Notice to Proceed (NTP Following the JOA and purchase order issuance, the County will issue a Notice to Proceed (NTP) that will provide the construction start date, the Work duration period, and the Substantial Completion date. The Contractor agrees to begin and complete construction within the dates specified on the NTP. The County must approve all extensions of time in writing. The County may also issue an Emergency Notice to Proceed (NTP). In the event the County requires the Contractor to respond to an immediate request for work, a Job Order will be created and an Emergency NTP will be issued. The Contractor will be required to perform the Scope of Work included with the Emergency NTP as directed by the County’s Project Manager or designee. The Detailed Scope of Work, Quotation, Subcontractor Listing, Shop Drawings and required Non Pre-priced backup documentation will be submitted upon completion of the emergency work in accordance with the Ordering Procedures detailed in Section III above.
Settlement Payment If the resulting net amount is positive, it shall be payable by the Defaulting Party to the Non-Defaulting Party, and if it is negative, then the absolute value of such amount shall be payable by the Non-Defaulting Party to the Defaulting Party.
EFFECTIVE DATE OF SETTLEMENT 38. The Effective Date of this Settlement shall be the first business day on which all of the following shall have occurred or been waived:
Rollovers of Exxon Xxxxxx Settlement Payments If you receive a qualified settlement payment from Exxon Xxxxxx litigation, you may roll over the amount of the settlement, up to $100,000, reduced by the amount of any qualified Exxon Xxxxxx settlement income previously contributed to a Traditional or Xxxx XXX or eligible retirement plan in prior taxable years. You will have until your tax return due date (not including extensions) for the year in which the qualified settlement income is received to make the rollover contribution. To obtain more information on this type of rollover, you may wish to visit the IRS website at xxx.xxx.xxx.
Contract Closure Contracting Officer shall give appropriate written notice to Purchaser when Purchaser has complied with the terms of this contract. Purchaser shall be paid refunds due from Timber Sale Account un- der B4.24 and excess cooperative deposits under B4.218.
Settlement Relief A. An Injunction, as set forth below in Section II.E hereof.
Settlement With respect to any Third Party Claims that relate solely to the payment of money damages in connection with a Third Party Claim and that will not result in the Indemnified Party’s becoming subject to injunctive or other relief or otherwise adversely affecting the business of the Indemnified Party in any manner, and as to which the indemnifying Party will have acknowledged in writing the obligation to indemnify the Indemnified Party hereunder, and subject to the Litigation Conditions being satisfied, the indemnifying Party will have the sole right to agree to the entry of any judgment, enter into any settlement or otherwise dispose of such Loss, on such terms as the indemnifying Party, in its sole discretion, will deem appropriate. With respect to all other Losses in connection with Third Party Claims, where the indemnifying Party has assumed the defense of the Third Party Claim in accordance with Section 9.6(d)(i), the indemnifying Party will have authority to agree to the entry of any judgment, enter into any settlement or otherwise dispose of such Loss provided it obtains the prior written consent of the Indemnified Party (such consent not to be unreasonably withheld, delayed or conditioned). The indemnifying Party will not be liable for any settlement or other disposition of a Loss by an Indemnified Party that is reached without the prior written consent of the indemnifying Party. Regardless of whether the indemnifying Party chooses to defend or prosecute any Third Party Claim, no Indemnified Party will admit any liability with respect to or settle, compromise or discharge, any Third Party Claim without the prior written consent of the indemnifying Party, such consent not to be unreasonably withheld, delayed or conditioned.
Settlement Payments On the first Business Day of each month ("Interest Settlement Date"), Collateral Agent will advise each Lender by telephone, fax or telecopy of the amount of such Lender's share of interest and fees on each of the Loans as of the end of the last day of the immediately preceding month. Provided that such Lender has made all payments required to be made by it under this Agreement, Collateral Agent will pay to such Lender, by wire transfer to such Lender's account (as specified by such Lender on the signature page of this Agreement or the applicable Assignment and Acceptance Agreement, as amended by such Lender from time to time after the date hereof or in the applicable Assignment and Acceptance Agreement) not later than 3:00 p.m. Chicago time on the next Business Day following the Interest Settlement Date, such Lender's share of interest and fees on each of the Loans. Such Lender's share of interest on each Loan will be calculated for that Loan by adding together the Daily Interest Amounts for each calendar day of the prior month for that Loan and multiplying the total thereof by the Interest Ratio for that Loan. Such Lender's share of the Unused Line Fee described in subsection 2.3(A) shall be an amount equal to (a)(i) such Lender's average Revolving Loan Commitment during such month, less (ii) the sum of (x) such Lender's average Daily Loan Balance of the Revolving Loans, plus (y) such Lender's Pro Rata Share of the average daily aggregate amount of Letter of Credit Reserve, in each case for the preceding month, multiplied by (b) the percentage required by subsection 2.3(A). Such Lender's share of all other fees paid to Collateral Agent for the benefit of Lenders hereunder shall be paid and calculated based on such Lender's Commitment with respect to the Loans on which such fees are associated. To the extent Collateral Agent does not receive the total amount of any fee owing by Borrowers under this Agreement, each amount payable by Collateral Agent to a Lender under this subsection 9.8(A)(4) with respect to such fee shall be reduced on a pro rata basis. The Collateral Agent and the Lenders hereby acknowledge and agree that in no event shall the aggregate fee payments received by such Lenders pursuant to this subsection 9.8(A)(4) exceed the total amount of fees pursuant to subsection 2.3.
Notice to Proceed Work shall not commence on this Project until the Director has issued a written Notice to Proceed to the Recipient. Such Notice will not be issued until the Director is assured that the Recipient has complied with the Recipient's responsibilities concerning OEPA plan approval, when applicable. A Notice to Proceed shall be required for all project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.
REPORT ON CONTRACT SALES ACTIVITY AND ADMINISTRATIVE FEE PAYMENT A. CONTRACT SALES ACTIVITY REPORT. Each calendar quarter, Supplier must provide a contract sales activity report (Report) to the Sourcewell Supplier Development Administrator assigned to this Contract. Reports are due no later than 45 days after the end of each calendar quarter. A Report must be provided regardless of the number or amount of sales during that quarter (i.e., if there are no sales, Supplier must submit a report indicating no sales were made). The Report must contain the following fields: • Participating Entity Name (e.g., City of Staples Highway Department); • Participating Entity Physical Street Address; • Participating Entity City; • Participating Entity State/Province; • Participating Entity Zip/Postal Code; • Participating Entity Contact Name; • Participating Entity Contact Email Address; • Participating Entity Contact Telephone Number; • Sourcewell Assigned Entity/Participating Entity Number; • Item Purchased Description; • Item Purchased Price; • Sourcewell Administrative Fee Applied; and • Date Purchase was invoiced/sale was recognized as revenue by Supplier.
