Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
SCHEDULE OF WORK FIRST PARTY’S proposed schedule for the various services required will be set forth in Exhibit A-1. A4. CHANGES IN WORK -- EXTRA WORK In addition to services described in Section A1, the parties may from time to time agree in writing that FIRST PARTY, for additional compensation, shall perform additional services including but not limited to: • Change in the services because of changes in scope of the work. • Additional tasks not specified herein as required by the CITY. The CITY and FIRST PARTY shall agree in writing to any changes in compensation and/or changes in FIRST PARTY’s services before the commencement of any work. If FIRST PARTY deems work he/she has been directed to perform is beyond the scope of this agreement and constitutes extra work, FIRST PARTY shall immediately inform the CITY in writing of the fact. The CITY shall make a determination as to whether such work is in fact beyond the scope of this agreement and constitutes extra work. In the event that the CITY determines that such work does constitute extra work, it shall provide compensation to the FIRST PARTY in accordance with an agreed cost that is fair and equitable. This cost will be mutually agreed upon by the CITY and FIRST PARTY. A supplemental agreement providing for such compensation for extra work shall be negotiated between the CITY and the FIRST PARTY. Such supplemental agreement shall be executed by the FIRST PARTY and may be approved by the City Manager upon recommendation of the Department Head.
PROGRESS SCHEDULE The Contractor, within ten (10) working days of receiving notice of the award of the contract, shall prepare and submit for the State's and Architect's information an estimated progress schedule for the Work. The progress schedule shall be related to the entire Project to the extent required by the Contract Documents, and shall provide for expeditious and practicable execution of the Work.
Construction Progress Schedule; Overall Project Schedule The Contractor shall submit for review by the Design Professional and approval by the Owner a Construction Progress Schedule based upon the Design Professional’s Preliminary Design and Construction Schedule and prepared using a CPM (Critical Path Method) process within sixty days after the Effective Date of the Contract, utilizing a full-featured software package in a form satisfactory to the Design Professional and Owner, showing the dates for commencement and completion of the Work required by the Contract Documents, including coordination of mechanical, plumbing, and electrical disciplines, as well as coordination of the various subdivisions of the Work within the Contract. Milestones must be clearly indicated and sequentially organized to identify the critical path of the Project. The Construction Schedule will be developed to represent the CSI specification divisions. It shall have the minimum number of activities required to adequately represent to the Owner the complete scope of Work and define the Project’s (and each Phase’s if phased) critical path and associated activities. The format of the Construction Progress Schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, inspections for Material Completion and Occupancy Date, and Final Completion Date. The Contractor shall submit, along with the Construction Progress Schedule, the Submittal Schedule for approval by the Design Professional, correlating the associated approval dates for the documents with the Construction Progress Schedule. Upon recommendation by the Design Professional and approval by the Owner, the Construction Progress Schedule shall become the Overall Project Schedule, which shall be utilized by the Design Professional, Owner and Contractor. The Contractor must provide the Design Professional and the Owner with monthly updates of the Overall Project Schedule indicating completed activities and any changes in sequencing or activity durations, including approved change orders. See also Article 3.3.5.
Sentencing Guidelines Calculations 8. Defendant understands that in imposing sentence the Court will be guided by the United States Sentencing Guidelines. Defendant understands that the Sentencing Guidelines are advisory, not mandatory, but that the Court must consider the Guidelines in determining a reasonable sentence.
CONTRACT EXHIBIT I PREFERRED PRICING AFFIDAVIT This preferred-pricing affidavit is entered into in accordance with section 216.0113, F.S., and as required by Contract No. 80101507-21-STC-ITSA (“Contract”) between (“Contractor”) and the Department of Management Services. As the person authorized by Contractor to sign this affidavit, I attest that the Contractor is in full compliance with the preferred-pricing clause of the Contract. Contractor’s Name: By: Signature Printed Name/Title Date: STATE OF COUNTY OF Sworn to (or affirmed) and subscribed before me this day of , by . Signature of Notary Vendor Name: FEIN# Vendor’s Authorized Representative Name and Title: Address: City, State, and Zip code: Phone Number: ( ) - E-mail: CORPORATE SEAL (IF APPLICABLE) (Print, Type, or Stamp Commissioned Name of Notary Public) [Check One] Personally Known OR Produced the following I.D.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.
Drug-Free Workplace Certification As required by Executive Order No. 90-5 dated April 12, 1990, issued by the Governor of Indiana, the Contractor hereby covenants and agrees to make a good faith effort to provide and maintain a drug-free workplace. The Contractor will give written notice to the State within ten (10) days after receiving actual notice that the Contractor, or an employee of the Contractor in the State of Indiana, has been convicted of a criminal drug violation occurring in the workplace. False certification or violation of this certification may result in sanctions including, but not limited to, suspension of contract payments, termination of this Contract and/or debarment of contracting opportunities with the State for up to three (3) years. In addition to the provisions of the above paragraph, if the total amount set forth in this Contract is in excess of $25,000.00, the Contractor certifies and agrees that it will provide a drug-free workplace by:
Construction Progress Schedule A schedule indicating proposed activity sequences and durations, milestone dates for receipt and approval of pertinent information, preparation, submittal, and processing of Shop Drawings and Samples, delivery of materials or equipment requiring long-lead time procurement, and proposed date(s) of Material Completion and Occupancy and Final Completion. The schedule will be developed to represent the sixteen or seventeen CSI Specification Divisions. It shall have a minimum number of activities as required to adequately represent to Owner the complete scope of work and define the Project’s critical path and associated activities. If the Project is to be phased, then each individual Phase should be identified from start through completion of the overall Project and should be individually scheduled and described, including any Owner’s occupancy requirements and showing portions of the Project having occupancy priority. The format of the schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, Material Completion and Occupancy Date, final inspection dates, Punchlist, and Final Completion date.