Review and Approval of Contractor's Submittals Sample Clauses

Review and Approval of Contractor's Submittals. The Architect will review and approve the Contractor's Submittals, such as shop drawings and product samples, for the limited purpose of checking for compliance with the Contract Documents. The Architect's review does not relieve the Contractor of his obligations under the Contract to comply with the plans and specifications. The Architect's approval of a submittal which contains a deviation which has not been specifically called to the Architect's attention excludes approval of that deviation and shall not serve as a waiver of the rights of the Architect or Owner unless the Architect makes specific written acceptance of said deviation on the Architect's letterhead or Owner makes specific written acceptance of said deviation on the Owner's letterhead.
Sample 1Sample 2Sample 3See All (10)
AutoNDA by SimpleDocs
Review and Approval of Contractor's Submittals. The Engineer will review and approve the Contractor's Submittals, such as shop drawings and product samples, for the limited purpose of checking for compliance with the Contract Documents. The Engineer's review does not relieve the Contractor of his obligations under the Contract to comply with the plans and specifications. The Engineer's approval of a submittal which contains a deviation which has not been specifically called to the Engineer's attention excludes approval of that deviation and shall not serve as a waiver of the rights of the Engineer or Owner unless the Engineer makes specific written acceptance of said deviation on the Engineer's letterhead or Owner makes specific written acceptance of said deviation on the Owner's letterhead.
Sample 1
Review and Approval of Contractor's Submittals. The Project Engineer will review and approve the CONTRACTOR’s Submittals, such as shop drawings and product samples, for the limited purpose of checking for compliance with the Contract Documents. The Project Engineer’s review does not relieve the CONTRACTOR of his obligations under the Contract to comply with the plans and specifications. The Project Engineer’s approval of a submittal which contains a deviation which has not been specifically called to the Project Engineer’s attention excludes approval of that deviation and shall not serve as a waiver of the rights of the Project Engineer or CITY unless the Project Engineer makes specific written acceptance of said deviation on the Project Engineer’s letterhead or the CITY makes specific written acceptance of said deviation on the CITY’s letterhead.
Sample 1
Review and Approval of Contractor's Submittals. The CONSULTANT will review and approve the CONTRACTOR's Submittals, such as shop drawings and product samples, for the limited purpose of checking for compliance with the Contract Documents. The CONSULTANT's review does not relieve the CONTRACTOR of his obligations under the Contract to comply with the plans and specifications. The CONSULTANT's approval of a submittal which contains a deviation which has not been specifically called to the CONSULTANT's attention excludes approval of that deviation and shall not serve as a waiver of the rights of the CONSULTANT or OWNER unless the CONSULTANT makes specific written acceptance of said deviation on the CONSULTANT's letterhead or OWNER makes specific written acceptance of said deviation on the OWNER's letterhead.
Sample 1

Related to Review and Approval of Contractor's Submittals

  • Approval of Contractor’s Staff 7.3.1 County has the absolute right to approve or disapprove all of the Contractor’s staff performing work hereunder and any proposed changes in the Contractor’s staff, including, but not limited to, the Contractor’s Project Manager.

  • Review and Approval Documents specified above must be submitted for review and approval by CITY Purchasing and Contracts prior to the commencement of work by CONTRACTOR. Neither approval by CITY nor failure to disapprove the insurance furnished by CONTRACTOR shall relieve CONTRACTOR of CONTRACTOR’S full responsibility to provide the insurance required by this Contract. Compliance with the insurance requirements of this Contract shall not limit the liability of CONTRACTOR or its sub-contractors, employees or agents to CITY or others, and shall be in addition to and not in lieu of any other remedy available to CITY under this Contract or otherwise. CITY reserves the right to request and review a copy of any required insurance policy or endorsement to assure compliance with these requirements.

  • CONTRACTOR’S SUBMISSION OF CONTRACT MODIFICATIONS In connection with any Contract modification, OGS reserves the right to:  request additional information  reject Contract modifications  remove Products from Contract modification requests  request additional discounts for new or existing Products

  • Contractor’s Submittals The Contract shall submit with reasonable promptness consistent with the Work Project Schedule and in orderly sequence all Shop Drawings, Samples, or other information required by the Contract Documents, or subsequently required by Change Order. Prior to submitting, the Contractor shall review each submittal for compliance with the Contract Documents and certify its approval by an approval stamp affixed to each copy. Submittal data presented without the Contractor’s certification will be returned without review or comment, and any delay resulting from such certification is the Contractor's responsibility.

  • State Approval of Replacement Personnel The Engineer may not replace the project manager or key personnel without prior consent of the State. The State must be satisfied that the new project manager or other key personnel is qualified to provide the authorized services. If the State determines that the new project manager or key personnel is not acceptable, the Engineer may not use that person in that capacity and shall replace him or her with one satisfactory to the State within forty-five (45) days.

  • County Review and Approval of Insurance Requirements The County reserves the right to review and adjust the Required Insurance provisions, conditioned upon County’s determination of changes in risk exposures.

  • REGULATORY FILINGS AND CAISO TARIFF COMPLIANCE 3.1 Filing

  • Project Implementation Manual The Recipient, through the PCU, shall: (i) take all action required to carry out Parts 1.1, 1.3, 1.4, 2, 3.1(b), 3.2, 3.3 and 4 (ii) of the Project in accordance with the provisions and requirements set forth or referred to in the Project Implementation Manual; (ii) submit recommendations to the Association for its consideration for changes and updates of the Project Implementation Manual as they may become necessary or advisable during Project implementation in order to achieve the objective of Parts 1.1, 1.3, 1.4, 2, 3.1(b), 3.2, 3.3 and 4(ii) of the Project; and (iii) not assign, amend, abrogate or waive the Project Implementation Manual or any of its provisions without the Association’s prior agreement. Notwithstanding the foregoing, if any of the provisions of the Project Implementation Manual is inconsistent with the provisions of this Agreement, the provisions of this Agreement shall prevail and govern.

  • FAA APPROVAL This Agreement may be subject to approval of the FAA. If the FAA disapproves this Agreement, it will become null and void, and both Parties will bear their own expenses relative to this Agreement, up to the date of disapproval.

  • Contract Closure Contracting Officer shall give appropriate written notice to Purchaser when Purchaser has complied with the terms of this contract. Purchaser shall be paid refunds due from Timber Sale Account un- der B4.24 and excess cooperative deposits under B4.218.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!