SHOP DRAWINGS, PRODUCT DATA AND SAMPLES 4.12.1 Shop Drawings are drawings, diagrams, schedules and other, data specially prepared for the Work by the Contractor or any Subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work.
4.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and other information furnished by the Contractor to illustrate a material, product or system for some portion of the Work.
4.12.3 Samples are physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged.
4.12.4 The Contractor shall review, approve and submit, with reasonable promptness and in such sequence as to cause no delay in the Work or in the work of the State or any separate contractor, all Shop Drawings, Product Data and Samples required by the Contract Documents.
4.12.5 By approving and submitting Shop Drawings, Product Data and Samples, the Contractor represents that he / she has determined and verified all materials, field measurements, and field construction criteria related thereto, or will do so, and that he / she has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents.
4.12.6 The Contractor shall not be relieved of responsibility for any deviation from the requirements of the Contract Documents by the Architect's approval of Shop Drawings, Product Data or Samples under Subparagraph 2.2.7 of these General Conditions unless the Contractor has specifically informed the Architect and the State in writing of such deviation at the time of sub- mission and the Architect and the State has given written approval to the specific deviation. The Contractor shall not be relieved from responsibility for errors or omissions in the Shop Drawings, Product Data or Samples by the Architect's approval thereof.
4.12.7 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data or Samples, to revisions other than those requested by the Architect on previous submittals.
4.12.8 No portion of the Work requiring submission of a Shop Drawing, Product Data or Sample shall be commenced until the submittal has been approved by the Architect as provided in Subparagraph 2.2.7 of these General Conditions. All such portions of the Work shall be in accordance with approved submittals.
Product ACCEPTANCE Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User(s) shall have thirty (30) days from the date of delivery to accept hardware products and sixty (60) days from the date of delivery to accept all other Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty (30) day increment. Authorized User shall notify Contractor of acceptance upon successful completion of the documented installation test. Such cancellation shall not give rise to any cause of action against the Authorized User for damages, loss of profits, expenses, or other remuneration of any kind. If the Authorized User elects to provide a deficiency statement specifying how the Product fails to meet the specifications within the testing period, Contractor shall have thirty (30) days to correct the deficiency, and the Authorized User shall have an additional sixty (60) days to evaluate the Product as provided herein. If the Product does not meet the specifications at the end of the extended testing period, Authorized User, upon prior written notice to Contractor, may then reject the Product and return all defective Product to Contractor, and Contractor shall refund any monies paid by the Authorized User to Contractor therefor. Costs and liabilities associated with a failure of the Product to perform in accordance with the functionality tests or product specifications during the acceptance period shall be borne fully by Contractor to the extent that said costs or liabilities shall not have been caused by negligent or willful acts or omissions of the Authorized User’s agents or employees. Said costs shall be limited to the amounts set forth in the Limitation of Liability Clause for any liability for costs incurred at the direction or recommendation of Contractor.
Influenza Vaccine Upon recommendation of the Medical Officer of Health, all employees shall be required, on an annual basis to be vaccinated and or to take antiviral medication for influenza. If the costs of such medication are not covered by some other sources, the Employer will pay the cost for such medication. If the employee fails to take the required medication, she may be placed on an unpaid leave of absence during any influenza outbreak in the home until such time as the employee has been cleared by the public health or the Employer to return to the work environment. The only exception to this would be employees for whom taking the medication will result in the employee being physically ill to the extent that she cannot attend work. Upon written direction from the employee’s physician of such medical condition in consultation with the Employer’s physician, (if requested), the employee will be permitted to access their sick bank, if any, during any outbreak period. If there is a dispute between the physicians, the employee will be placed on unpaid leave. If the employee gets sick as a reaction to the drug and applies for WSIB the Employer will not oppose the application. If an employee is pregnant and her physician believes the pregnancy could be in jeopardy as a result of the influenza inoculation and/or the antiviral medication she shall be eligible for sick leave in circumstances where she is not allowed to attend at work as a result of an outbreak. This clause shall be interpreted in a manner consistent with the Ontario Human Rights Code.
Behaviour No obscene or insulting language or disorderly behaviour shall be permitted. This includes any form of entertainment that may be considered lewd or inappropriate for a public place or that may offend or cause embarrassment to others.
RE-WEIGHING PRODUCT Deliveries are subject to re- weighing at the point of destination by the Authorized User. If shrinkage occurs which exceeds that normally allowable in the trade, the Authorized User shall have the option to require delivery of the difference in quantity or to reduce the payment accordingly. Such option shall be exercised in writing by the Authorized User.
Competing Products The provisions of Section 21 are set forth on attached Exhibit H and are incorporated in this Section 21 by this reference.
Product Complaints Subdistributor shall promptly notify Distributor of (but in no event later than 24 hours after receipt), and provide, upon Distributor’s request, reasonable assistance to address and investigate, any complaint or adverse claim about any Product or its use of which Subdistributor becomes aware;
Product Recalls (a) If either Party reasonably decides or is required by any government authority or court of competent jurisdiction, to initiate a product recall, withdrawal or field correction with respect to, or if there is any governmental seizure of, the Product, the Party initiating or required to initiate such action will notify the other Party promptly of the details regarding such action, including providing copies of all relevant documentation concerning such action. The Parties will assist each other in investigating any such situation and all regulatory contacts that are made and all activities concerning seizure, recall, withdrawal or field correction will be jointly coordinated by HSL and LMI.
(b) If any such recall, withdrawal, field correction or seizure occurs due solely to (i) failure of any Product produced by HSL hereunder to conform to Specifications (including, without limitation, being adulterated or misbranded) or any warranty or other requirement set forth in this Agreement, (ii) the failure of HSL to comply in all material respects with any applicable law, rule, regulation, guideline, standard, court order or decree or (iii) the negligent or intentional wrongful act or omission of HSL in connection with the production of Product hereunder, then HSL shall bear the **** of any such seizure, recall, withdrawal or field correction and shall reimburse LMI for its ****, including any purchase price payments made to HSL and related taxes to the extent related to such recalled Product. To the extent any such recall, withdrawal, field correction or seizure occurs for any reason other than that set forth in the immediately preceding sentence, then LMI shall bear the **** of any such seizure, recall, withdrawal or field correction. If both HSL and LMI contribute to the cause of a seizure, recall, withdrawal or field correction, the cost and expense thereof will be shared in proportion to each Party’s contribution to the problem. For the purposes of this Agreement, the expenses of any recall, withdrawal, field correction or seizure shall include, without limitation, the out-of-pocket expenses of notification and destruction or return of the recalled Product and all other out-of-pocket costs incurred in connection with such recall but shall not include a Party’s lost profits. HSL’s reimbursement for the costs of LMI Materials related to such recall, withdrawal or field correction is limited by Section 5.6(c).
Product Recall (a) If a recall is required by applicable Law, or if Buyer or Supplier reasonably determines that a recall is advisable because the goods may create a potential safety hazard, are not in compliance with any applicable code, standard or legal requirement, or contain a defect or non-conformance with the requirements of this Order occurring or likely to occur in multiple goods, which such defects or non-conformances are substantially similar or have substantially similar causes or effects (collectively a “Serial Defect”), the parties shall promptly communicate such facts to each other. At Buyer’s request, Supplier shall promptly develop a corrective action plan satisfactory to Buyer, which shall include all actions required to recall and/or repair the goods and any actions required by applicable Law (“Corrective Action Plan”) for Buyer’s review and approval. At Buyer’s election, Xxxxx may develop the Corrective Action Plan. In no event shall Buyer and Supplier’s failure to agree on the Corrective Action Plan delay the timely notification of a potential safety hazard, non-compliance or Serial Defect to users of the goods, cause either party to be non-compliant with applicable Law or prevent Buyer from taking reasonable actions to prevent injury or damage to persons, equipment or other property. Supplier and Buyer shall cooperate with and assist each other in any corrective actions and/or filings, if applicable.
(b) To the extent a recall is required by applicable Law, or due to a potential safety hazard, non-compliance or Serial Defect, which is caused by Supplier, Supplier shall indemnify and hold Buyer harmless from all reasonable costs and expenses incurred in connection with any recall, repair, replacement or refund program, including all costs related to: (i) investigating and/or inspecting the affected goods; (ii) notifying Buyer’s customers; (iii) repairing, or where repair of the goods is impracticable or impossible, repurchasing or replacing the recalled goods; (iv) packing and shipping the recalled goods; and (v) media notification. Each party shall consult the other before making any statements to the public or a governmental agency relating to such recall, potential safety hazard, non- compliance or Serial Defect, except where such consultation would prevent timely notification required by Law.
Recall Employees who have been laid off shall be re-employed in seniority order from most senior to least senior. Employees whose positions have been eliminated through layoff or otherwise, shall be called first to fill a vacancy within their job family.
1. Prior to other employees being recalled from the recall list, an employee who displaced another employee pursuant to provisions contained in this article shall have the right to be recalled to a vacant position for which they are qualified. However, the employee who displaces another employee shall not be eligible for a position at a higher pay grade than the one he/she originally held at the time of layoff. If the employee who displaced another employee fills a vacancy in his/her original department, then the employee whom he/she displaced will automatically be recalled into the position from which he/she previously held. After this process, other employees will be recalled to fill a vacancy for which they are qualified in the same department they were assigned at the time of their layoff.
2. Employees may be offered a position outside their department/program for which they are qualified. Employees may refuse a position outside their department/program. Employees who refuse such a position a second time shall have no further rights to recall.
3. Each employee on layoff shall be required to provide the District Personnel Office, in writing, with a current address to which a letter of recall may be sent. Employees being recalled shall be notified by “Certified Mail Delivery Confirmation” and shall have five (5) working days from the date of the receipt of notice to respond to the School Board’s offer and return to work. The School Board reserves the right to temporarily assign an employee to the vacancy until the recalled employee reports to work. If the letter is mailed to the address provided by the employee and is returned to the School Board because the address is incorrect, the School Board has fulfilled the obligation of this sub-section. If the School Board does not receive an affirmative response, the employee will be moved to the bottom of the recall list. If the recall notice is returned in the allotted time, yet not marked appropriately by the Human Resources & Equity Department, the employee shall retain his/her place on the recall list for the next job opening for which he/she is qualified. However, after the third returned notice, the employee’s name will be dropped from the recall list and the School Board shall have no further obligation to the employee.
4. An employee whose contract is non-renewed due to reorganization shall be entitled to recall rights for a layoff period of eighteen (18) months. All other employees shall be entitled to recall rights for a layoff period of twelve (12) months.
5. The employee laid off pursuant to this Article shall be given the opportunity to continue insurance coverages in existing programs during the layoff provided that the premium for such insurance programs shall be paid by the employee on a monthly basis in advance of the month due.
6. No new or substitute appointments may be made while there are laid off employees available who are qualified to fill the vacancies, except that employees may be hired into positions that have been offered and refused by employees on the layoff/recall list.
