Construction Responsibilities The party named in Article 1, Responsible Parties, under AGREEMENT is responsible for the following:
A. Advertise for construction bids, issue bid proposals, receive and tabulate the bids, and award and administer the contract for construction of the Project. Administration of the contract includes the responsibility for construction engineering and for issuance of any change orders, supplemental agreements, amendments, or additional work orders that may become necessary subsequent to the award of the construction contract. In order to ensure federal funding eligibility, projects must be authorized by the State prior to advertising for construction.
B. If the State is the responsible party, the State will use its approved contract letting and award procedures to let and award the construction contract.
C. If the Local Government is the responsible party, the Local Government shall submit its contract letting and award procedures to the State for review and approval prior to letting.
D. If the Local Government is the responsible party, the State must concur with the low bidder selection before the Local Government can enter into a contract with the vendor.
E. If the Local Government is the responsible party, the State must review and approve change orders.
F. Upon completion of the Project, the party responsible for constructing the Project will issue and sign a “Notification of Completion” acknowledging the Project’s construction completion and submit certification(s) sealed by a professional engineer(s) licensed in the State of Texas.
G. For federally funded contracts, the parties to this Agreement will comply with federal construction requirements cited in 23 CFR Part 635 and with requirements cited in 23 CFR Part 633, and shall include the latest version of Form “FHWA-1273” in the contract bidding documents. If force account work will be performed, a finding of cost effectiveness shall be made in compliance with 23 CFR 635, Subpart B.
PRE-CONSTRUCTION PHASE SERVICES The Pre-Construction Phase shall be deemed to commence upon the date specified in a written Notice to Proceed with Pre-Construction Phase Services issued by Owner and shall continue through completion of the Construction Documents and procurement of all major Subcontractor agreements. Contractor is not entitled to reimbursement for any costs incurred for Pre-Construction Phase Services performed before issuance of the written Notice to Proceed. Pre-Construction Phase Services may overlap Construction Phase Services. Contractor shall perform the following Pre-Construction Phase Services:
Customer Responsibilities Notwithstanding the above, Customer agrees that except as provided by this DPA, Customer is responsible for its secure use of the Services, including securing its account authentication credentials, protecting the security of Customer Data when in transit to and from the Services and taking any appropriate steps to securely encrypt or backup any Customer Data uploaded to the Services.
Contractor Responsibilities 19.1. Contractor shall perform national criminal history checks for Ohio, Indiana, and Kentucky, and 10-panel drug screening tests on all prospective employees performing work under this RFP or coming onto a CMHA property and any resulting contract and provide summaries of the results to the Authority if requested. For the purposes of this section, the term “employees” includes contractor. Prospective employees whose criminal background check discloses a misdemeanor or felony involving crimes of moral turpitude, sexual offenses or harm to persons or property shall not be employed to perform work under this RFP or any resulting contract. Contractor is required to perform drug screening of all employees and to ensure acceptable test results. Criminal history and drug screening checks will be completed at the sole expense of the contractor. Any employee of the Contractor suspected of being under the influence of drugs and or alcohol will be reported to the appropriate personnel at CMHA and/or other local law enforcement. If the employee is determined to be under the influence of drugs or alcohol in any form or manner, or believed by proper authority to be dealing in illicit sale of alcohol or drugs they will be removed and shall not be allowed to return to any job site on the Authority’s property. The Contractor’s contract may be suspended and/or terminated should such a situation occur or if the Contractor fails to submit results pursuant to this section.
19.1.1. If CMHA requests additional drug screening, the test shall be performed within 24 hours and the summary shall be sent directly to CMHA from the testing facility.
19.2. Contractor(s) shall provide uniforms and ID Badges identifying Contractor for all employees working on CMHA’s properties. No employees will be allowed on CMHA’s properties out of uniform and without his/her ID badge on his/her person. Contractor(s) must submit a picture of the uniform and a sample of his/her ID badge if requested by CMHA.
19.3. Contractor’s personnel shall be neat and conduct all work in a professional and efficient manner. If any employee of Contractor is deemed unacceptable by CMHA, Contractor shall immediately replace such personnel with an acceptable substitute to CMHA.
19.4. Contractor(s) shall practice acceptable safety precautions so as not to cause harm to any persons or property while performing services under this RFP or any resulting contract. Contractor(s) shall follow industry safety standards, and use only industry approved safety equipment in accordance with the manufacturer’s specifications in the performance of all duties.
19.5. Contractor(s) shall pay all of its employees, including any and all approved Sub-Contractors, at least the legal minimum wages as determined by the United States Department of Labor and the United States Department of Housing and Urban Development and Department of Labor Prevailing Wage. Wage Determinations can be accessed via the Department of Labor website, xxx.xxxx.xxx.
19.6. Upon completion of the work, Contractor(s) shall clean up the area where the work was performed and Contractor(s) shall remove any debris generated by the products and/or services at CMHA premises. At no time, will Contractor(s) discard debris into any CMHA refuse container.
19.7. Contractor(s) shall clearly mark all work areas that might reasonably be expected to endanger the health and safety of residents, guests, or any other persons. Contractor(s) will provide such signs, markers and barricades as required to identify all work areas and minimize inherent dangers.
19.8. The contractor shall be responsible for notifying CMHA immediately of any damages (i.e. fire, container leaking) deemed to be a health or safety hazard whether the damage is caused by the contractor or other means.
19.9. The Contractor shall be responsible for safeguarding all CMHA property provided for Contractor use. At the close of each workday, CMHA facilities, property and materials shall be inspected and secured.
Specific Responsibilities Without limiting the responsibilities of the Manager, the Manager will:
1. Maintain office facilities (which may be in the offices of the Manager or a corporate affiliate but shall be in such location as the Trust reasonably determines).
2. Furnish statistical and research data, clerical services and stationery and office supplies.
3. Compile data for, prepare for execution by the Fund and file all the Fund’s federal and state tax returns and required tax filings other than those required by this Agreement to be made by the Fund’s custodian and transfer agent.
4. Prepare compliance filings pursuant to state securities laws with the advice of the Trust’s counsel.
5. Prepare the Trust’s Annual and Semi-Annual Reports to Shareholders and amendments to its Registration Statements (on Form N-1A or any replacement therefor).
6. Compile data for, prepare and file timely Notices to the SEC required pursuant to Rule 24f-2 under the 1940 Act.
7. Determine the daily pricing of the portfolio securities and computation of the net asset value and the net income of Fund in accordance with the Prospectus, resolutions of the Trust’s Board of Trustees, and the procedures set forth in EXHIBIT A: NET ASSET VALUE CALCULATIONS.
8. Keep and maintain the financial accounts and records of the Fund and provide the Trust with certain reports, as needed or requested by the Fund.
9. Provide officers for the Trust as requested by the Trust’s Board of Trustees.
10. Perform fund accounting services for the Fund as set forth in EXHIBIT B: FUND ACCOUNTING FUNCTIONS.
11. Generally assist in all aspects of the operations of the Fund.
Owner Responsibilities The project owner or the engineer or architect of record acting as the owner’s agent shall fund special inspection services.
Vendor Responsibilities Note: NO EXCEPTIONS OR REVISIONS WILL BE CONSIDERED IN C-M, O-S, V-W. Indemnification
ARCHITECT’S RESPONSIBILITIES § 2.1 The Architect shall provide professional services as set forth in this Agreement. The Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the services required by this Agreement, or shall cause such services to be performed by appropriately licensed design professionals.
§ 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project.
§ 2.3 The Architect shall identify a representative authorized to act on behalf of the Architect with respect to the Project.
§ 2.4 Except with the Owner’s knowledge and consent, the Architect shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Architect’s professional judgment with respect to this Project.
§ 2.5 The Architect shall maintain the following insurance until termination of this Agreement. If any of the requirements set forth below are in addition to the types and limits the Architect normally maintains, the Owner shall pay the Architect as set forth in Section 11.9.
§ 2.5.1 Commercial General Liability with policy limits of not less than « » ($ « » ) for each occurrence and « » ($ « » ) in the aggregate for bodily injury and property damage.
§ 2.5.2 Automobile Liability covering vehicles owned, and non-owned vehicles used, by the Architect with policy limits of not less than « » ($ « » ) per accident for bodily injury, death of any person, and property damage arising out of the ownership, maintenance and use of those motor vehicles, along with any other statutorily required automobile coverage.
§ 2.5.3 The Architect may achieve the required limits and coverage for Commercial General Liability and Automobile Liability through a combination of primary and excess or umbrella liability insurance, provided such primary and excess or umbrella liability insurance policies result in the same or greater coverage as the coverages
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Engineer Responsibilities No subcontract relieves the Engineer of any responsibilities under this contract.
