Seller’s Remedies If Purchaser fails to perform its obligations pursuant to this Contract at or prior to Closing for any reason except failure by Seller to perform hereunder, or if prior to Closing any one or more of Purchaser's representations or warranties are breached in any material respect, and this failure or breach is not cured within three (3) Business Days after written notice from Seller to Purchaser (other than failure to close for any reason unrelated to a default by Seller, for which there shall be no notice or cure period), then Seller, as its SOLE and EXCLUSIVE remedy (except as provided in Sections 6(c) and 9), may (i) terminate this Contract and receive the Xxxxxxx Money as liquidated damages and not as penalty, in full satisfaction of claims against Purchaser hereunder, or (ii) waive Purchaser’s failure or breach and proceed to Closing. Seller and Purchaser agree that Seller's damages resulting from Purchaser's default are difficult, if not impossible, to determine, and the Xxxxxxx Money is a fair estimate of those damages and has been agreed to in an effort to cause the amount of damages to be certain. Notwithstanding anything in this Section 11(a) to the contrary, in the event of Purchaser's default or termination of this Contract, Seller shall have all remedies available at law or in equity if Purchaser or any party related to or affiliated with Purchaser is asserting any claims or right to the Property that would otherwise delay or prevent Seller from having clear, indefeasible and marketable title to the Property other than as a result of Purchaser’s exercise of its remedies under subsection (b) hereof. If Closing is consummated, then Seller shall have all remedies available at law or in equity if Purchaser fails to perform any post-closing obligation of Purchaser under this Contract.
Purchaser’s Remedies If Seller defaults on its obligations hereunder, or Portfolio Seller defaults in its obligations under the Portfolio Purchase and Sale Agreement at or prior to Closing for any reason, or if prior to Closing any one or more of Seller’s, or, with respect to the Portfolio Purchase and Sale Agreement, Portfolio Sellers’, representations or warranties or covenants are breached in any material respect (subject to the provisions of Section 4.4 hereof and of the Portfolio Purchase and Sale Agreement and the first Sentence of Section 9.3 hereof and of the Portfolio Purchase and Sale Agreement), and such default or breach is not cured by the earlier of the third (3rd) Business Day after written notice thereof from Purchaser or the Closing Date (except no notice or cure period shall apply if Seller fails to consummate the sale of the Membership Interests hereunder or Portfolio Seller fails to consummate the sale of the Portfolio Property under the Portfolio Purchase and Sale Agreement), Purchaser shall elect, as its sole remedy hereunder, either to (a) terminate this Agreement by giving Seller timely written notice of such election prior to or at Closing and recover the Xxxxxxx Money, in which event Seller shall be liable to Purchaser for its out of pocket expenses incurred in connection with the transaction contemplated hereby, but not to exceed $300,000.00, (b) enforce specific performance to consummate the sale of the Membership Interests hereunder, or (c) waive said failure or breach and proceed to Closing without any reduction in the Purchase Price. Notwithstanding anything herein to the contrary, Purchaser shall be deemed to have elected to terminate this Agreement in its entirety if Purchaser fails to deliver to Seller written notice of its intent to proceed otherwise on or before ten (10) Business Days following the scheduled Closing Date or, having given notice that it intends to seek specific performance, fails to file a lawsuit asserting such claim or cause of action in New York County, New York within two months following the scheduled Closing Date. EXCEPT FOR iSTAR’S POTENTIAL LIABILITY PURSUANT TO THE MEZZANINE LOAN AND SECTION 9.4, IN NO EVENT SHALL SELLER’S DIRECT OR INDIRECT PARTNERS, SHAREHOLDERS, MEMBERS, MANAGERS, OWNERS OR AFFILIATES, ANY OFFICER, MANAGER, DIRECTOR, EMPLOYEE OR AGENT OF THE FOREGOING, OR ANY AFFILIATE OR CONTROLLING PERSON THEREOF HAVE ANY LIABILITY FOR ANY CLAIM, CAUSE OF ACTION OR OTHER LIABILITY ARISING OUT OF OR RELATING TO THIS AGREEMENT, THE MEMBERSHIP INTERESTS, THE REAL PROPERTY OR THE IMPROVEMENTS, WHETHER BASED ON CONTRACT, COMMON LAW, STATUTE, EQUITY OR OTHERWISE.
REMEDY OF DEFECTS (a) The BUILDER shall remedy, at its expense, any defects, against which the VESSEL is guaranteed under this Article, by making all necessary repairs or replacements at the SHIPYARD or elsewhere as provided for in (b) hereinbelow. In such case, the VESSEL shall be taken at the BUYER's cost and responsibility to the place selected, ready in all respects for such repairs or replacements and in any event, the BUILDER shall not be responsible for towage, dockage, wharfage, port charges and anything else incurred for the BUYER's getting and keeping the VESSEL ready for such repairing or replacing. (b) However, if it is impractical (which shall include, but not be limited to, an emergency) to bring the VESSEL to the SHIPYARD, the BUYER may cause the necessary repairs or replacements to be made elsewhere which is deemed by the BUYER with the consent of the BUILDER which shall not be unreasonably withheld, to be suitable for the purpose, provided that, in such event, the BUILDER may forward or supply replacement parts or materials under the terms described in (c) hereinbelow, unless forwarding or supplying thereof under the terms described in (c) hereinbelow would impair or delay the operation or working schedule of the VESSEL. In the event that the BUYER proposes to cause the necessary repairs or replacements to be made to the VESSEL at any shipyard or works other than the SHIPYARD, the BUYER shall first (but in all events as soon as reasonably possible) give the BUILDER notice by email or facsimile of the time and place such repairs will be made, and if the VESSEL is not thereby delayed, or her operation or working schedule is not thereby impaired, the BUILDER shall have the right to verify by its own representative(s) the nature and extent of the defects complained of. The BUILDER shall, in such case, promptly advise the BUYER by email or facsimile, after such examination has been completed, of its acceptance or rejection of the defects as ones that are covered by the guarantee herein provided. Upon the BUILDER's acceptance of the defects as justifying remedy under this Article, or upon award of the arbitration so determining, the BUILDER shall compensate the BUYER an amount equal to the reasonable cost of making the same repairs or replacements at the SHIPYARD. (c) In the event that it is necessary for the BUILDER to forward a replacement for a defective part under this guarantee, replacement parts shall be shipped to the BUYER under the C.I.F terms to the BUYER's nominated port. The BUILDER reserves the option to retrieve, at the BUILDER's cost, any of the replaced equipment/parts in case defects are remedied in accordance with the provisions in this Article. (d) Any dispute under this Article shall be referred to arbitration in accordance with the provisions of Article XIII hereof.
Indemnification by Purchaser Purchaser shall indemnify, defend and hold Seller, its affiliates and its and their respective directors, managers, officers, employees, agents, representatives and advisors (the “Seller Indemnitees”) harmless from and shall reimburse the applicable Seller Indemnitee for any Losses suffered or incurred by any Seller Indemnitee which result from: (a) Any material breach of a representation or warranty by Purchaser, or non-fulfillment of any covenant or obligation of Purchaser contained in this Agreement; and (b) Litigation, proceedings, governmental investigations, orders, injunctions or decrees, the basis for which occurred after the Agreement Date, resulting from any of the items described in Section 11.02(a) above; provided, however, that the applicable Seller Indemnitee has taken all commercially reasonable and appropriate actions to mitigate any such losses, damages, deficiencies, claims, causes of action or expenses as reasonably requested by Purchaser, which such failure of mitigation shall not relieve Purchaser of its indemnification obligations in this Section 11.02 but may affect the amount of such obligation; and further provided, that any Losses incurred by the Seller Indemnitee pursuant to any attempt to mitigate any such losses, damages, deficiencies, claims, causes of action or expenses shall be reimbursed by Purchaser as part of its indemnification obligations in this Section 11.02. Seller shall notify Purchaser promptly after receiving written notice of the assertion of any litigation, proceedings, governmental investigations, orders, injunctions, decrees or any third party claims subject to indemnification under this Agreement (each, a “Third Party Claim”). Upon receipt of such notice of a Third Party Claim, Purchaser shall have the right to assume the defense of such Third Party Claim using counsel of its choice reasonably satisfactory to the applicable Seller Indemnitee, but may not enter into any settlement without the prior written consent of Purchaser, which shall not be unreasonably withheld. A Seller Indemnitee shall have the right to select separate counsel and to otherwise separately defend itself but shall not consent to the entry of a judgment or enter into any settlement with respect to the Third Party Claim without the prior written consent of Purchaser, which consent shall not be unreasonably withheld. Any exercise of such rights by a Seller Indemnitee shall not relieve Purchaser of its obligations and liabilities under this Section 11.02 or any other provision of this Agreement. With respect to any Third Party Claim subject to indemnification under this Agreement, the applicable Seller Indemnitee shall be required to cooperate in good faith with Purchaser to ensure the proper and adequate defense of such Third-Party Claim.
Indemnification by Buyer (a) After the Closing and subject to this Article VII, Buyer shall indemnify, defend and hold harmless the Seller Indemnitees against, and reimburse the Seller Indemnitees for, all Liabilities that the Seller Indemnitees may at any time suffer or incur, or become subject to: (i) as a result of or in connection with the breach or inaccuracy of any representation or warranty set forth in Article IV or contained in any certificate or instrument delivered by Buyer pursuant hereto; or (ii) as a result of or in connection with any breach or failure by Buyer to perform any of its covenants, agreements or obligations contained in this Agreement. (b) Notwithstanding anything to the contrary contained herein, Buyer shall not be required to indemnify, defend or hold harmless the Seller Indemnitees against, or reimburse the Seller Indemnitees for, any Liabilities pursuant to Section 7.3(a)(i): (i) until the aggregate amount of the Seller Indemnitees’ Liabilities for which the Seller Indemnitees are finally determined to be otherwise entitled to indemnification under Section 7.3(a)(i) exceeds the Deductible, after which Buyer shall be obligated for all the Seller Indemnitees’ Liabilities for which the Seller Indemnitees are finally determined to be otherwise entitled to indemnification under Section 7.3(a)(i) (but only Liabilities in excess of the Deductible) and (ii) in a cumulative aggregate amount with respect to indemnification under Section 7.3(a)(i) exceeding the Indemnification Cap. The foregoing limitation in this Section 7.3(b) shall not apply to any claim arising under Section 7.3(a)(ii) or any claim arising from the Fraud of the Buyer. (c) The Buyer shall not be required to indemnify, defend or hold harmless the Seller Indemnitees against, or reimburse the Seller Indemnitees for, any Liabilities pursuant to Section 7.3(a)(i) in a cumulative aggregate amount exceeding the Purchase Price. The foregoing limitation in this Section 7.3(c) shall not apply to any claim arising from the Fraud of the Buyer. (d) The representations, warranties, covenants, agreements and obligations of Buyer and any Seller Indemnitee’s right to indemnification with respect thereto shall not be affected or deemed waived by reason of (i) any investigation made by or on behalf of Seller Indemnitees (including by any of their respective Representatives) or by reason of the fact that such Seller Indemnitee or any of such Representatives knew or should have known that any such representation or warranty is, was or might be inaccurate, (ii) the waiver of any condition based on the accuracy of any representation or warranty, or on the performance of or compliance with any covenant, agreement or obligation or (iii) the Closing.
Indemnification by Purchasers Each Purchaser shall, severally and not jointly, indemnify and hold harmless the Company, its directors, officers, agents and employees, each Person who controls the Company (within the meaning of Section 15 of the Securities Act and Section 20 of the Exchange Act), and the directors, officers, agents or employees of such controlling Persons, to the fullest extent permitted by applicable law, from and against all Losses (as determined by a court of competent jurisdiction in a final judgment not subject to appeal or review) arising solely out of any untrue statement of a material fact contained in the Registration Statement, any Prospectus, or any form of prospectus, or in any amendment or supplement thereto, or arising solely out of any omission of a material fact required to be stated therein or necessary to make the statements therein (in the case of any Prospectus or form of prospectus or supplement thereto, in the light of the circumstances under which they were made) not misleading to the extent, but only to the extent, that such untrue statement or omission is contained in any information so furnished in writing by such Purchaser to the Company specifically for inclusion in such Registration Statement or such Prospectus or to the extent that (i) such untrue statements or omissions are based solely upon information regarding such Purchaser furnished in writing to the Company by such Purchaser expressly for use therein, or to the extent that such information relates to such Purchaser or such Purchaser's proposed method of distribution of Registrable Securities and was reviewed and expressly approved in writing by such Purchaser expressly for use in the Registration Statement, such Prospectus or such form of Prospectus or in any amendment or supplement thereto or (ii) in the case of an occurrence of an event of the type specified in Section 6.2(c)(v)-(vii), the use by such Purchaser of an outdated or defective Prospectus after the Company has notified such Purchaser in writing that the Prospectus is outdated or defective and prior to the receipt by such Purchaser of the Advice contemplated in Section 6.5. In no event shall the liability of any selling Purchaser hereunder be greater in amount than the dollar amount of the net proceeds received by such Purchaser upon the sale of the Registrable Securities giving rise to such indemnification obligation.
Indemnification by Buyers (a) Subject to this Article 11, Buyers, from and after Closing, shall indemnify and hold harmless Sellers, their Affiliates, and their respective officers, directors, equity holders, managers, members, principals, attorneys, agents, employees or other representatives (collectively, “Sellers Indemnified Parties”) from and against any and all Indemnifiable Losses that such Sellers Indemnified Party incurs as a result of, or with respect to (i) the breach of any of the representations or warranties made by Buyers in this Agreement, (ii) any breach or non-fulfillment of any of the covenants or other agreements made by Buyers in this Agreement, (iii) any of the Assumed Liabilities, and (iv) any fraud, willful misconduct or criminal acts of Buyers or their officers, directors, members, shareholders, employees, agents and independent contractors; (b) Buyers will have no obligation to indemnify Sellers Indemnified Parties pursuant to Section 11.2(a)(i) in respect of Indemnifiable Losses arising from the breach of, or inaccuracy in, any representation or warranty described therein unless the aggregate amount of all such Indemnifiable Losses incurred or suffered by Sellers Indemnified Parties exceeds $700,000, in which event the Sellers Indemnified Parties shall be entitled to seek indemnification under Sections 11.2(a)(i) for all claims over $350,000; provided, however, that the foregoing limitation will not apply to claims for indemnification pursuant to Section 11.2(a)(i) in respect of breaches of, or inaccuracies in, representations and warranties set forth in Section 5.1 (Organization; Capacity) or Section 5.2 (Authority; Noncontravention) (collectively, “Buyers Fundamental Representations”). For avoidance of doubt, claims for indemnification pursuant to Sections 11.2(a)(ii), (iii) and (iv) are not subject to the monetary limitation set forth in this Section 11.2(b); and (c) Buyers’ aggregate liability in respect of claims for indemnification pursuant to Section 11.2(a)(i) and (ii) will not exceed an amount equal to the 20% Cap for its breach of representations, warranties and covenants other than the Buyers Fundamental Representations. Buyer’s aggregate liability in respect of claims for indemnification under this Agreement will not exceed the Purchase Price Cap, except that Buyers’ aggregate liability in respect of claims pursuant to Section 11.2(a)(iii) shall not be subject to the 20% Cap or the Purchase Price Cap. (d) Anything herein to the contrary notwithstanding, obligations of Buyer under Section 10.1, 10.2 and Section 10.13 shall not be subject to the monetary limitation set forth in Section 11.2(b) or the 20% Cap or the Purchase Price Cap in Section 11.2(c).
Infringement Remedies If, in either party’s opinion, any piece of equipment, software, commodity, or service supplied by Contractor or its subcontractors, or its operation, use or reproduction, is likely to become the subject of a copyright, patent, trademark, or trade secret infringement claim, Contractor must, at its expense: (a) procure for the State the right to continue using the equipment, software, commodity, or service, or if this option is not reasonably available to Contractor, (b) replace or modify the same so that it becomes non-infringing; or (c) accept its return by the State with appropriate credits to the State against Contractor’s charges and reimburse the State for any losses or costs incurred as a consequence of the State ceasing its use and returning it.
Limited Remedy If Microsoft, or the device manufacturer or installer, breaches its limited warranty, it will, at its election, either: (i) repair or replace the software at no charge, or (ii) accept return of the software (or at its election the device on which the software was preinstalled) for a refund of the amount paid, if any. The device manufacturer or installer (or Microsoft if you acquired them directly from Microsoft) may also repair or replace supplements, updates, and replacement of the software or provide a refund of the amount you paid for them, if any. These are your only remedies for breach of warranty. This limited warranty gives you specific legal rights, and you may also have other rights which vary from state to state or country to country.
