Particular Methods of Procurement of Goods Works and Services (other than Consultants’ Services)
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Particular Methods of Procurement of Goods and Works International Competitive Bidding. Goods and works shall be procured under contracts awarded on the basis of International Competitive Bidding.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Wage Schedule The pay rate (including increments and stated extras) as agreed to and hereinafter in this Schedule provided, shall be in effect during the term of the Agreement, from April 1, 2019 to March 31, 2022.
Wage Schedules The Parties shall, upon completing a wage adjustment calculation, forthwith prepare, publish, post and distribute a wage schedule resulting therefrom. The final determination of the wage schedules shall be issued no later than the 7th day of March or September, for the May and November adjustments, respectively.
Choice of Law clauses for TIPS Members If the vendor is awarded a contract with TIPS under this solicitation, the vendor agrees to make any Choice of Law clauses in any contract or agreement entered into between the awarded vendor and with a TIPS member entity to read as follows: "Choice of law shall be the laws of the state where the customer resides" or words to that effect.
Choice of Law clauses with TIPS Members If the vendor is awarded a contract with TIPS under this solicitation, the vendor agrees to make any Choice of Law clauses in any contract or agreement entered into between the awarded vendor and with a TIPS member entity to read as follows: "Choice of law shall be the laws of the state where the customer resides" or words to that effect.
Delivery Schedule The Goods specified in the List of Goods are required to be delivered within the acceptable time range (after the earliest and before the final date, both dates inclusive) specified in Section V, Schedule of Requirements. No credit will be given to deliveries before the earliest date, and Tenders offering delivery after the final date shall be treated as non-responsive. Within this acceptable period, an adjustment of [insert the adjustment factor], will be added, for evaluation purposes only, to the Tender price of Tenders offering deliveries later than the “Earliest Delivery Date” specified in Section V, Schedule of Requirements.
Time Schedule 4.1. A project schedule is included in Appendix A. 4.2. Any delay of services or change in sequence of tasks must be approved in writing by Delaware. 4.3. In the event that Vendor fails to complete the project or any phase thereof within the time specified in the Contract, or with such additional time as may be granted in writing by Delaware, or fails to prosecute the work, or any separable part thereof, with such diligence as will insure its completion within the time specified in this Agreement or any extensions thereof, Delaware shall suspend the payments scheduled as set forth in Appendix A.
