Design and Drawings (i) Design and Drawings shall be developed in conformity with the Specifications and Standards set forth in Schedule-D. In the event, the Contractor requires any relaxation in design standards due to restricted Right of Way in any section, the alternative design criteria for such section shall be provided for review and approval of the Authority’s Engineer.
(ii) The Contractor shall appoint a proof check consultant (the “Proof Consultant”) after proposing to the Authority a panel of three (3) names of qualified and experienced firms from whom the Authority may choose one (1) to be the Proof Consultant. Provided, however, that if the panel is not acceptable to the Authority and the reasons for the same are furnished to the Contractor, the Contractor shall propose to the Authority a revised panel of three (3) names from the firms empanelled as proof consultants by the [Ministry of Road Transport and Highways] for obtaining the consent of the Authority. The Contractor shall also obtain the consent of the Authority for two (2) key personnel of the Proof Consultant who shall have adequate experience and qualifications in highways and bridges respectively. The Authority shall, within 15 (fifteen) days of receiving a proposal from the Contractor hereunder, convey its decision, with reasons, to the Contractor, and if no such decision is conveyed within the said period, the Contractor may proceed with engaging of the Proof Consultant.
(iii) The Proof Consultant shall:
(a) evolve a systems approach with the Design Director so as to minimise the time required for final designs and construction drawings; and
(b) proof check the detailed calculations, drawings and designs, which have been approved by the Design Director.
(iv) In respect of the Contractor’s obligations with respect to the design and Drawings of the Project Highway as set forth in Schedule-I, the following shall apply:
(a) The Contractor shall prepare and submit, with reasonable promptness and in such sequence as is consistent with the Project Completion Schedule, three (3) copies each of the design and Drawings, duly certified by the Proof Consultant, to the Authority’s Engineer for its approval. Provided, however, that in respect of Major Xxxxxxx and Structures, the Authority’s Engineer may require additional drawings for approval in accordance with Good Industry Practice.
(b) by submitting the Drawings for review and approval to the Authority’s Engineer, the Contractor shall be deemed to have represented that it has determined and verified that the design and engineering, including field construction criteria related thereto, are in conformity with the Scope of the Project, the Specifications and Standards and the Applicable Laws;
(c) within 15 (fifteen) days of the receipt of the Drawings, the Authority’s Engineer shall review the same and convey its approval/observations to the Contractor with particular reference to their conformity or otherwise with the Scope of the Project and the Specifications and Standards. Provided, however that in case of a major bridge or structure, the aforesaid period of 15 (fifteen) days may be extended up to 30 (thirty) days;
(d) if the aforesaid observations of the Authority’s Engineer indicate that the Drawings are not in conformity with the Scope of the Project or the Specifications and Standards, such Drawings shall be revised by the Contractor in conformity with the provisions of this Agreement and resubmitted to the Authority’s Engineer for review and approval. The Authority’s Engineer shall give its observations, if any, within 10 (ten) days of receipt of the revised Drawings. In the event the Contractor fails to revise and resubmit such Drawings to the Authority’s Engineer for review/approval as aforesaid, the Authority’s Engineer may withhold the payment for the affected works in accordance with the provisions of Clause 19.5 (iv). If the Contractor disputes any decision, direction or determination of the Authority’s Engineer hereunder, the Dispute shall be resolved in accordance with the Dispute Resolution Procedure;
(e) no review/approval and/or observation of the Authority’s Engineer and/or its failure to review/approval and/or convey its observations on any Drawings shall relieve the Contractor of its obligations and liabilities under this Agreement in any manner nor shall the Authority’s Engineer or the Authority be liable for the same in any manner; and if errors, omissions, ambiguities, inconsistencies, inadequacies or other Defects are found in the Drawings, they and the construction works shall be corrected at the Contractor's cost, notwithstanding any approval under this Article 10;
(f) the Contractor shall be responsible for delays in submitting the Drawing as set forth in Schedule-I caused by reason of delays in surveys and field investigations, and shall not be entitled to seek any relief in that regard from the Authority; and
(g) the Contractor warrants that its designers, including any third parties engaged by it, shall have the required experience and capability in accordance with Good Industry Practice and it shall indemnify the Authority against any damage, expense, liability, loss or claim, which the Authority might incur, sustain or be subject to arising from any breach of the Contractor’s design responsibility and/or warranty set out in this Clause.
(h) the Contractor shall ensure that all the designs and drawings shall be approved from the Authority’s Engineer within 90 days (ninety) from the Appointed Date.
(v) Any cost or delay in construction arising from review/approval by the Authority’s Engineer shall be borne by the Contractor.
(vi) Works shall be executed in accordance with the Drawings provided by the Contractor in accordance with the provisions of this Clause 10.2 and the approval of the Authority’s Engineer thereon as communicated pursuant to the provisions of sub- Clause (c) & (d) of Clause 10.2 (iv). Such Drawings shall not be amended or altered without prior written notice to the Authority’s Engineer. If a Party becomes aware of an error or defect of a technical nature in the design or Drawings, that Party shall promptly give notice to the other Party of such error or defect.
(vii) Within 90 (ninety) days of the Project Completion Date, the Contractor shall furnish to the Authority and the Authority’s Engineer a complete set of as- built Drawings, in 2 (two) hard copies and in micro film form or in such other medium as may be acceptable to the Authority, reflecting the Project Highway as actually designed, engineered and constructed, including an as-built survey illustrating the layout of the Project Highway and setback lines, if any, of the buildings and structures forming part of Project Facilities.
Technical Specifications and Drawings a) The Goods and Related Services supplied under this Contract shall conform to the technical specifications and standards mentioned in Section VI, Schedule of Requirements and, when no applicable standard is mentioned, the standard shall be equivalent or superior to the official standards whose application is appropriate to the Goods' country of origin.
b) The Supplier shall be entitled to disclaim responsibility for any design, data, drawing, specification or other document, or any modification thereof provided or designed by or on behalf of the Procuring Entity, by giving a notice of such disclaimer to the Procuring Entity.
c) Wherever references are made in the Contract to codes and standards in accordance with which it shall be executed, the edition or the revised version of such codes and standards shall be those specified in the Schedule of Requirements. During Contract execution, any changes in any such codes and standards shall be applied only after approval by the Procuring Entity and shall be treated in accordance with GCC Clause 33.
Application of Commitment Reductions; Payment of Fees The Administrative Agent will promptly notify the Appropriate Lenders of any termination or reduction of unused portions of the Letter of Credit Sublimit or the Swing Line Sublimit or the unused Commitments of any Class under this Section 2.06. Upon any reduction of unused Commitments of any Class, the Commitment of each Lender of such Class shall be reduced by such Lender’s Pro Rata Share of the amount by which such Commitments are reduced (other than the termination of the Commitment of any Lender as provided in Section 3.07). All commitment fees accrued until the effective date of any termination of the Aggregate Commitments shall be paid on the effective date of such termination.
Payment of Checks, Drafts and Orders Subject to Section 9.5, the Assuming Institution agrees to pay all properly drawn checks, drafts and withdrawal orders of depositors of the Failed Bank presented for payment, whether drawn on the check or draft forms provided by the Failed Bank or by the Assuming Institution, to the extent that the Deposit balances to the credit of the respective makers or drawers assumed by the Assuming Institution under this Agreement are sufficient to permit the payment thereof, and in all other respects to discharge, in the usual course of conducting a banking business, the duties and obligations of the Failed Bank with respect to the Deposit balances due and owing to the depositors of the Failed Bank assumed by the Assuming Institution under this Agreement.
Issuance of and Drawings and Reimbursement Under Letters of Credit (a) The Letter of Credit Commitment.
(i) Subject to the terms and conditions set forth herein, (A) each Issuing Bank agrees, in reliance upon the agreements of the other Lenders set forth in this Section 2.03, (1) from time to time on any Business Day during the period from the Closing Date until the Letter of Credit Expiration Date, to issue Letters of Credit for the account of the Borrower or any of its Subsidiaries, and to amend Letters of Credit previously issued by it, in accordance with subsection (b) below, and (2) to honor drafts under the Letters of Credit; and (B) the Lenders severally agree to participate in Letters of Credit issued for the account of the Borrower or any of its Subsidiaries; provided that the Issuing Banks shall not be obligated to issue any Letter of Credit, and no Lender shall be obligated to participate in any Letter of Credit if as of the date of such issuance, (x) the Available Amount for all Letters of Credit issued by such Issuing Bank would exceed the lesser of the Letter of Credit Sublimit at such time and such Issuing Bank’s Letter of Credit Commitment at such time, (y) the Available Amount of such Letter of Credit would exceed the Unused Revolving Credit Commitment or (z) the sum of (1) the aggregate principal amount of all Revolving Credit Advances plus Swing Line Advances and Letter of Credit Advances outstanding at such time plus (2) the aggregate Available Amount of all Letters of Credit outstanding at such time exceed the Borrowing Base at such time. Within the foregoing limits, and subject to the terms and conditions hereof, the Borrower’s ability to obtain Letters of Credit shall be fully revolving, and accordingly the Borrower may, during the foregoing period, obtain Letters of Credit to replace Letters of Credit that have expired or that have been drawn upon and reimbursed. All Existing Letters of Credit issued for the account of the Borrower or its Subsidiaries shall be deemed to have been issued pursuant hereto, and from and after the Closing Date shall be subject to and governed by the terms and conditions hereof.
(ii) No Issuing Bank shall be under any obligation to issue any Letter of Credit if: (A) any order, judgment or decree of any governmental authority or arbitrator shall by its terms purport to enjoin or restrain such Issuing Bank from issuing such Letter of Credit, or any law applicable to such Issuing Bank or any request or directive (whether or not having the force of law) from any governmental authority with jurisdiction over such Issuing Bank shall prohibit, or request that such Issuing Bank refrain from, the issuance of letters of credit generally or such Letter of Credit in particular or shall impose upon such Issuing Bank any unreimbursed loss, cost or expense which such Issuing Bank in good xxxxx xxxxx material to it; (B) the expiry date of such requested Letter of Credit would occur after the Letter of Credit Expiration Date, unless all the Revolving Credit Lenders have approved such expiry date; (C) the issuance of such Letter of Credit would violate one or more policies of such Issuing Bank; or (D) such Letter of Credit is in an initial amount less than $100,000 (unless such Issuing Bank agrees otherwise), or is to be denominated in a currency other than U.S. dollars.
(iii) No Issuing Bank shall be under any obligation to amend any Letter of Credit if (A) such Issuing Bank would have no obligation at such time to issue such Letter of Credit in its amended form under the terms hereof, or (B) the beneficiary of such Letter of Credit does not accept the proposed amendment to such Letter of Credit.
Checks, Drafts, etc All checks, drafts or other orders for the payment of money, notes or other evidences of indebtedness issued in the name of the corporation, shall be signed by such officer or officers, agent or agents of the corporation and in such manner as shall from time to time be determined by resolution of the directors.
Selection of Architect/Construction Drawings (i) Tenant shall retain an architect approved in writing, in advance by Landlord, such approval not to be unreasonably withheld, conditioned or delayed (the “Architect”) to prepare the Construction Drawings. Tenant shall retain engineering consultants approved in writing, in advance by Landlord, such approval not to be unreasonably withheld (the “Building Consultants”) to prepare all plans and engineering working drawings and perform all work relating to mechanical, electrical and plumbing (“MEP”), HVAC/Air Balancing, life-safety, structural, sprinkler and riser work.
(ii) The plans and drawings to be prepared by Architect and the Building Consultants hereunder (i.e., both the Space Plan and the Working Drawings, as each term is defined below) shall be known collectively as the “Construction Drawings.” All Construction Drawings shall comply with the drawing format and specifications reasonably determined or approved by Landlord and shall be subject to Landlord’s prior written approval, not to be unreasonably withheld, conditioned or delayed. All MEP drawings must be fully engineered or prepared on a “design-build-assist” basis with a Landlord-approved MEP basis of design (“BOD”), as prepared by an approved MEP engineer consultant. The MEP drawings cannot be prepared on a strictly “design-build” basis. Landlord’s review of the Construction Drawings shall be for its sole purpose and shall not obligate Landlord to review the same, for quality, design, Code compliance or other like matters. Accordingly, notwithstanding that any Construction Drawings are reviewed by Landlord or its space planner, architect, engineers and consultants, and notwithstanding any advice or assistance which may be rendered to Tenant by Landlord or Landlord’s space planner, architect, engineers, and consultants, Landlord shall have no liability whatsoever in connection therewith and shall not be responsible for any omissions or errors contained in the Construction Drawings.
Order to Stop Work The Commission, may, by written order to Contractor/Vendor at any time, and without notice to any Surety, require Contractor/Vendor to stop all or any part of the work called for by this contract. This order shall be for a specified period not exceeding 90 days after the order is delivered to Contractor/Vendor, unless the parties agree to any further period. Any such order shall be identified specifically as a stop work order issued pursuant to this clause. Upon receipt of such an order, Contractor/Vendor shall forthwith comply with its terms and take all reasonable steps to minimize the occurrence of costs allocable to the work covered by the order during the period of work stoppage. Before the stop work order expires, or within any further period to which the parties shall have agreed, the Commission shall either: Cancel the stop work order; or, Terminate the work covered by such order as provided in the Termination for Default clause or the Termination for Convenience clause of this Contract.
Procedures for Issuance and Amendment of Letters of Credit; Auto-Extension Letters of Credit (i) Each Letter of Credit shall be issued or amended, as the case may be, upon the request of the Borrower delivered to the L/C Issuer (with a copy to the Administrative Agent) in the form of a Letter of Credit Application, appropriately completed and signed by a Responsible Officer of the Borrower. Such Letter of Credit Application may be sent by facsimile, by United States mail, by overnight courier, by electronic transmission using the system provided by the L/C Issuer, by personal delivery or by any other means acceptable to the L/C Issuer. Such Letter of Credit Application must be received by the L/C Issuer and the Administrative Agent not later than 11:00 a.m. at least two Business Days (or such later date and time as the Administrative Agent and the L/C Issuer may agree in a particular instance in their sole discretion) prior to the proposed issuance date or date of amendment, as the case may be. In the case of a request for an initial issuance of a Letter of Credit, such Letter of Credit Application shall specify in form and detail satisfactory to the L/C Issuer: (A) the proposed issuance date of the requested Letter of Credit (which shall be a Business Day); (B) the amount thereof; (C) the expiry date thereof; (D) the name and address of the beneficiary thereof; (E) the documents to be presented by such beneficiary in case of any drawing thereunder; (F) the full text of any certificate to be presented by such beneficiary in case of any drawing thereunder; (G) the purpose and nature of the requested Letter of Credit; and (H) such other matters as the L/C Issuer may require. In the case of a request for an amendment of any outstanding Letter of Credit, such Letter of Credit Application shall specify in form and detail satisfactory to the L/C Issuer (1) the Letter of Credit to be amended; (2) the proposed date of amendment thereof (which shall be a Business Day); (3) the nature of the proposed amendment; and (4) such other matters as the L/C Issuer may require. Additionally, the Borrower shall furnish to the L/C Issuer and the Administrative Agent such other documents and information pertaining to such requested Letter of Credit issuance or amendment, including any Issuer Documents, as the L/C Issuer or the Administrative Agent may require.
(ii) Promptly after receipt of any Letter of Credit Application, the L/C Issuer will confirm with the Administrative Agent (by telephone or in writing) that the Administrative Agent has received a copy of such Letter of Credit Application from the Borrower and, if not, the L/C Issuer will provide the Administrative Agent with a copy thereof. Unless the L/C Issuer has received written notice from any Revolving Credit Lender, the Administrative Agent or any Loan Party, at least one Business Day prior to the requested date of issuance or amendment of the applicable Letter of Credit, that one or more applicable conditions contained in Article IV shall not then be satisfied, then, subject to the terms and conditions hereof, the L/C Issuer shall, on the requested date, issue a Letter of Credit for the account of the Borrower or enter into the applicable amendment, as the case may be, in each case in accordance with the L/C Issuer’s usual and customary business practices. Immediately upon the issuance of each Letter of Credit, each Revolving Credit Lender shall be deemed to, and hereby irrevocably and unconditionally agrees to, purchase from the L/C Issuer a risk participation in such Letter of Credit in an amount equal to the product of such Revolving Credit Lender’s Applicable Revolving Credit Percentage times the amount of such Letter of Credit.
(iii) If the Borrower so requests in any applicable Letter of Credit Application, the L/C Issuer may, in its sole and absolute discretion, agree to issue a Letter of Credit that has automatic extension provisions (each, an “Auto-Extension Letter of Credit”); provided that any such Auto-Extension Letter of Credit must permit the L/C Issuer to prevent any such extension at least once in each twelve-month period (commencing with the date of issuance of such Letter of Credit) by giving prior notice to the beneficiary thereof not later than a day (the “Non-Extension Notice Date”) in each such twelve-month period to be agreed upon at the time such Letter of Credit is issued. Unless otherwise directed by the L/C Issuer, the Borrower shall not be required to make a specific request to the L/C Issuer for any such extension. Once an Auto-Extension Letter of Credit has been issued, the Revolving Credit Lenders shall be deemed to have authorized (but may not require) the L/C Issuer to permit the extension of such Letter of Credit at any time to an expiry date not later than the Letter of Credit Expiration Date; provided, however, that the L/C Issuer shall not permit any such extension if (A) the L/C Issuer has determined that it would not be permitted, or would have no obligation at such time to issue such Letter of Credit in its revised form (as extended) under the terms hereof (by reason of the provisions of clause (ii) or (iii) of Section 2.03(a) or otherwise), or (B) it has received notice (which may be by telephone or in writing) on or before the day that is seven Business Days before the Non-Extension Notice Date (1) from the Administrative Agent that the Required Revolving Lenders have elected not to permit such extension or (2) from the Administrative Agent, any Revolving Credit Lender or the Borrower that one or more of the applicable conditions specified in Section 4.02 is not then satisfied, and in each such case directing the L/C Issuer not to permit such extension.
(iv) Promptly after its delivery of any Letter of Credit or any amendment to a Letter of Credit to an advising bank with respect thereto or to the beneficiary thereof, the L/C Issuer will also deliver to the Borrower and the Administrative Agent a true and complete copy of such Letter of Credit or amendment.
Changes in Tax, Debt, Credit and Documentary Stamp Laws (a) If any law is enacted or adopted or amended after the date of this Agreement which deducts the Debt from the value of the Property for the purpose of taxation and which imposes a tax, either directly or indirectly, on the Debt or Lender’s interest in the Property, Borrower will pay the tax, with interest and penalties thereon, if any. If Lender is advised by counsel chosen by it that the payment of tax by Borrower would be unlawful or taxable to Lender or unenforceable or provide the basis for a defense of usury then Lender shall have the option by written notice of not less than ninety (90) days to declare the Debt immediately due and payable.
(b) Borrower will not claim or demand or be entitled to any credit or credits on account of the Debt for any part of the Taxes or Other Charges assessed against the Property, or any part thereof, and no deduction shall otherwise be made or claimed from the assessed value of the Property, or any part thereof, for real estate tax purposes by reason of the Security Instrument or the Debt. If such claim, credit or deduction shall be required by applicable law, Lender shall have the option, by written notice of not less than ninety (90) days, to declare the Debt immediately due and payable.
(c) If at any time the United States of America, any State thereof or any subdivision of any such State shall require revenue or other stamps to be affixed to the Note, the Security Instrument, or any of the other Loan Documents or impose any other tax or charge on the same, Borrower will pay for the same, with interest and penalties thereon, if any.
