Review of the Claim Sample Clauses

Review of the Claim. The A/E shall review the Claim and prepare a written analysis of its content, which shall include:
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Review of the Claim. 8.9.1 The A/E shall review the Claim and prepare a written analysis of its content, which shall include: 8.9.1.1 a narrative of the A/E’s examination of the facts giving rise to the Claim; 8.9.1.2 identification of relevant Contract Documents and language; 8.9.1.3 an analysis of whether the CM complied with the requirements of the Contract Documents pertaining to Claim initiation and substantiation including, without limitation, the issues of entitlement to, and calculation of, adjustments of the Contract Sum, Contract Times, or both; 8.9.1.4 an analysis of claimed additional labor, materials, and equipment for the scope of the Work items described; 8.9.1.5 an analysis of any time extension for any interference, disruption, hindrance, impact, or delay claimed (to include the calculation of any concurrent delays affecting entitlement); 8.9.1.6 a concluding opinion regarding CM entitlement to, and the appropriateness and reasonableness of all, or any part of, the Claim; and 8.9.1.7 an appendix containing copies of contemporaneous documentation supporting the concluding opinion. 8.9.2 The A/E shall submit the written analysis to the Project Manager no more than 30 days after receiving the CM’s substantiated and certified Claim.
Sample 1Sample 2
Review of the Claim. If the Contractor wishes to have the Town review the Claim, the Contractor shall send a written notice to the Project Sponsor (as set out in the Contract), no later than 28 days after submitting the Notice of Claim, expressly referring to this Section 1.2.57.1.2.4 and requesting the Town review the Claim (the “Level 1 Notice”). Failure by the Contractor to provide the Level 1 Notice by such deadline shall be deemed by the County to be an abandonment of the Claims Review Process for Contractor Claims (as set out in Section 1.2.57.1), unless otherwise agreed to in writing by the Town. The parties will make bona fide efforts to review the Claim but the Work must proceed or continue without delay during the following process to review the Claim:
Sample 1

Related to Review of the Claim

  • Review of Documents Borrower has reviewed: (a) the Note, (b) the Security Instrument, (c) the Commitment Letter, and (d) all other Loan Documents.

  • Review of Decision Within sixty (60) days after the Secretary’s receipt of a request for review, he or she will review the Company’s determination. After considering all materials presented by the Claimant, the Secretary will render a written opinion, written in a manner calculated to be understood by the Claimant, setting forth the specific reasons for the decision and containing specific references to the pertinent provisions of this Agreement on which the decision is based. If special circumstances require that the sixty (60) day time period be extended, the Secretary will so notify the Claimant and will render the decision as soon as possible, but no later than one hundred twenty (120) days after receipt of the request for review.

  • Review Rights The State and the U.S. Department of Transportation, when federal funds are involved, and any of their authorized representatives shall have the right at all reasonable times to review or otherwise evaluate the work performed hereunder and the premises in which it is being performed.

  • Claims Review Population A description of the Population subject to the Claims Review.

  • Settlement of Third Party Claims Notwithstanding any other provision of this Agreement, the Indemnifying Party shall not enter into settlement of any Third Party Claim without the prior written consent of the Indemnified Party, except as provided in this Section 8.05(b). If a firm offer is made to settle a Third Party Claim without leading to liability or the creation of a financial or other obligation on the part of the Indemnified Party and provides, in customary form, for the unconditional release of each Indemnified Party from all liabilities and obligations in connection with such Third Party Claim and the Indemnifying Party desires to accept and agree to such offer, the Indemnifying Party shall give written notice to that effect to the Indemnified Party. If the Indemnified Party fails to consent to such firm offer within ten days after its receipt of such notice, the Indemnified Party may continue to contest or defend such Third Party Claim and in such event, the maximum liability of the Indemnifying Party as to such Third Party Claim shall not exceed the amount of such settlement offer. If the Indemnified Party fails to consent to such firm offer and also fails to assume defense of such Third Party Claim, the Indemnifying Party may settle the Third Party Claim upon the terms set forth in such firm offer to settle such Third Party Claim. If the Indemnified Party has assumed the defense pursuant to Section 8.05(a), it shall not agree to any settlement without the written consent of the Indemnifying Party (which consent shall not be unreasonably withheld or delayed).

  • Review of Fund Documents During the term of this Sub-Advisory Agreement, MassMutual shall furnish to the Sub-Adviser at its principal office all prospectuses, proxy statements, reports to shareholders, sales literature, or other material prepared for distribution to shareholders of the Fund or the public, which refer to the Sub-Adviser or its clients in any way, prior to the use thereof, and MassMutual shall not use any such materials if the Sub-Adviser reasonably objects in writing five (5) days (or such other time as may be mutually agreed, which would include longer time periods for review of the Fund’s prospectus and other parts of its registration statement) after receipt thereof. MassMutual shall ensure that materials prepared by employees or agents of MassMutual or its affiliates that refer to the Sub-Adviser or its clients in any way are consistent with those materials previously approved by the Sub-Adviser as referenced in the preceding sentence.

  • ADB’s Review of Procurement Decisions 11. All contracts procured under international competitive bidding procedures and contracts for consulting services shall be subject to prior review by ADB, unless otherwise agreed between the Borrower and ADB and set forth in the Procurement Plan.

  • Complaints Investigation The employee who complains of harassment under the provisions of the Human Rights Code must first comply with the Employer’s harassment policy procedures before filing a grievance or human rights complaint.

  • Joint Remediation Committee If the Sellers (acting reasonably) determine that the Purchasers have committed a Major Default, then, at the election of the Sellers, within three (3) Business Days of the Sellers providing the Purchasers written notice of such determination, the Sellers and the Purchasers shall establish a joint remediation committee of designated executives from the Sellers and the Purchasers (“Joint Remediation Committee”) consisting of three (3) members of each of the Sellers and the Purchasers. The Joint Remediation Committee shall be responsible for overseeing the development of a mutually agreeable plan in accordance with subsection 3 below to either (i) remediate any breaches giving rise to the Major Default to the extent such breaches can be remediated and/or (ii) prevent similar breaches from recurring in the future (clauses (i) and (ii), a “Corrective Action Plan”). Each member of the Joint Remediation Committee shall have sufficient authority on the part of his or her respective party to make decisions relating to matters reviewed by the Joint Remediation Committee, and shall be approved by the other party (such approval not to be unreasonably delayed, conditioned or withheld). The Joint Remediation Committee shall have access to Purchaser Personnel that are primarily responsible for the area of the business relationship (such as information technology, data security or regulatory) where the breaches giving rise to the Major Default arise (such Purchaser Personnel, collectively, the “Subject Matter Experts”). The Sellers and the Purchasers shall cause their respective members on the Joint Remediation Committee to, and the Purchasers shall cause the Subject Matter Experts to, act in good faith in connection with the development of the Corrective Action Plan.

  • Review of Materials During the term of this Agreement, Client shall ensure that all prospectuses, statements of additional information, registration statements, proxy statements, reports to shareholders, advertising and sales literature or other materials prepared for distribution to Fund shareholders or the public, which refer to the Subadviser in any way, prepared by employees or agents of Client or its affiliates are consistent with information previously provided by Subadviser. Subadviser shall promptly notify the Client of any changes to information pertaining to the Subadviser and stated in the materials described in this Section 6(g).

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!