Scope Change Due to Injunction (ARCA Delay Event) Sample Clauses

Scope Change Due to Injunction (ARCA Delay Event). To the extent an ARCA Delay Event described in clause (d) of the definition thereof causes a material delay in Contractor’s performance of the Work that Contractor cannot, in the absence of incurring material cost or impacting the critical path, overcome the effect thereof, Contractor shall be entitled to claim a Scope Change Order in accordance with the procedures of this Article 12 to appropriately adjust one or more of the Project Schedule, the Payment and Values Schedule and the Guaranteed Substantial Completion Date (but not the Contract Sum). Concessionaire’s obligation to extend the Guaranteed Completion Date as a result of such a Scope Change Order shall be subject to Concessionaire’s receipt of approval thereof from VDOT under the Comprehensive Agreement. Concessionaire shall proceed in accordance with Section 12.15(c) hereof to obtain such approval under the Comprehensive Agreement. The provisions of Section
Sample 1
AutoNDA by SimpleDocs

Related to Scope Change Due to Injunction (ARCA Delay Event)

  • Authority Event of Default Any of the following events shall constitute an event of default by the Authority ("Authority Event of Default”), when not caused by a Developer Event of Default:

  • Contract Renegotiation, Suspension, or Termination Due to Change in Funding If the funds DSHS relied upon to establish this Contract or Program Agreement are withdrawn, reduced or limited, or if additional or modified conditions are placed on such funding, after the effective date of this contract but prior to the normal completion of this Contract or Program Agreement:

  • Termination due to Event of Default (a) Termination due to Parties Event of Default

  • TERMINATION DUE TO CHANGE IN FUNDING ‌ 35 In the event funding from HCA, MCO, State, Federal, or other sources is withdrawn, reduced, or limited 36 in any way after the effective date of this Contract and prior to its normal completion, either party may 37 terminate this Contract subject to re-negotiations.

  • Reports of unusual occurrence The Contractor shall, during the Maintenance Period, prior to the close of each day, send to the Authority and the Authority’s Engineer, by facsimile or e- mail, a report stating accidents and unusual occurrences on the Project Highway relating to the safety and security of the Users and Project Highway. A monthly summary of such reports shall also be sent within 3 (three) business days of the closing of month. For the purposes of this Clause 15.4, accidents and unusual occurrences on the Project Highway shall include:

  • REGULATORY EVENT If a Regulatory Event occurs, the Parties shall use their best efforts to reform this ESA to give effect to the original intent of the Parties. If a Regulatory Event affects Competitive Supplier and Competitive Supplier incurs excess costs as a result thereof, such amount shall be allocated to and collected from Participating Consumers on a per kWh basis through applicable monthly invoice(s).

  • Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.

  • Consequences of Events of Default and Corrective Action If an Event of Default occurs, the Province may, at any time, take one or more of the following actions:

  • Termination Due To Lack Of Funding Appropriation If, in the judgment of the Director of Accounts and Reports, Department of Administration, sufficient funds are not appropriated to continue the function performed in this agreement and for the payment of the charges hereunder, State may terminate this agreement at the end of its current fiscal year. State agrees to give written notice of termination to contractor at least 30 days prior to the end of its current fiscal year, and shall give such notice for a greater period prior to the end of such fiscal year as may be provided in this contract, except that such notice shall not be required prior to 90 days before the end of such fiscal year. Contractor shall have the right, at the end of such fiscal year, to take possession of any equipment provided State under the contract. State will pay to the contractor all regular contractual payments incurred through the end of such fiscal year, plus contractual charges incidental to the return of any such equipment. Upon termination of the agreement by State, title to any such equipment shall revert to contractor at the end of the State's current fiscal year. The termination of the contract pursuant to this paragraph shall not cause any penalty to be charged to the agency or the contractor.

  • Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!