied maintained by the Contractor as of the beginning date of this contract and each subcontract, supplier contract, or consultant contract, and upon final payment to the subcontractor or consultant. State officials, including officials of the Georgia Department of Audits and Accounts, officials of the Owner, retain the right to inspect and audit the Project Site and employment records of the Contractor, subcontractors and consultants without notice during normal working hours until Final Completion, and as otherwise specified by law and by Rules and Regulations of the Georgia Department of Audits and Accounts.

  • Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!