Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
Contract Renegotiation, Suspension, or Termination Due to Change in Funding If the funds DSHS relied upon to establish this Contract or Program Agreement are withdrawn, reduced or limited, or if additional or modified conditions are placed on such funding, after the effective date of this contract but prior to the normal completion of this Contract or Program Agreement:
a. At DSHS’s discretion, the Contract or Program Agreement may be renegotiated under the revised funding conditions.
b. At DSHS’s discretion, DSHS may give notice to Contractor to suspend performance when DSHS determines that there is reasonable likelihood that the funding insufficiency may be resolved in a timeframe that would allow Contractor’s performance to be resumed prior to the normal completion date of this contract.
(1) During the period of suspension of performance, each party will inform the other of any conditions that may reasonably affect the potential for resumption of performance.
(2) When DSHS determines that the funding insufficiency is resolved, it will give Contractor written notice to resume performance. Upon the receipt of this notice, Contractor will provide written notice to DSHS informing DSHS whether it can resume performance and, if so, the date of resumption. For purposes of this subsubsection, “written notice” may include email.
(3) If the Contractor’s proposed resumption date is not acceptable to DSHS and an acceptable date cannot be negotiated, DSHS may terminate the contract by giving written notice to Contractor. The parties agree that the Contract will be terminated retroactive to the date of the notice of suspension. DSHS shall be liable only for payment in accordance with the terms of this Contract for services rendered prior to the retroactive date of termination.
c. DSHS may immediately terminate this Contract by providing written notice to the Contractor. The termination shall be effective on the date specified in the termination notice. DSHS shall be liable only for payment in accordance with the terms of this Contract for services rendered prior to the effective date of termination. No penalty shall accrue to DSHS in the event the termination option in this section is exercised.
Termination for Market Change (a) In the event of delay or interruption under B8.33, exceeding 90 days, and Contract has not been modified to include replacement timber, this contract may be terminated upon election and written notice by Purchaser, if (i) a rate redetermination for market change under B3.33 shows that the appraised weighted average Indicated Advertised Rate of all Included Timber remaining immediately prior to the delay or interruption has been reduced through a market change by an amount equal to or more than the the weighted average Current Contract Rate, or (ii) the appraised value of the remaining timber is insufficient to cover the adjusted base rates as determined under B3.33.
Termination Without Just Cause In the case of a termination of Executive’s employment hereunder Without Just Cause in accordance with Section 1.6.6, Executive shall be entitled to the following in lieu of any other compensation or benefits (under Section 1.4 of this Agreement or otherwise) from Employer:
(i) Executive shall receive Termination Compensation each month during the Compensation Continuance Period, subject, however, to Executive’s compliance with Executive’s Section 2 covenants (including, without limitation, compliance with the noncompetition and nonsolicitation covenants of Section 2) for a one (1) year period following Executive’s Termination Date.
(ii) Employer shall use their best efforts to accelerate vesting of any unvested benefits of Executive under any employee stock-based or other benefit plan or arrangement to the extent permitted by Code Section 409A or other applicable law and the terms of such plan or arrangement.
(iii) Employer shall make available to Executive, at Employer’s cost, outplacement services by such entity or person as shall be designated by Employer, with the cost to Employer of such outplacement services not to exceed Twenty Thousand Dollars ($20,000).
(iv) During the Compensation Continuance Period, Executive shall either continue to participate (treating Executive as an “active employee” of Employer for this purpose) in the same group hospitalization plan, health care plan, dental care plan, life or other insurance or death benefit plan, and any other present or future similar group employee benefit plan or program for which officers of Employer generally are eligible, on the same terms as were in effect prior to Executive’s Termination Date, or, to the extent such participation is not permitted by any group plan insurer, under comparable individual plans and coverage (to the extent commercially available). The Termination Compensation and other benefits provided for in this Section 1.7.3 shall be paid by Employer in accordance with the standard payroll practices and procedures in effect prior to Executive’s Termination Date. If Executive breaches Executive’s obligations under Section 1.7.3 or Section 2 of this Agreement, Executive shall not be entitled to receive any further Termination Compensation or benefits pursuant to this Section 1.7.3 from and after the date of such breach.
Independence from Material Breach Determination Except as set forth in Section X.D.1.c, these provisions for payment of Stipulated Penalties shall not affect or otherwise set a standard for OIG’s decision that Xxxxx has materially breached this IA, which decision shall be made at OIG’s discretion and shall be governed by the provisions in Section X.D, below.
Termination for Force Majeure 15.5.1. The License Agreement may be terminated for Force Majeure Reasons as specified in Article -14.
Excusable Delay The parties shall not be obligated to perform and shall not be deemed to be in default hereunder, if the performance of a non-monetary obligation required hereunder is prevented by the occurrence of any of the following, other than as the result of the financial inability of the party obligated to perform: acts of God, strikes, lock-outs, other industrial disturbances, acts of a public enemy, war or war-like action (whether actual, impending or expected and whether de jure or de facto), acts of terrorists, arrest or other restraint of government (civil or military), blockades, insurrections, riots, epidemics, landslides, lightning, earthquakes, fires, hurricanes, storms, floods, washouts, sink holes, civil disturbances, explosions, breakage or accident to equipment or machinery, confiscation or seizure by any government or public authority, nuclear reaction or radiation, radioactive contamination or other causes, whether of the kind herein enumerated or otherwise, that are not reasonably within the control of the party claiming the right to delay performance on account of such occurrence.
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Termination as a Result of Death or Disability The Executive’s employment with the Company shall terminate automatically upon the Executive’s death during the Employment Term. If the Disability of the Executive has occurred during the Employment Term (pursuant to the definition of “Disability” set forth below), the Company may give to the Executive written notice of its intention to terminate the Executive’s employment. In such event, the Executive’s employment with the Company shall terminate effective on the 30th day after receipt of such notice by the Company (the “Disability Effective Date”), provided that, within the 30 days after receipt of notice, the Executive shall not have returned to substantial performance of the Executive’s duties. For purposes of this Agreement, “Disability” shall mean the absence of the Executive from the Executive’s duties with the Company for 120 consecutive days, or a total of 180 days in any 12-month period, as a result of incapacity due to mental or physical illness which is determined to be total and permanent by a physician jointly selected by the Company and the Executive or the Executive’s legal representative, or, if the parties cannot agree on the selection of such physician then each shall choose a physician and the two physicians shall jointly select a physician to make such binding determination.
