Scope of the Services UNOPS intends to retain the Contractor for the implementation of the Services, and the Contractor intends to provide the Services. The Contractor has represented to UNOPS that it has the appropriate experience, expertise, licences, and resources to undertake the Services and has agreed to undertake the Services in accordance with the Contract. In reliance on the Contractor’s representations UNOPS has entered into the Contract. The Contract sets out the terms and conditions upon which the Contractor will undertake the Services.
SCOPE OF THE WORK The Contractor shall furnish all the materials, perform all of the Work, and do all things required by the Contract Documents.
Scope of the Project Under this Agreement, the scope of the Project (the “Scope of the Project”) shall mean and include:
(a) construction of the Project Highway on the Site set forth in Schedule- A and as specified in Schedule-B together with provision of Project Facilities as specified in Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D;
(b) maintenance of the Project Highway in accordance with the provisions of this Agreement and in conformity with the requirements set forth in Schedule-E; and
(c) performance and fulfilment of all other obligations of the Contractor in accordance with the provisions of this Agreement and matters incidental thereto or necessary for the performance of any or all of the obligations of the Contractor under this Agreement.
Scope of the Agreement This Agreement shall apply to all investments made by investors of either Contracting Party in the territory of the other Contracting Party, accepted as such in accordance with its laws and regulations, whether made before or after the coming into force of this Agreement.
Procurement of the Site (i) The Authority Representative, the Contractor and Authority’s Engineer shall, within 10 (ten) days of the date of this Agreement, inspect the Site and prepare a detailed memorandum containing an inventory of the Site including the vacant and unencumbered land, buildings, structures, road works, trees and any other immovable property on or attached to the Site (hereinafter referred to as the “Handover Memorandum”). Subject to the provisions of Clause 8.2 (iii), the Handover Memorandum shall have appended thereto an appendix (the “Appendix”) specifying in reasonable detail those parts of the Site to which vacant access and Right of Way has not been given to the Contractor along with details of hindrances in the Construction Zone. For sake of clarity the Handover Memorandum shall clearly specify the parts of Site where work can be executed. Signing of the Handover Memorandum, in three counterparts (each of which shall constitute an original), by the authorized representatives of the Authority, Contractor and Authority’s Engineer shall be deemed to constitute a valid evidence of giving the Right of Way to the Contractor for discharging its obligations under and in accordance with the provisions of this Agreement and for no other purpose whatsoever.
(ii) Whenever the Authority is ready to hand over any part or parts of the Site included in the Appendix, it shall inform the Contractor, by notice, of the proposed date and time such of hand over. The Authority Representative and the Contractor shall, on the date so notified, inspect the specified parts of the Site, and prepare a memorandum containing an inventory of the vacant and unencumbered land, buildings, structures, road works, trees and any other immovable property on or attached to the Site so handed over. The signing of the memorandum, in three (3) counterparts (each of which shall constitute an original), by the authorised representatives of the Parties shall be deemed to constitute a valid evidence of giving the relevant Right of Way to the Contractor. If the contractor fails to join for site inspection or disputes the parts of the site available for work, the Authority’s Engineer shall decide the parts of the site where work can be executed and notify to both the parties within 3 days of the proposed date of inspection. The parties agree that such notification of the Authority’s Engineer as mentioned hereinabove shall be final and binding on the parties.
(iii) The Authority shall provide the Right of Way to the Contractor in respect of all land included in the Appendix by the date specified in Schedule-A for those parts of the Site referred to therein, and in the event of delay for any reason other than Force Majeure or breach of this Agreement by the Contractor, it shall pay to the Contractor, Damages in a sum calculated in accordance with Clause 8.3. The Contractor agrees that it shall not be entitled to claim any other damages on account of any such delay by the Authority.
(iv) Notwithstanding anything to the contrary contained in this Clause 8.2, the Authority shall specify the parts of the Site, if any, for which Right of Way shall be provided to the Contractor on the dates specified in Schedule-A. Such parts shall also be included in the Appendix prepared in pursuance of Clause 8.2 (i).
(v) The Authority further acknowledges and agrees that prior to the Appointed Date, it shall have procured issuance of the statutory notification under Applicable Laws for vesting of all the land comprising the Project in the Authority and has taken possession of area for Construction Zone for at least 90% (ninety per cent) of the total length of the Project Highway. The Parties also acknowledge and agree that the conditions specified in this Clause 8.2 (iii) shall not be modified or waived by either Party.
(vi) For the avoidance of doubt, the Parties expressly agree that the Appendix shall in no event contain sections of the Project Highway the cumulative length of which exceeds 10% (ten percent) of the total length of the Project Highway.
(vii) Pursuant to signing of Handover Memorandum under clause 8.2 (i), Contractor shall submit to the Authority’s Engineer, a monthly land possession report till expiry of 180 (one hundred and eighty) days from Appointed Date, in respect of those parts of the site to which vacant access and right of way was not given to the contractor and included in Appendix to the memorandum signed under clause 8.2 (i), duly specifying the part of the site, if any, for which the right of way is yet to be handed over.
SCOPE OF THE CONTRACT The Contractor shall perform the Services set out [in Schedule 1] [below2] in accordance with the Contract. [The Contractor’s key personnel assigned to perform the Services are: [provide a list] During the provision of the Services, if substitution of Contractor’s [key personnel] [experts] is necessary, the Contractor shall propose other experts or at least the same level of qualifications for approval by the Fund. [The Contractor shall obtain the Fund’s prior approval in writing before entering into a subcontract for engaging a subconsultant for the performance of any part of the Services.]
Scope of Use The Fund will use the System and the Data Access Services only for the processing of securities transactions, the keeping of books of account for the Fund and accessing data for purposes of reporting and analysis. The Fund shall not, and shall cause its employees and agents not to (i) permit any unauthorized third party to use the System or the Data Access Services, (ii) sell, rent, license or otherwise use the System or the Data Access Services in the operation of a service bureau or for any purpose other than as expressly authorized under this Addendum, (iii) use the System or the Data Access Services for any fund, trust or other investment vehicle), other than as set forth herein, without the prior written consent of State Street, (iv) allow access to the System or the Data Access Services through terminals or any other computer or telecommunications facilities located outside the Designated Locations, (v) allow or cause any information (other than portfolio holdings, valuations of portfolio holdings, and other information reasonably necessary for the management or distribution of the assets of the Fund) transmitted from State Street’s databases, including data from third party sources, available through use of the System or the Data Access Services to be redistributed or retransmitted to another computer, terminal or other device for other than use for or on behalf of the Fund or (vi) modify the System in any way, including without limitation developing any software for or attaching any devices or computer programs to any equipment, system, software or database which forms a part of or is resident on the Designated Configuration.
Scope of Collaboration As part of the collaboration, the Controllers will act as Joint Controller. The roles of the Controller and the associated tasks are specified in more detail in Appendix 1. If one party is solely responsible for a data processing operation, this party will implement all relevant data protection provisions on its own responsibility. However, such data processing procedures are not subject to this Agreement. Joint data processing and the type of Personal Data collected and processed within the framework of collaboration are specified in Appendix 1.
Scope of Activities Transmission planning activities will be coordinated in accordance with the Amended and Restated Northeast ISO/RTO Planning Coordination Protocol (“Protocol”), between and among PJM Interconnection, L.L.C., the New York Independent System Operator, Inc. and ISO New England Inc., effective as of December 12, 2004 as amended on July 10, 2013.
SCOPE OF SERVICES/CASE HANDLING A. Upon execution by GPM, attorneys are retained to provide legal services for the purpose of seeking damages and other relief in the Litigation. Client provides authorization to seek appointment as Lead Plaintiff in the class action, while the Attorneys will seek to be appointed Class Counsel. If this occurs, the Litigation will be prosecuted as a class action.
B. If you obtain access to non-public information during the pendency of the Litigation, you must not engage in transactions in securities.
C. Attorneys are authorized to prosecute the Litigation. The appointed Lead Plaintiffs will monitor, review and participate with counsel in the prosecution of the Litigation. The Attorneys shall consult with the appointed Lead Plaintiffs concerning all major substantive matters related to the Litigation, including, but not limited to, the complaint, dispositive motions and settlement. Because of potential differences of opinion between Clients concerning, among other things, strategy, goals and objectives of the Litigation, the Attorneys shall consult with the appointed Lead Plaintiffs as to the courses of action to pursue. The Client agrees to abide by the decisions of the appointed Lead Plaintiffs, which shall be final and binding on all Clients.
D. GPM is given the authority to opt the Client out of any class action proceeding relating to the claims authorized herein and/or pursue the Client claim individually in a group action, if the Client is not appointed Lead Plaintiff and GPM is not appointed Class Counsel.
E. The Attorneys shall provide sufficient resources, including attorney time and capital for payment of costs and expenses, to vigorously prosecute the Litigation.
F. Any recovery from defendants that the Attorneys are responsible for will be divided among class members based on the recognized loss by each class member as calculated by a damage allocation plan which will be prepared by a financial expert or consultant, provided to the appointed Lead Plaintiffs, be subject to the Court's approval and will account for such factors as size of securities ownership, date of purchase, date of sale and continued holdings, if any. Under the rules governing class action litigation, while the Lead Plaintiffs recover according to the same formula as other class members, the Court may approve, upon application therefore, reimbursement of the Lead Plaintiffs’ reasonable costs and expenses directly related to the representation of the class. Examples are lost wages and travel expenses associated with testifying in the action.
