Claim Initiation Sample Clauses

Claim Initiation. Every Claim shall be stated with specificity in writing and signed by Contractor under penalty of perjury and presented to the District within ten (10) calendar days from the date Contractor discovers or reasonably should discover, that an act, error or omission of District, its agents or employees, or action, condition or other situation has occurred that may entitle Contractor to file a Claim. Contractor shall provide this writing even if Contractor has not yet been damaged, 7.2.1. Identify all of the issues, events, conditions, circumstances and/or causes giving rise to the Claim; 7.2.2. Identify all pertinent dates and/or durations and all actual and/or anticipated effects on the Contract Price, milestones and/or Contract Time adjustments; and 7.2.3. Identify in detail line-item costs if the Claim seeks money. 7.2.4. If the Claim involves extra work, a detailed cost breakdown of the amounts the Contractor is seeking, including actual cost records (including without limitation, payroll records, material and rental invoices and the like) demonstrating that those costs have actually been incurred. To the extent costs have not yet been incurred at the time the Claim is submitted, actual cost records must be submitted on a current basis not less than once a week during any periods costs are incurred. A cost record will be considered current if submitted within seven (7) days of the date the cost reflected in the record is incurred. At the request of District, extra costs may be subject to further verification procedures (such as having an inspector verify the performance of alleged extra work on a daily basis). 7.2.5. If the Claim involves an error or omission in the Agreement: 7.2.5.1. An affirmative 7.2.5.2. A detailed statement demonstrating that the error or omission reasonably should not have been discovered, by Contractor, its Subcontractors and suppliers, prior to submitting a proposal for the Work. 7.2.6. Contractor shall not be entitled to compensation for escalation of materials costs unless Contractor demonstrates to the satisfaction of the District that such cost escalation is the result of unusual, unforeseeable market conditions, not the fault of the Contractor, and were not reasonably foreseeable at the time of the award of the Contract. Contractor shall provide evidence to District of the costs included in the Contract for those materials and that those costs were reasonable at the time and that Contractor timely ordered the materials at iss...
Sample 1Sample 2Sample 3See All (9)
AutoNDA by SimpleDocs

Related to Claim Initiation

  • Initiation (i) Seller shall deliver a Transaction Request or Purchase Price Increase Request, as applicable, to Buyer on or prior to the date and time set forth in Section 4(b)(vii) prior to entering into any Transaction. Such Transaction Request or Purchase Price Increase Request shall include an Asset Schedule with respect to the Underlying Assets to be sold in such requested Transaction. Buyer shall confirm the terms of each Transaction by issuing a written confirmation to the Seller promptly after the parties enter into such Transaction in the form of Exhibit A attached hereto (a “Confirmation”). Such Confirmation shall set forth (A) the Purchase Date, (B) the Purchase Price, (C) the Repurchase/Release Date, (D) the Pricing Rate applicable to the Transaction, (E) the applicable Purchase Price Percentages, and (F) additional terms or conditions not inconsistent with this Agreement. Seller shall execute and return the Confirmation to Buyer via facsimile or electronic mail on or prior to 5:00 p.m. (New York time) on the date one (1) Business Day prior to the related Purchase Date. (ii) The Repurchase/Release Date for each Transaction shall not be later than the Termination Date. (iii) Each Confirmation, together with this Agreement, shall be conclusive evidence of the terms of the Transaction(s) covered thereby. (iv) Subject to the terms and conditions of this Agreement, during such period Seller may sell, repurchase and resell Purchased Assets, Pledged Assets, Underlying Assets and Eligible Assets hereunder. (v) No later than the date and time set forth in the Custodial Agreement, Seller shall deliver to the Custodian the Asset File pertaining to each Eligible Asset to be purchased by Buyer. (vi) Upon Buyer’s receipt of the Trust Receipt in accordance with the Custodial Agreement and subject to the provisions of this Section 4, the Purchase Price may then be made available to Seller by Buyer transferring, via wire transfer to the account designated by the Seller, in the aggregate amount of such Purchase Price in funds immediately available.

  • Project Initiation i - Upon final execution of the Agreement with the DISTRICT, the ARCHITECT shall: ♦ Review the Program Management Plan (PMP) with the DISTRICT and its representatives to familiarize them with the proposed tasks and schedule and develop necessary modifications. The PMP defines the Program Master Schedule and Budgets and each Project scope and budget. ii - Within the first week following execution of the Agreement, meet with the DISTRICT and its representatives to prepare a detailed task analysis and work plan for documentation in a computer-generated project schedule. iii - This task analysis and work plan will identify specific tasks including, but not limited to: ♦ interviews, ♦ data collection ♦ analysis, ♦ report preparation, ♦ planning, ♦ Architectural programming, concepts and schematic design preparation and estimating that are part of the work of the Project. Also identified will be milestone activities or dates, specific task responsibilities, required completion times necessary for the review and approval by the DISTRICT and by all regulatory agencies and additional definition of deliverables. iv - Participate in a general Project kick-off meeting to include the ARCHITECT, appropriate sub-consultants, and DISTRICT staff. v - The project kick-off meeting will introduce key team members from the DISTRICT and the ARCHITECT to each other, defining roles and responsibilities relative to the Project. vi - Identify and review pertinent information and/or documentation necessary from the DISTRICT for the completion of the Project. vii - Review and explain the overall project goals, general approach, tasks, work plan and procedures and deliverable products of the Project. viii - Review and explain the task analysis and Project work plan for all parties present; determine any adjustments or fine tuning that needs to be made to the work plan. ix - Review documentation of the Project kick-off meeting prepared by the DISTRICT’S representative and comment prior to distribution. x - Base Drawings and Site Survey Information

  • Notice; Defense of Claims An indemnified party may make claims for indemnification hereunder by giving written notice thereof to the indemnifying party within the period in which indemnification claims can be made hereunder. If indemnification is sought for a claim or liability asserted by a third party, the indemnified party shall also give written notice thereof to the indemnifying party promptly after it receives notice of the claim or liability being asserted, but the failure to do so shall not relieve the indemnifying party from any liability except to the extent that it is prejudiced by the failure or delay in giving such notice. Such notice shall summarize the bases for the claim for indemnification and any claim or liability being asserted by a third party. Within 20 days after receiving such notice the indemnifying party shall give written notice to the indemnified party stating whether it disputes the claim for indemnification and whether it will defend against any third party claim or liability at its own cost and expense. If the indemnifying party fails to give notice that it disputes an indemnification claim within 20 days after receipt of notice thereof, it shall be deemed to have accepted and agreed to the claim, which shall become immediately due and payable. The indemnifying party shall be entitled to direct the defense against a third party claim or liability with counsel selected by it (subject to the consent of the indemnified party, which consent shall not be unreasonably withheld) as long as the indemnifying party is conducting a good faith and diligent defense. The indemnified party shall at all times have the right to fully participate in the defense of a third party claim or liability at its own expense directly or through counsel; provided, however, that if the named parties to the action or proceeding include both the indemnifying party and the indemnified party and the indemnified party is advised that representation of both parties by the same counsel would be inappropriate under applicable standards of professional conduct, the indemnified party may engage separate counsel at the expense of the indemnifying party. If no such notice of intent to dispute and defend a third party claim or liability is given by the indemnifying party, or if such good faith and diligent defense is not being or ceases to be conducted by the indemnifying party, the indemnified party shall have the right, at the expense of the indemnifying party, to undertake the defense of such claim or liability (with counsel selected by the indemnified party), and to compromise or settle it, exercising reasonable business judgment. If the third party claim or liability is one that by its nature cannot be defended solely by the indemnifying party, then the indemnified party shall make available such information and assistance as the indemnifying party may reasonably request and shall cooperate with the indemnifying party in such defense, at the expense of the indemnifying party.

  • Objections to Claims At the time of delivery of any Officer's -------------------- Certificate to the Escrow Agent, a duplicate copy of such certificate shall be delivered to the Shareholder Representative and for a period of thirty (30) days after such delivery, the Escrow Agent shall make no delivery to Parent of any Escrow Amounts pursuant to Section 7.2(d) hereof unless the Escrow Agent shall have received written authorization from the Shareholder Representative to make such delivery. After the expiration of such thirty (30) day period, the Escrow Agent shall make delivery of the Escrow Amount from the Escrow Fund in accordance with Section 7.2(d) hereof, provided that no such payment or delivery may be made if the Shareholder Representative shall object in a written statement to the claim made in the Officer's Certificate, and such statement shall have been delivered to the Escrow Agent prior to the expiration of such thirty (30) day period.

  • Defense of Third Party Claims In the case of a Third-Party Claim, the Indemnifying Party shall have the right: (a) to control and conduct any proceedings or negotiations in connection therewith and necessary or appropriate to defend the claim, (b) to take all other reasonable steps or proceedings to settle or defend any such Third-Party Claim; provided, that the Indemnifying Party shall not settle any Third-Party Claim without the prior written consent of the Indemnified Party (which consent shall not be unreasonably withheld, conditioned, or delayed), and (c) to employ counsel designated by the Indemnifying Party to contest any such Third-Party Claim in the name of the Indemnified Party or otherwise. The Indemnifying Party shall, within fifteen (15) days of receipt of a Third-Party Claim Notice (the “Indemnity Notice Period”), give written notice to the Indemnified Party of its intention to assume the defense of such Third-Party Claim. If the Indemnifying Party does not deliver to the Indemnified Party within the Indemnity Notice Period written notice that the Indemnifying Party shall assume the defense of any such Third-Party Claim, then the Indemnified Party may defend against any such Third-Party Claim in any such manner as it may deem appropriate, provided, that the Indemnified Party shall not settle any such Third-Party Claim without the prior written consent of the Indemnifying Party, which consent shall not be unreasonably withheld, conditioned, or delayed. In the event that the Indemnifying Party does assume the defense of such Third-Party Claim, the Indemnified Party shall have the right to fully participate in (but not control) such defense (including with counsel of its choice), at its sole expense, and the Indemnifying Party shall reasonably cooperate with the Indemnified Party in connection with such participation. In the event that either the Indemnifying Party or the Indemnified Party assumes the defense of a Third-Party Claim as provided above (the “Controlling Party”), the non-Controlling Party shall have the right to fully participate (but not control) in such defense (including with counsel of its choice), at its sole expense, and the Controlling Party shall reasonably cooperate with the non-Controlling Party in connection with such participation; provided, however, that Buyer and Seller shall each use its commercially reasonable efforts with respect to any information shared pursuant to this Section 7.3(b) to preserve attorney-client privilege.

  • Third Party Claim Procedures In the case of any claim asserted by a third party (a “Third Party Claim”) against a party entitled to indemnification under this Agreement (an “Indemnified Party”), notice shall be given by the Indemnified Party to the party required to provide indemnification (the “Indemnifying Party”) promptly after such Indemnified Party has actual knowledge of such Third Party Claim, and the Indemnified Party shall permit the Indemnifying Party (at the expense of such Indemnifying Party and so long as the Indemnifying Party acknowledges in writing its obligation to indemnify the Indemnified Party for Losses related to such Third Party Claim) to assume the defense of such Third Party Claim, provided that (a) counsel for the Indemnifying Party who shall conduct the defense of such Third Party Claim shall be reasonably satisfactory to the Indemnified Party, and the Indemnified Party may participate in such defense at such Indemnified Party’s expense, and (b) the failure of any Indemnified Party to give notice as provided herein shall not relieve the Indemnifying Party of its indemnification obligation under this Agreement except to the extent that such failure results in a lack of actual notice to the Indemnifying Party and such Indemnifying Party is materially prejudiced as a result of such failure to be given notice. If the Indemnifying Party does not promptly assume the defense of such Third Party Claim following notice thereof, the Indemnified Party shall be entitled to assume and control such defense and to settle or agree to pay in full such Third Party Claim without the consent of the Indemnifying Party without prejudice to the ability of the Indemnified Party to enforce its claim for indemnification against the Indemnifying Party hereunder. Except with the prior written consent of the Indemnified Party, no Indemnifying Party, in the defense of any such Third Party Claim, shall consent to entry of any judgment or enter into any settlement that provides for injunctive or other nonmonetary relief affecting the Indemnified Party or that does not include as an unconditional term thereof the giving by each claimant or plaintiff to such Indemnified Party of an irrevocable release from all liability and wrongdoing with respect to such Third Party Claim. Seller and Buyers shall cooperate in the defense of any Third Party Claim subject to this Article IX and the records of each shall be reasonably available to the other with respect to such defense.

  • Defense of the Underlying Proceeding (a) Indemnitee shall notify the Company promptly in writing upon being served with any summons, citation, subpoena, complaint, indictment, request or other document relating to any Proceeding which may result in the right to indemnification or the advance of Expenses hereunder and shall include with such notice a description of the nature of the Proceeding and a summary of the facts underlying the Proceeding. The failure to give any such notice shall not disqualify Indemnitee from the right, or otherwise affect in any manner any right of Indemnitee, to indemnification or the advance of Expenses under this Agreement unless the Company’s ability to defend in such Proceeding or to obtain proceeds under any insurance policy is materially and adversely prejudiced thereby, and then only to the extent the Company is thereby actually so prejudiced. (b) Subject to the provisions of the last sentence of this Section 13(b) and of Section 13(c) below, the Company shall have the right to defend Indemnitee in any Proceeding which may give rise to indemnification hereunder; provided, however, that the Company shall notify Indemnitee of any such decision to defend within 15 calendar days following receipt of notice of any such Proceeding under Section 13(a) above. The Company shall not, without the prior written consent of Indemnitee, which shall not be unreasonably withheld or delayed, consent to the entry of any judgment against Indemnitee or enter into any settlement or compromise which (i) includes an admission of fault of Indemnitee, (ii) does not include, as an unconditional term thereof, the full release of Indemnitee from all liability in respect of such Proceeding, which release shall be in form and substance reasonably satisfactory to Indemnitee, or (iii) would impose any Expense, judgment, fine, penalty or limitation on Indemnitee. This Section 13(b) shall not apply to a Proceeding brought by Indemnitee under Section 12 of this Agreement. (c) Notwithstanding the provisions of Section 13(b) above, if in a Proceeding to which Indemnitee is a party by reason of Indemnitee’s Corporate Status, (i) Indemnitee reasonably concludes, based upon an opinion of counsel approved by the Company, which approval shall not be unreasonably withheld or delayed, that Indemnitee may have separate defenses or counterclaims to assert with respect to any issue which may not be consistent with other defendants in such Proceeding, (ii) Indemnitee reasonably concludes, based upon an opinion of counsel approved by the Company, which approval shall not be unreasonably withheld or delayed, that an actual or apparent conflict of interest or potential conflict of interest exists between Indemnitee and the Company, or (iii) if the Company fails to assume the defense of such Proceeding in a timely manner, Indemnitee shall be entitled to be represented by separate legal counsel of Indemnitee’s choice, subject to the prior approval of the Company, which approval shall not be unreasonably withheld or delayed, at the expense of the Company. In addition, if the Company fails to comply with any of its obligations under this Agreement or in the event that the Company or any other person takes any action to declare this Agreement void or unenforceable, or institutes any Proceeding to deny or to recover from Indemnitee the benefits intended to be provided to Indemnitee hereunder, Indemnitee shall have the right to retain counsel of Indemnitee’s choice, subject to the prior approval of the Company, which approval shall not be unreasonably withheld or delayed, at the expense of the Company (subject to Section 12(d) of this Agreement), to represent Indemnitee in connection with any such matter.

  • Defense Costs No defense costs shall be included within or erode the limits of coverage of any of the insurance policies, except that litigation and mediation defense costs may be included within the limits of coverage of professional and pollution liability policies.

  • Claim Procedure Any Person entitled to indemnification hereunder shall (i) give prompt written notice to the indemnifying party of any claim with respect to which it seeks indemnification (provided that the failure to give prompt notice shall impair any Person’s right to indemnification hereunder only to the extent such failure has prejudiced the indemnifying party) and (ii) unless in such indemnified party’s reasonable judgment a conflict of interest between such indemnified and indemnifying parties may exist with respect to such claim, permit such indemnifying party to assume the defense of such claim with counsel reasonably satisfactory to the indemnified party. If such defense is assumed, the indemnifying party shall not be subject to any liability for any settlement made by the indemnified party without its consent (but such consent shall not be unreasonably withheld, conditioned or delayed). An indemnifying party who is not entitled to, or elects not to, assume the defense of a claim shall not be obligated to pay the fees and expenses of more than one counsel for all parties indemnified by such indemnifying party with respect to such claim, unless in the reasonable judgment of any indemnified party a conflict of interest may exist between such indemnified party and any other of such indemnified parties with respect to such claim. In such instance, the conflicted indemnified parties shall have a right to retain one separate counsel, chosen by the Holders representing a majority of the Registrable Securities included in the registration if such Holders are indemnified parties, at the expense of the indemnifying party.

  • Initiation – Written Claim The claimant initiates a claim by submitting to the Plan Administrator a written claim for the benefits. If such a claim relates to the contents of a notice received by the claimant, the claim must be made within sixty (60) days after such notice was received by the claimant. All other claims must be made within one hundred eighty (180) days of the date on which the event that caused the claim to arise occurred. The claim must state with particularity the determination desired by the claimant.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!