Responsibilities With Respect to Facilities Management
Responsibilities With Respect to Facilities Management Sample Clauses
Related to Responsibilities With Respect to Facilities Management
Responsibilities of the District 12.1. The District shall examine the documents submitted by the Architect and shall render decisions so as to avoid unreasonable delay in the process of the Architect’s Services. 12.2. The District shall verbally or in writing advise Architect if the District becomes aware of any fault or defect in the Project, including any errors, omissions or inconsistencies in the Architect’s documents. Failure to provide such notice shall not relieve Architect of its responsibility therefore, if any. 12.3. Unless the District and Architect agree that a hazardous materials consultant shall be a Consultant of the Architect, the District shall furnish the services of a hazardous material consultant or other consultants when such services are requested in writing by Architect and deemed necessary by the District or are requested by the District. These services shall include: asbestos and lead paint survey; abatement documentation; and specifications related to said matters, which are to be incorporated into bid documents prepared by Architect. If the hazardous materials consultant is furnished by the District and is not a Consultant of the Architect, the specifications shall include a note to the effect that the hazardous materials consultant’s specifications are included in the Architect’s bid documents for the District’s convenience and have not been prepared or reviewed by the Architect. The note shall also direct questions about the hazardous materials consultant’s specifications related to asbestos and lead paint survey and/or abatement documentation to the preparer of the hazardous materials consultant’s specifications.
Responsibilities of the City The City’s Contract Manager will be responsible for exercising general oversight of the Contractor’s activities in completing the Scope of Work. Specifically, the Contract Manager will represent the City’s interests in resolving day-to-day issues that may arise during the term of this Contract, shall participate regularly in conference calls or meetings for status reporting, shall promptly review any written reports submitted by the Contractor, and shall approve all invoices for payment, as appropriate. The City’s Contract Manager shall give the Contractor timely feedback on the acceptability of progress and task reports.
RESPONSIBILITIES OF CITY City or its representative shall issue all communications to Contractor. City has the authority to request changes in the work in accordance with the terms of this Agreement and with the terms in Exhibit A – Scope of Work. City has the authority to stop work or to suspend any work.
Cost Responsibility for Interconnection Facilities and Distribution Upgrades 4.1 Interconnection Facilities 4.2 Distribution Upgrades
RESPONSIBILITIES OF THE UNIVERSITY The UNIVERSITY shall designate in writing a faculty member to coordinate with a designee of the FIELDWORK SITE.
Responsibilities of the Company 3.3.1 The Company shall provide participants of CopyTrade with a complete package of services according to the Customer Agreement. The Company is liable for proper performance of technological solutions according to the Customer Agreement. 3.3.2 The Company bears no liability to participants of CopyTrade for lost profit or losses, which may directly or indirectly occur as a result of trading operations performed or not performed by an Investor or a Trader. 3.3.3 The Company bears no liability to participants of CopyTrade for lost profit or losses, which may be directly or indirectly occur as a result of their ignorance of regulatory documents or cooperation scheme. 3.3.4 The Company doesn’t evaluate Traders’ professional skills and suitability not on a single stage of their activity and bears no responsibility to Investors for any losses or lost profit they may incur. 3.3.5 The Company is not liable for:
Responsibilities of the Contractor The Contractor shall provide all technical and professional expertise, knowledge, management, and other resources required for accomplishing all aspects of the tasks and associated activities identified in the Scope of Work. In the event that the need arises for the Contractor to perform services beyond those stated in the Scope of Work, the Contractor and the City shall negotiate mutually agreeable terms and compensation for completing the additional services.
Responsibilities of Contractor A. The Contractor shall perform all work on the described project as required by the Contract documents. The work to be performed includes the labor and services necessary to produce such replacement, and all materials, supplies, tools, transportation, equipment, and machinery required for replacement. B. This project bid includes all materials, labor and equipment to complete the reconstruction and resurfacing of streets as outlined in the Project Manual for WWREYN - XXXXXXXX SANITARY SEWER - PHASE 1 dated March 25th, 2021 as outlined in Attachment A.
Restrictions on Activities of the Trust Notwithstanding any other provision of this Agreement and any provision of law that otherwise so empowers the Trust, so long as any Certificates are outstanding, the Trust shall not, and none of the Trustee, the Delaware Trustee, the Company or the Servicer shall knowingly cause the Trust to, do any of the following: (i) engage in any business or activity other than those set forth in Section 2.01; (ii) incur or assume any indebtedness except for such indebtedness that may be incurred by the Trust in connection with the execution or performance of this Agreement or any other agreement contemplated hereby; (iii) guarantee or otherwise assume liability for the debts of any other party; (iv) do any act in contravention of this Agreement or any other agreement contemplated hereby to which the Trust is a party; (v) do any act which would make it impossible to carry on the ordinary business of the Trust; (vi) confess a judgment against the Trust; (vii) possess or assign the assets of the Trust for other than a Trust purpose; (viii) cause the Trust to lend any funds to any entity, except as contemplated by this Agreement; or (ix) change the purposes and powers of the Trust from those set forth in this Agreement.
RESPONSIBILITIES OF THE STATE 3.2.1 The State will identify a Project Manager for the Project. The Project Manager will be the sole point of contact between the Contractor and the State. The Project Manager will be the State’s representative authorized to communicate the State’s position and directions related to all contract work and to coordinate all change orders with the Commissioner of Buildings and General Services as deemed necessary. 3.2.2 If applicable, the State shall furnish all surveys describing the physical characteristics, legal limitations and utility locations for the site of the Project, and a legal description of the site. 3.2.3 Except as provided in Subparagraph 4.7.1, the State shall secure and pay for necessary approvals, easements, assessments and charges required for the construction, use or occupancy of permanent structures or for permanent changes in existing facilities. 3.2.4 Information or services under the State's control shall be furnished by the State with reasonable promptness to avoid delay in the orderly progress of the Work. 3.2.5 Unless otherwise provided in the Contract Documents, the Contractor will be furnished, free of charge, all copies of Drawings and Specifications reasonably necessary for the execution of the Work. 3.2.6 The State shall forward instructions to the Contractor through the Architect. 3.2.7 The foregoing are in addition to any other duties and responsibilities of the State enumerated in the Contract Documents including those responsibilities described in Articles 6, 9 and 11 of this agreement. 3.2.8 The State may utilize a Clerk-of-the-Works to provide inspection and monitoring work on behalf of the State. If a Clerk-of-the-Works is utilized, it is the responsibility of the Architect and the Contractor to review and understand the Clerk’s duties, responsibilities and limitations of authority. Upon request, the State shall provide a copy of the Clerk-of-the-Works contract to Architect and Contractor.
