Contract Construction 6.27.1 The parties acknowledge that each party and its counsel have reviewed this CONTRACT and that the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this CONTRACT or any amendment or exhibits hereto.
PARKING RULES AND REGULATIONS The following rules and regulations govern the use of the parking facilities which serve the Building. Tenant will be bound by such rules and regulations and agrees to cause its employees, subtenants, assignees, contractors, suppliers, customers and invitees to observe the same:
1. Tenant will not permit or allow any vehicles that belong to or are controlled by Tenant or Tenant’s employees, subtenants, customers or invitees to be loaded, unloaded or parked in areas other than those designated by Landlord for such activities. No vehicles are to be left in the parking areas overnight and no vehicles are to be parked in the parking areas other than normally sized passenger automobiles, motorcycles and pick-up trucks. No extended term storage of vehicles is permitted.
2. Vehicles must be parked entirely within painted stall lines of a single parking stall.
3. All directional signs and arrows must be observed.
4. The speed limit within all parking areas shall be five (5) miles per hour.
5. Parking is prohibited: (a) in areas not striped for parking; (b) in aisles or on ramps; (c) where “no parking” signs are posted; (d) in cross-hatched areas; and (e) in such other areas as may be designated from time to time by Landlord or Landlord’s parking operator.
6. Landlord reserves the right, without cost or liability to Landlord, to tow any vehicle if such vehicle’s audio theft alarm system remains engaged for an unreasonable period of time.
7. Washing, waxing, cleaning or servicing of any vehicle in any area not specifically reserved for such purpose is prohibited.
8. Landlord may refuse to permit any person to park in the parking facilities who violates these rules with unreasonable frequency, and any violation of these rules shall subject the violator’s car to removal, at such car owner’s expense. Tenant agrees to use its best efforts to acquaint its employees, subtenants, assignees, contractors, suppliers, customers and invitees with these parking provisions, rules and regulations.
9. Parking stickers, access cards, or any other device or form of identification supplied by Landlord as a condition of use of the parking facilities shall remain the property of Landlord. Parking identification devices, if utilized by Landlord, must be displayed as requested and may not be mutilated in any manner. The serial number of the parking identification device may not be obliterated. Parking identification devices, if any, are not transferable and any device in the possession of an unauthorized holder will be void. Landlord reserves the right to refuse the sale of monthly stickers or other parking identification devices to Tenant or any of its agents, employees or representatives who willfully refuse to comply with these rules and regulations and all unposted city, state or federal ordinances, laws or agreements.
10. Loss or theft of parking identification devices or access cards must be reported to the management office in the Development immediately, and a lost or stolen report must be filed by the Tenant or user of such parking identification device or access card at the time. Landlord has the right to exclude any vehicle from the parking facilities that does not have a parking identification device or valid access card. Any parking identification device or access card which is reported lost or stolen and which is subsequently found in the possession of an unauthorized person will be confiscated and the illegal holder will be subject to prosecution.
11. All damage or loss claimed to be the responsibility of Landlord must be reported, itemized in writing and delivered to the management office located within the Development within ten (10) business days after any claimed damage or loss occurs. Any claim not so made is waived. Landlord is not responsible for damage by water or fire, or for the acts or omissions of others, or for articles left in vehicles. In any event, the total liability of Landlord, if any, is limited to Two Hundred Fifty Dollars ($250.00) for all damages or loss to any car. Landlord is not responsible for loss of use.
Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the internal laws of the State of New York.
Compliance with Rules and Regulations PFPC undertakes to comply with all applicable requirements of the Securities Laws and any laws, rules and regulations of governmental authorities having jurisdiction with respect to the duties to be performed by PFPC hereunder. Except as specifically set forth herein, PFPC assumes no responsibility for such compliance by the Fund or any other entity.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
COMPLIANCE WITH GOVERNMENTAL RULES AND REGULATIONS; RECORDS The Trust assumes full responsibility for its compliance with all securities, tax, commodities and other laws, rules and regulations applicable to it.
Compliance with Governmental Rules and Regulations Except as otherwise provided in the Agreement and except for the accuracy of information furnished to the Fund by Price Services, each Fund assumes full responsibility for the preparation, contents and distribution of its prospectuses and compliance with all applicable requirements of the ’40 Act, the ‘34 Act, the ‘33 Act, and any other laws, rules and regulations of governmental authorities having jurisdiction over the Fund. Price Services shall be responsible for complying with all laws, rules and regulations of governmental authorities having jurisdiction over transfer agents and their activities and cooperating with respect to examinations and requests from such governmental authorities.
Compliance with OFAC Rules and Regulations None of the Credit Parties or their Subsidiaries or their respective Affiliates (a) is a Sanctioned Person, (b) has more than 15% of its assets in Sanctioned Countries, or (c) derives more than 15% of its operating income from investments in, or transactions with Sanctioned Persons or Sanctioned Countries. No part of the proceeds of any Extension of Credit hereunder will be used directly or indirectly to fund any operations in, finance any investments or activities in or make any payments to, a Sanctioned Person or a Sanctioned Country.
SUPERVISION AND CONSTRUCTION PROCEDURES 4.3.1 The Contractor shall supervise and direct the Work, using his / her best skill and attention. The Contractor shall be solely responsible for all construction means, methods, techniques, sequences and procedures and for coordinating all portions of the Work under the Contract. All aspects of the Project shall be subject to the inspection and approval of the State. Contractor guarantees to repair, replace, re-execute or otherwise correct any defect in workmanship, materials, or the like that fails to conform to the requirements of this Contract or that appears during the progress of the Work or within one year of final acceptance by the State.
4.3.2 The Contractor shall be responsible to the State for the acts and omissions of his / her employees, Subcontractors and their agents and employees, and other persons performing any of the Work under a contract with the Contractor.
4.3.3 The Contractor shall not be relieved from his / her obligations to perform the Work in accordance with the Contract Documents either by the activities or duties of the Architect in his / her administration of the Contract, or by inspections, tests or approvals required or performed under Paragraph 7.7 by persons other than the Contractor.
4.3.4 The Contractor shall acquaint himself (herself / itself) with the limits of the property or right- of-way of the State and shall not trespass on other property. The Contractor shall adequately protect the project, adjacent property and the public, and shall be responsible for any damage or injury due to the Contractor’s act or neglect, and shall save the State harmless in respect thereto.
4.3.5 All work shall be done in such a manner as not to interfere with the State’s operating functions. Contractor and his employees shall familiarize themselves and comply with all rules and regulations applicable to the project.
4.3.6 The Contractor shall keep the premises free from liens arising out of or from the Project. Contractor shall obtain and submit waivers of liens with a request for a progress or final payment.
BUILDING RULES AND REGULATIONS The following rules and regulations shall apply, where applicable, to the Premises, the Building, the parking facilities (if any), the Property and the appurtenances. In the event of a conflict between the following rules and regulations and the remainder of the terms of the Lease, the remainder of the terms of the Lease shall control. Capitalized terms have the same meaning as defined in the Lease.
