Service Delivery Requirements All services provided by the Vendor under the terms and conditions of this Contract shall be delivered in accordance with:
DELIVERY REQUIREMENTS Contractor must ensure that delivery of goods and/or services will be made as required by this Master Contract, the Purchase Order used by Purchasers, or as otherwise mutually agreed in writing between the Purchaser and Contractor. The following apply to all deliveries:
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Forecasting Requirements for Trunk Provisioning Within ninety (90) days of executing this Agreement, Reconex shall provide Verizon a two (2) year traffic forecast. This initial forecast will provide the amount of traffic to be delivered to and from Verizon over each of the Local Interconnection Trunk groups over the next eight (8) quarters. The forecast shall be updated and provided to Verizon on an as-needed basis but no less frequently than semiannually. All forecasts shall comply with the Verizon CLEC Interconnection Trunking Forecast Guide and shall include, at a minimum, Access Carrier Terminal Location (“ACTL”), traffic type (Local Traffic/Toll Traffic, Operator Services, 911, etc.), code (identifies trunk group), A location/Z location (CLLI codes for Reconex-IPs and Verizon-IPs), interface type (e.g., DS1), and trunks in service each year (cumulative).
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Training Delivery Type Code -- Code Short Description Long Description (If Applicable) 01 Traditional Classroom (no technology)
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Minimum Condition and Warranty Requirements for TIPS Sales All goods quoted or sold through a TIPS Sale shall be new unless clearly stated otherwise in writing. All new goods and services shall include the applicable manufacturers minimum standard warranty unless otherwise agreed to in the Supplemental Agreement.
Quality Requirements Performance Indicator Heading Indicator (specific) Threshold Method of Measurement Frequency of monitoring Consequence of Breach QUALITY Patient Safety - Incidents I1 Number of incidents Adverse incidents include the following: clinical or non clinical adverse events that have potential to cause avoidable harm to a patient, including medical errors or adverse events related to medical devices or other equipment. Clinical or non- clinical accidents, accidental injuries to staff and members of the public, verbal, physical or psychological abuse or harassment, unusual or dangerous occurrences, damage to trust property, plant or equipment, fire or flood, security, theft or loss, near misses are identified as any event where under different circumstances significant injury or loss may have occurred Number of recorded incidents in the contract month Monthly Remedial Action Plan brought to Performance Meeting following breach; action under Module C Clause 32 if needed I2 Number of Sis Definition of SUI according to trust policy and national guidance Number of Serious Untoward Incidents reported in contract month Monthly Remedial Action Plan brought to Performance Meeting following breach; action under Module C Clause 32 if needed S1 Percentage of eligible staff received child safeguarding training at level 2 (as identified in LSCB training strategy) 95% Number received training/ Number of identified staff requiring training Monthly S2 Percentage of eligible staff received adult safeguarding awareness training at level 2 ( as identified in K&M Safeguarding Vulnerable Adults training strategy) 95% Number of staff trained/ Number of identified staff requiring training Monthly
EMHS Governance, Safety and Quality Requirements 4.1 Participates in the maintenance of a safe work environment.
