Scope Change Due to Discovery of Pre-Existing Hazardous Substances on the VDOT Existing ROW Sample Clauses

Scope Change Due to Discovery of Pre-Existing Hazardous Substances on the VDOT Existing ROW. To the extent a discovery of the Pre-Existing Hazardous Substances on the VDOT Existing ROW causes a material delay in Contractor’s performance of the Work that Contractor cannot, in the absence of incurring material cost or impacting the critical path, overcome the effect thereof, Contractor shall be entitled to claim a Scope Change Order in accordance with the procedures of this Article 12 to appropriately adjust one or more of the Guaranteed Substantial Completion Date, the Project Schedule, the Payment and Values Schedule and the Contract Sum. The Contract Sum shall be adjusted only in an amount necessary to reimburse Contractor for all reasonable costs and expenses incurred to investigate, mitigate or avoid the effects of the discovery of the Pre-Existing Hazardous Substances on the VDOT Existing ROW. Concessionaire’s obligation to pay Contractor any increase on the Contract Sum as a result of such a Scope Change Order shall be subject to Concessionaire’s receipt of necessary funds in respect thereof from VDOT under Section 7.09(a) of the Comprehensive Agreement. The provisions of Section 12.15 hereof shall apply in the event Contractor and Concessionaire cannot agree on the amount or other terms of any claim to be made against VDOT pursuant to the Comprehensive Agreement in respect of such a Scope Change Order.
AutoNDA by SimpleDocs

Related to Scope Change Due to Discovery of Pre-Existing Hazardous Substances on the VDOT Existing ROW

  • Obligation to Notify Owner of Existing Hazardous Materials The Contractor shall immediately notify the Owner and the Design Professional, both orally and in writing, of the presence and location of any physical evidence of, or information regarding the presence of Hazardous Materials at the Site of which it becomes aware. If the Contractor encounters Hazardous Materials on the Site the Contractor shall (i) immediately stop performance of Work or that portion of the Work affected by or affecting such Hazardous Materials; (ii) secure the contaminated area against intrusion; (iii) not disturb or remove the Hazardous Materials; (iv) not proceed, or allow any subcontractor or supplier to proceed, with any Work or other activities in the area affected by such Hazardous Materials until such materials have been properly remediated and until directed in writing to do so by the Owner; and, (v) take any other steps necessary to protect life and health and the surrounding environment. The Contractor shall be entitled to adjustment of the Contract Time and the Contract Sum pursuant to Section 5, Part 2 of these General Conditions in order to compensate for the impact of any required demolition, re-work, shutdown, delay, protection of work, disruption, and start-up resulting from the encountering of such Hazardous Materials on the Site for which the Contractor is not responsible.

  • No Storing Hazardous Articles Not to keep or store any offensive, combustible, obnoxious, hazardous or dangerous articles in the said Apartment, the Common Areas, and the Building.

  • Environmental Inspection at End of Agreement Term A. At Authority’s discretion, at least one hundred and twenty (120) days before the expiration or early termination of the Term as provided herein, Company will conduct an environmental inspection and examination of the Company Premises. At its discretion, Authority may complete environmental reviews to determine if recognized environmental conditions exist that could warrant soil and groundwater sampling. If warranted by the findings of Company or Authority’s inspection or if requested by Authority, a compliance audit or site assessment will be performed within the aforementioned time period by a qualified professional acceptable to Authority who will report the findings to Authority. The cost for professional consulting or engineering services required for such audit will be at the expense of Company. If a site assessment is conducted, Company agrees to pay all associated laboratory and testing fees incurred to test and analyze samples collected during the site assessment process. The Authority may also choose to conduct the compliance audit or site assessment. If the results of the assessment indicate that the Company Premises have been impacted by the release of Hazardous Substances, Company will immediately take such action as is necessary and will provide a substantial guaranty in a form and content acceptable to Authority that Company will clean up the contamination at its own expense, at no expense to Authority, and in accordance with Applicable Laws to the extent that it is obligated to do so by virtue of the foregoing provisions of this Article.

  • Prohibition Against Selecting and Installing Products Containing Hazardous Materials The Contractor shall not select, install or otherwise incorporate any products or materials containing Hazardous Materials within the boundaries of the Site. Should the Contractor or any Subcontractors have knowledge that, or believe that, an item, component, material, substance, or accessory within a product or assembly selected by the Contractor or any Subcontractor may contain Hazardous Materials it is the Contractor’s responsibility to secure a written certification from the manufacturer of any suspected material which identifies the specific Hazardous Material(s) contained, together with the Material Safety Data Sheets (MSDS) for such materials which shall be submitted to the Owner and Design Professional.

  • How Do I Get More Information? For more information, including the full Notice, Claim Forms and Settlement Agreement go to xxx.xxxxxxxxxxxxxxxxxxxx.xxx, contact the settlement administrator at 0-000-000-0000, or call Class Counsel at 1-866-354-3015. Exhibit E UNITED STATES DISTRICT COURT FOR THE SOUTHERN DISTRICT OF FLORIDA Xxxxx v. AvMed, Inc., Case No. 10-cv-24513 If You Paid for or Received Insurance from AvMed, Inc. at Any Time Through December of 2009, You May Be Part of a Class Action Settlement. IMPORTANT: PLEASE READ THIS NOTICE CAREFULLY. THIS NOTICE RELATES TO THE PENDENCY OF A CLASS ACTION LAWSUIT AND, IF YOU ARE A MEMBER OF THE SETTLEMENT CLASSES, CONTAINS IMPORTANT INFORMATION ABOUT YOUR RIGHTS TO MAKE A CLAIM UNDER THE SETTLEMENT OR TO OBJECT TO THE SETTLEMENT (A federal court authorized this notice. It is not a solicitation from a lawyer.) Your legal rights are affected whether or not you act. Please read this notice carefully. YOUR LEGAL RIGHTS AND OPTIONS IN THIS SETTLEMENT SUBMIT A CLAIM FORM This is the only way to receive a payment. EXCLUDE YOURSELF You will receive no benefits, but you will retain any rights you currently have to xxx the Defendant about the claims in this case. OBJECT Write to the Court explaining why you don’t like the Settlement. GO TO THE HEARING Ask to speak in Court about your opinion of the Settlement. DO NOTHING You won’t get a share of the Settlement benefits and will give up your rights to xxx the Defendant about the claims in this case. These rights and options – and the deadlines to exercise them – are explained in this Notice. QUESTIONS? CALL 0-000-000-0000 TOLL FREE, OR VISIT XXX.XXXXXXXXXXXXXXXXXXXX.XXX PARA UNA NOTIFICACIÓN EN ESPAÑOL, LLAMAR O VISITAR NUESTRO WEBSITE BASIC INFORMATION

  • Modifications and Updates to the Wire Center List and Subsequent Transition Periods 2.1.4.12.1 In the event BellSouth identifies additional wire centers that meet the criteria set forth in Section 2.1.4.5, but that were not included in the Initial Wire Center List, BellSouth shall include such additional wire centers in a carrier notification letter (CNL). Each such list of additional wire centers shall be considered a “Subsequent Wire Center List”.

  • ECR Number Environmental Commitment Record Requirements Description of ADOT Responsibilities TMP-3 The following measures will be implemented for the Selected Alternative: • All equipment exhaust systems will be in good working order. Properly designed engine enclosures and intake silencers will be used. • Equipment will be maintained on a regular basis. New equipment will be subject to new product emission standards. • Stationary equipment will be located as far away from sensitive receivers as possible. • Construction-related noise generators will be shielded from noise receivers (e.g., use temporary enclosures to shield generators or crushers, take advantage of site conditions to provide topographic separation). • Construction alerts will be distributed to keep the public informed of construction activities, and a toll-free number for construction-related complaints will be provided. • During the design phase, hours of operation will be evaluated to minimize disruptions during construction. ADOT to oversee for compliance TMP-4 Congestion from construction-related traffic will create temporary impacts in the project vicinity. The magnitude of these impacts will vary depending on the location of the sources of the fill material and of the disposition sites for surplus material, the land uses along the routes, the duration of hauling operations, staging locations, and the construction phasing. To identify acceptable routes and times of operation, ADOT, or its representative, will prepare an agreement with local agencies regarding hauling of construction materials on public streets. ADOT to oversee for compliance TP Attachment 000-0 Xxxxx Xxxxxxxx Xxxxxxx Project Record of Decision (ROD) Developer’s Environmental Commitment Requirements The following table includes the Project-specific environmental commitments as written in the ROD, with minor modifications for clarification purposes. As it relates to these Technical Provisions, references to freeway, project, South Mountain Freeway, proposed action, proposed freeway, and Selected Alternative mean the Project, and references to contractor mean Developer. Developer shall comply with and perform all of the contractor and ADOT requirements, including the ADOT obligations, commitments, and responsibilities, identified in the following table, except to the extent of those requirements that are specifically identified in the third column, entitled “Description of ADOT Responsibilities,” which are not delegated to Developer.

  • DISCOVERY OF HAZARDOUS MATERIALS If, during the performance of the Work, Contractor or Contractor’s subcontractor(s) encounter material believed to be asbestos, polychlorinated biphenyl (PCB), or any other identified or non-identified potentially hazardous material (which has not been rendered harmless and labeled as such), Contractor and Contractor’s subcontractor(s) shall immediately stop work in the area affected and report the condition, in writing, to District. The Work in the affected area shall not continue or be resumed except by written direction of District and by agreement by Contractor.

  • Certification of Funds; Budget and Fiscal Provisions; Termination in the Event of Non-Appropriation This Agreement is subject to the budget and fiscal provisions of the City’s Charter. Charges will accrue only after prior written authorization certified by the Controller, and the amount of City’s obligation hereunder shall not at any time exceed the amount certified for the purpose and period stated in such advance authorization. This Agreement will terminate without penalty, liability or expense of any kind to City at the end of any fiscal year if funds are not appropriated for the next succeeding fiscal year. If funds are appropriated for a portion of the fiscal year, this Agreement will terminate, without penalty, liability or expense of any kind at the end of the term for which funds are appropriated. City has no obligation to make appropriations for this Agreement in lieu of appropriations for new or other agreements. City budget decisions are subject to the discretion of the Mayor and the Board of Supervisors. Contractor’s assumption of risk of possible non-appropriation is part of the consideration for this Agreement. THIS SECTION CONTROLS AGAINST ANY AND ALL OTHER PROVISIONS OF THIS AGREEMENT.

  • No Restriction on Existing Examination and Investigative Authority That this Agreement shall in no way preclude any State Mortgage Regulator from exercising its examination or investigative authority authorized under the laws of the corresponding Participating State in the instance a determination is made wherein Respondent is found not to be adhering to the requirements of the Agreement, other than inadvertent and isolated errors that are promptly corrected by Respondent, or involving any unrelated matter not subject to the terms of this Agreement. The Parties agree that the failure of Respondent to comply with any term or condition of this Agreement with respect to a particular State shall be treated as a violation of an Order of the State and may be enforced as such. Moreover, Respondent acknowledges and agrees that this Agreement is only binding on the State Mortgage Regulators and not any other Local, State or Federal Agency, Department or Office.

Time is Money Join Law Insider Premium to draft better contracts faster.