Requests for Supplementary Information Sample Clauses

Requests for Supplementary Information. It shall be the responsibility of the Contractor to make timely requests of the County for any additional information not already in his possession which should be furnished by the County under the terms of this Contract, and which he will require in the planning and execution of the work. Such requests may be submitted from time to time as the need approaches, but each shall be filed in ample time to permit appropriate action to be taken by all parties involved so as to avoid delay. Each request shall be in writing, and list the various items and the latest date by which each will be required by the Contractor. The first list shall be submitted within two weeks after Contract award and shall be as complete as possible at that time. The Contractor shall, if requested, furnish promptly any assistance and information the Engineer may require in responding to these requests of the Contractor. The Contractor shall be fully responsible for any delay in his work or to others arising from his failure to comply fully with the provision of this section.
Sample 1See All (4)
AutoNDA by SimpleDocs
Requests for Supplementary Information. Upon request from the Commission or the Office, the Beneficiary undertakes to provide at its own expense and within a given deadline of twenty (20) working days, any complementary information, invoices or documents concerning the activities undertaken and the use of the grant awarded in the framework of the agreement. This information may also be requested on a sampling basis.
Sample 1
Requests for Supplementary Information. It shall be the responsibility of the Contractor to make timely requests of Xxxx County for any additional information which should be furnished by Xxxx County under the terms of this Contract, and which is required in the planning and execution of the work. Such requests may be submitted from time to time as the need approaches, but each shall be filed in ample time to permit appropriate action to be taken by all parties involved so as to avoid delay. Each request shall be in writing, and list the various items and the latest date by which each will be required by the Contractor. The first list shall be submitted within two weeks after Contract award and shall be as complete as possible at that time. The Contractor shall, if requested, furnish promptly any assistance and information the Engineer may require in responding to these requests of the Contractor. The Contractor shall be fully responsible for any delay in his work or to others arising from his failure to comply fully with the provision of this section.
Sample 1

Related to Requests for Supplementary Information

  • SUPPLEMENTARY INFORMATION Paperwork Reduction Act The collection of information in this final rule has been reviewed and, pending receipt and evaluation of public comments, approved by the Office of Management and Budget (OMB) under 44 U.S.C. 3507 and assigned control number 1545-1675. The collection of information in this regulation is in Sec. 1.860E-1(c)(5)(ii). This information is required to enable the IRS to verify that a taxpayer is complying with the conditions of this regulation. The collection of information is mandatory and is required. Otherwise, the taxpayer will not receive the benefit of safe harbor treatment as provided in the regulation. The likely respondents are businesses and other for-profit institutions. Comments on the collection of information should be sent to the Office of Management and Budget, Attn: Desk Officer for the Department of the Treasury, Office of Information and Regulatory Affairs, Xxxxxxxxxx, XX, 00000, with copies to the Internal Revenue Service, Attn: IRS Reports Clearance Officer, W:CAR:MP:FP:S, Xxxxxxxxxx, XX 00000. Comments on the collection of information should be received by September 17, 2002. Comments are specifically requested concerning: Whether the collection of information is necessary for the proper performance of the functions of the Internal Revenue Service, including whether the information will have practical utility; The accuracy of the estimated burden associated with the collection of information (see below); How the quality, utility, and clarity of the information to be collected may be enhanced; How the burden of complying with the collection of information may be minimized, including through the application of automated collection techniques or other forms of information technology; and Estimates of capital or start-up costs and costs of operation, maintenance, and purchase of service to provide information. An agency may not conduct or sponsor, and a person is not required to respond to, a collection of information unless it displays a valid control number assigned by the Office of Management and Budget. The estimated total annual reporting burden is 470 hours, based on an estimated number of respondents of 470 and an estimated average annual burden hours per respondent of one hour. Books or records relating to a collection of information must be retained as long as their contents may become material in the administration of any internal revenue law. Generally, tax returns and tax return information are confidential, as required by 26 U.S.C. 6103.

Time is Money Join Law Insider Premium to draft better contracts faster.