Responsibility for Construction of Phase II of the Project Sample Clauses

Responsibility for Construction of Phase II of the Project. Safeway has applied for a building permit for the Safeway Facilities. Safeway hereby agrees and commits to the City that, on receipt of the necessary building permits; satisfaction of the conditions of the Safeway/Hospital Exchange Agreement; and the Hospital’s conveyance of title to the Project Site to Safeway, Safeway shall promptly commence and diligently prosecute to completion, subject to Unavoidable Delays, the construction of the Safeway Facilities, at a cost of not less than the Estimated Completed Cost of Construction. If the Bonds have been sold, failure to commence construction of the Safeway Facilities within 120 days of receipt of a City building permit for the Safeway Facilities and satisfaction of all the above conditions, other than attributable to Unavoidable Delays, will constitute an abandonment of Phase II of the Project and Event of Default under Section 8.2 hereof.
Sample 1
AutoNDA by SimpleDocs

Related to Responsibility for Construction of Phase II of the Project

  • RESPONSIBILITY FOR CONSTRUCTION COST 5.2.1 Evaluations of the Owner's Project budget, preliminary estimates of Construction Cost and detailed estimates of Construction Cost prepared by the Design Professional represent the Design Professional's best judgment as a design professional familiar with the construction industry. It is recognized, however, that neither the Design Professional nor the Owner has control over the cost of labor, materials or equipment, over the Contractor's methods of determining bid prices, or over competitive bidding or market conditions. Accordingly, the Design Professional cannot and does not warrant or represent that bids or cost proposals will not vary from the Owner's Project budget or from any estimate of Construction Cost or evaluation prepared or agreed to by the Design Professional.

  • BUILDER’S RISK FOR CONSTRUCTION RENOVATION PROJECTS If the project is CONSTRUCTION RENOVATION of an existing structure, and the State has already determined that Contractor will not be obligated to obtain and maintain Builder’s Risk insurance, then the following provisions apply:

  • Project Construction The Contractor agrees to provide continuous on-site supervision on each Job Order, while progress on the project is being accomplished. The Contractor’s Project Manager will ensure:

  • CONSTRUCTION OF THE PROJECT The Allottee has seen the proposed layout plan, specifications, amenities and facilities of the Apartment/ Plot and accepted the floor plan, payment plan and the specification, amenities and facilities annexed along with this Agreement which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the said layout plans, floor plans and specifications, amenities and facilities. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent authorities and shall also strictly abide by the bye-laws, FAR, and density norms and provisions prescribed by the relevant building bye-laws and shall not have an option to make any variation/ alteration/ modification in such plans, other than in the manner provided under the Act, and breach of this term by the Promoter shall constitute a material breach of this Agreement.

  • Construction Phase - Administration of the Construction Contract 1.6.1 The Construction Phase shall commence with the acceptance of the Construction Manager’s Guaranteed Maximum Price (or acceptance of a partial Guaranteed Maximum Price for a stage or phase) and issuance of a Notice to Proceed with Construction Services and terminate sixty (60) days after Final Payment to the Contractor is made, or when all of Architect/Engineer’s services have been satisfactorily performed, whichever occurs later.

  • COMPENSATION FOR CONSTRUCTION PHASE SERVICES 5.1 For the Construction Manager’s performance of the Work as described in Section 2.3, the Owner shall pay the Construction Manager the Contract Sum in current funds. The Contract Sum is the Cost of the Work as defined in Section 6.1.1 plus the Construction Manager’s Fee.

  • ADDITIONAL CONSTRUCTION The Promoter undertakes that it has no right to make additions or to put up additional structure(s) anywhere in the Project after the building plan has been approved by the competent authority (ies) except for as provided in the Act.

  • Construction and Maintenance There are on-going maintenance, renovation and construction projects taking place in and around the residences. The work typically takes place during regular business hours, but may begin earlier or extend into evenings or weekends. On-going construction or renovation projects will continue through midterm and final exam periods. The University will take measures to ensure that prudent construction practices are followed, but there may be noise, dust and temporary interruption of some services. Residents may be required to temporarily or permanently relocate to facilitate construction or renovation to their residence area. There will be no compensation or reduction to your residence fees due to disruption and/or relocation.

  • Execution of the Project Section 3.01. (a) The Borrower declares its commitment to the objectives of the Project as set forth in Schedule 2 to this Agreement, and, to this end, shall carry out the Project with due diligence and efficiency and in conformity with appropriate administrative, financial, banking, accounting and environmental practices, and shall provide, promptly as needed, the funds, facilities, services and other resources required for the Project.

  • Post-Construction Phase A. Upon written authorization from Owner during the Post-Construction Phase, Engineer shall:

Time is Money Join Law Insider Premium to draft better contracts faster.