Shift Work Shift work is work not in excess of ordinary hours (ie 38 hours per week), but carried out wholly or partly between the hours of 7.00pm and 7.00am, Monday to Friday. Shift work is work scheduled at least 24 hours prior to the commencement of the shift. Employees required to work shift work will be paid at time and one quarter of the ordinary rate per hour for ordinary hours worked.
Tenant Improvements Landlord shall cause the Core and Shell Contractor or another Contractor designated by Landlord and approved by Tenant, such consent not to be unreasonably withheld or delayed (“TI Contractor”, and together with Core and Shell Contractor, “Contractor”) to commence and thereafter diligently prosecute the construction of the tenant improvements in the Premises pursuant to the Work Letter (the “Tenant Improvements”); provided, however, that before performing the Tenant Improvements, Landlord shall prepare in good faith an estimated budget for the construction of the Tenant Improvements and deliver such budget to Tenant for Tenant’s written approval prior the start of construction (the “Budget”). Landlord and Tenant shall work together cooperatively and in good faith to achieve a mutually acceptable Budget. Landlord shall update the Budget for Tenant’s review and approval at reasonable intervals and shall notify Tenant in writing if the Budget is likely to be exceeded. If there is an indication that the Budget is likely to be exceeded, Landlord and Tenant shall work together cooperatively, if required by Tenant, to modify the scope of the Tenant Improvements to bring the same in line with a budget reasonably acceptable to Tenant. The Tenant Improvements shall be performed in a workmanlike manner and shall substantially conform with Applicable Laws and the Approved TI Plans (as defined in the Work Letter). Tenant shall pay all TI Costs, except that Landlord shall pay for TI Costs that do not exceed the TI Allowance. The “TI Allowance” shall mean (a) One Hundred Twenty Five Dollars ($125.00) per rentable square foot of the Premises (the “Initial TI Allowance”), together with (b) the Additional Allowance. The “TI Costs” shall mean all Tenant Core and Shell Costs (as defined in the Work Letter) and all costs and expenses of performing the TI Work, including without limitation the hard and soft costs of (i) construction, (ii) the Construction Management Fee (as such term is defined in the Work Letter) and any Project or construction management fees paid by Tenant to an unaffiliated third party (such fees not to exceed three percent (3%) of the TI Allowance), (iii) space planning, design, architect, engineering, data and phone cabling and other related services, (iv) costs and expenses for labor, material, equipment, data and phone cabling and fixtures (including, without limitation, any of the Attached Property (as defined in Section 18.5), (v) building permits and other taxes, fees, charges and levies by governmental and quasi-governmental agencies for permits or for inspections of the Tenant Improvements, and (vi) the Warm Shell Costs. In no event shall the TI Allowance be used for: (w) the purchase of any furniture, personal property or other non-building system equipment, (x) costs resulting from a Tenant Delay, (y) costs resulting from any default by Tenant of its obligations under this Lease, or (z) costs that are recoverable or reasonably recoverable by Tenant from a third party (e.g., insurers, warrantors, or tortfeasors). In the event the estimated total TI Costs (as set forth in the Budget) exceed the TI Allowance, Tenant shall deposit with Landlord such overage (the “TI Allowance Excess”), within five (5) business days of receiving the Budget (the “TI Deposit”). In the event Landlord determines the estimate of the TI Costs set forth in the Budget underestimates the amount of TI Costs so that the TI Deposit will not be sufficient to cover the TI Allowance Excess, then Landlord shall communicate the same to Tenant and, if required by Tenant, the parties shall discuss revisions to the Budget and Tenant may make a TI Tenant Change Order Request to reduce TI Costs, and unless the TI Costs are reduced to be within the Budget and previously paid TI Deposit, Tenant shall promptly pay the additional amount to Landlord, and such additional amount shall be added to the TI Deposit. If the sum of the TI Allowance plus the TI Deposit is not sufficient to cover the TI Costs, Tenant shall reimburse Landlord the difference between (a) the TI Costs and (b) the sum of the TI Allowance and the TI Deposit. However, Landlord shall be solely responsible for any costs related to the Tenant Improvements to the extent the same result from Landlord’s gross negligence, intentional misconduct or breach of Lease. Landlord and Tenant shall work together cooperatively at no cost or risk to Landlord to maximize Tenant’s ability, to the extent reasonably possible, to obtain the benefit of any applicable research and development tax credits with respect to the Tenant Improvements.
Contract Work Contract work means capital project work within existing plant facilities, major maintenance and/or revamp work, plant modifications and/or shutdown work, minor maintenance and/or repair work, breakdown maintenance.
Project Work PURCHASER shall complete the following projects in accordance with the specifications provided in Exhibits B, C, D, E, and F and written instructions from STATE. Project locations are shown on Exhibit A unless otherwise described. PURCHASER shall furnish all material unless otherwise specified.
Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
Tenant’s Work Section 5.1 Except as may be expressly provided in this lease, Tenant shall not replace any fixtures in the Premises or make any changes, improvements, alterations or additions (collectively, “Tenant’s Work”), to the Premises, the Real Property, the Building systems, or any part thereof, without Xxxxxxxx’s prior consent. Landlord’s consent shall not be unreasonably withheld or delayed if Tenant’s Work (a) is nonstructural, and (b) does not (i) affect any part of the Real Property outside the Premises (including the Building roof) or the exterior of the Premises, (ii) affect any structural element of the Building, (iii) adversely affect any Building system, or (iv) require an amendment of the certificate of occupancy for the Premises or the Building, ( c) is not visible outside the Premises and (d) is performed only by contractors and subcontractors first approved by Landlord (which approval shall not be unreasonably withheld or delayed). Xxxxxxxx’s consent shall not be required with respect to such of Tenant’s Work as are cosmetic alterations (such as painting the interior of the Premises, carpeting, and installation of shelving and display cases) inside the Premises (“Cosmetic Alterations”), provided Tenant complies with the other applicable provisions of this lease. Tenant’s Work shall be performed, at Tenant’s expense, with diligence when started so as to promptly complete it in a good and worker-like manner using new materials of first class quality and in compliance with this lease, all Laws and Tenant’s Plans (as defined in Section 5.2) as approved by Landlord. As part of Tenant’s Work, Tenant shall soundproof the Premises and install appropriate ventilation if required so that Tenant’s use of the Premises shall not result in noise and/or odors being transmitted outside the Premises. Tenant’s Work shall be fully paid for by Tenant when payment is due and shall not be financed with any conditional sales or title retention agreements or by the granting of any security interests, liens, encumbrances or financing statements. Tenant’s Work shall be deemed, upon installation, to be improvements and betterments that become the property of Landlord at installation, and shall remain upon and be surrendered with the Premises, at the expiration of the Term (or the sooner termination of this lease in accordance with its provisions) unless Landlord notifies Tenant in accordance with the provisions of this Article that Landlord relinquishes its rights thereto, in which case Tenant shall be obligated to remove such Tenant’s Work.
Section 5.2 Prior to commencing any Tenant’s Work other than purely Cosmetic Alterations, Tenant shall, at Tenant’s expense, deliver to Landlord detailed plans and specifications, for Tenant’s Work, in form reasonably satisfactory to Landlord, prepared, certified, signed and sealed by an architect or engineer licensed to practice in the State of New York, and suitable for filing with the applicable Authority, if filing is required by applicable Laws (such plans and specifications together with revisions thereto, collectively, “Tenant’s Plans”), and obtain Landlord’s approval of Xxxxxx’s Plans. Xxxxxxxx’s approval of Xxxxxx’s Plans shall not be unreasonably withheld or delayed to the extent Xxxxxxxx’s consent to Xxxxxx’s Work shown on Tenant’s Plans is not to be unreasonably withheld or delayed pursuant to this Article. Before commencing Tenant’s Work, Tenant shall (a) obtain (and deliver to Landlord copies of) all required permits and authorizations of any Authority for such work, and (b) deliver to Landlord such security as shall be reasonably satisfactory to Landlord, and (c) deliver to Landlord certificates (in form reasonably acceptable to Landlord) evidencing the following insurance coverages from each contractor and subcontractor: (i) worker’s compensation insurance covering all persons to be employed in the performance of any Tenant’s Work, and
Extra Work At any time during the Term of this Agreement, City may request that Consultant perform Extra Work. As used herein, “Extra Work” means any work which is determined by City to be necessary for the proper completion of the Project, but which the Parties did not reasonably anticipate would be necessary at the execution of this Agreement. Consultant shall not perform, nor be compensated for, Extra Work without written authorization from City’s Representative.
Landlord’s Work Prior to the execution of the Lease, Landlord and Tenant have approved the detailed description of base, shell and core work for the Phase I Premises and Phase II Premises attached hereto as Exhibit B-1 (the “Base, Shell and Core Description”). Based upon and in conformity with the Base Shell and Core Description, Landlord shall cause its architect and engineers, at Landlord’s sole cost and expense, to prepare and deliver to Tenant, for Tenant’s approval, detailed specifications and engineered working drawings in CAD format, which shall include, without limitation, ADA path of travel, restroom locations and counts, exit lighting plans for the Phase I Work (the “Base Building Working Drawings”) by no later than June 1, 2019. Within seven (7) days after Tenant’s and Landlord’s receipt of the Base Building Working Drawings, Tenant and Landlord shall approve or disapprove the same, which approval shall not be unreasonably withheld; provided, however, that Tenant may only disapprove the Base Building Working Drawings to the extent such Base Building Working Drawings are inconsistent with the Base, Shell and Core Description and only if Tenant delivers notice thereof to Landlord within such seven (7) day period. If any specific changes proposed by Tenant to rectify any inconsistencies with the Base, Shell and Core Description are timely and properly proposed by Tenant, Landlord shall cause its architect and engineers to revise the Base Building Working Drawings to incorporate such revisions and submit the same for Tenant’s approval in accordance with the foregoing provisions, and the parties shall follow the foregoing procedures for approving the Base Building Working Drawings until the same are finally approved by Landlord and Tenant. Upon Landlord’s and Tenant’s approval of the Base Building Working Drawings, the same shall be referred to as the “Approved Working Drawings for Landlord’s Phase I Work”. Based upon and in conformity with the Base, Shell and Core Description, Landlord shall cause its architect and engineers, at Landlord’s sole cost and expense, to prepare and deliver to Tenant, for Tenant’s approval, detailed specifications and engineered working drawings in CAD format, which shall include, without limitation, ADA path of travel, restroom locations and counts, exit lighting plans for the Phase II Work (the “Phase II Base Building Working Drawings”) by no later than October 1, 2019. Within seven (7) days after Tenant’s and Landlord’s receipt of the Phase II Base Building Working Drawings, Tenant and Landlord shall approve or disapprove the same, which approval shall not be unreasonably withheld; provided, however, that Tenant may only disapprove the Phase II Base Building Working Drawings to the extent such Phase II Base Building Working Drawings are inconsistent with the Base, Shell and Core Description and only if Tenant delivers notice thereof to Landlord within such seven (7) day period. If any specific changes proposed by Tenant to rectify any inconsistencies with the Base, Shell and Core Description are timely and properly proposed by Tenant, Landlord shall cause its architect and engineers to revise the Phase II Base Building Working Drawings to incorporate such revisions and submit the same for Tenant’s approval in accordance with the foregoing provisions, and the parties shall follow the foregoing procedures for approving the Phase II Base Building Working Drawings until the same are finally approved by Landlord and Tenant. Upon Landlord’s and Tenant’s approval of the Phase II Base Building Working Drawings, the same shall be referred to as the “Approved Working Drawings for Landlord’s Phase II Work”. The improvements shown on the Approved Working Drawings for Landlord’s Phase I Work and the Approved Working Drawings for Landlord’s Phase II Work are hereby collectively referred to as “Landlord’s Work”. The Approved Working Drawings for Landlord’s Phase I Work and the Approved Working Drawings for Landlord’s Phase II Work are sometimes collectively referred to herein as the “Approved Working Drawings for Landlord’s Work”.
Demolition work (a) As of 1 October 2020 where Employees are directly performing demolition works that would require a demolition permit that allows the performance of such work, they will receive the amount of $8.35 per hour or the site allowance, whichever is the greater. This allowance will be adjusted annually in accordance with CPI (All Groups, Melbourne) movements measured in the twelve month period ending the previous December quarter effective as of 1 March 2021, rounded to the nearest 5 cents.
(b) As of 1 October 2020 where Employees are employed in connection with, and on work, with employees of demolition contractors (ie. working within the demolition zone and/or subject to the additional disabilities arising from that demolition), they will receive the amount of $7.50 per hour or the site allowance, whichever is the greater. This allowance will be adjusted annually in accordance with CPI (All Groups, Melbourne) movements measured in the twelve month period ending the previous December quarter effective as of 1 March 2021, rounded to the nearest 5 cents.
UNIT WORK When the Employer deems it necessary in order to carry out a mission and operations of the campus, the Employer may contract out work provided that the contracting out does not displace bargaining unit employees or reduces their scheduled hours. The Maine Community College shall notify MSEA-SEIU when contracting out is to be implemented. MSEA-SEIU may request to meet and confer on the impact on contracting out such work. The Maine Community College shall meet with MSEA-SEIU within thirty (30) days of such request. Notice to MSEA-SEIU shall be not later than one hundred twenty (120) days prior to the commencement of the contracting out. In emergency circumstances, when the College enters into a contract under which contracting out will commence in less than thirty (30) days, when possible, notification shall be made two (2) weeks prior to implementing the contract, but in no event later than ten (10) working days after the commencement of the contracting out. Prior to the meeting and conferring on contracting out, the Maine Community College System will provide MSEA-SEIU all relevant written information, including copies of bids received, any cost analysis used by the College to evaluate the need for contracting out, and all other relevant material used by the College in making its decision regarding contracting out. Contracting out of the type of work normally performed by existing bargaining unit members for limited periods not to exceed six (6) months shall be allowed without the Union’s agreement if one or more of the following conditions are present at the affected campus or other non-campus location (such as the System Office in Augusta):
1. The skills and abilities or legally required licenses or equipment needed to perform the work are not available within the bargaining unit.
2. The opportunity to do the work is declined by any qualified and available bargaining unit employees. “Qualified” as used in this Article is defined as having special skills, abilities, license or equipment necessary to perform the work.
