DELIVERY: FOB DESTINATION, INSIDE DELIVERY, FREIGHT PAID Whenever possible, contractors should give the ordering entities 3 working days prior notice of any deliveries and/or installations. Furniture contractors will not be responsible for the removal/moving of existing furnishings unless requested by the ordering entity. Contractors should verify site readiness prior to delivery. All deliveries will be made during normal working hours unless otherwise arranged with the ordering entity. Contractor will communicate any scheduling delays and/or changes immediately. Agencies will not be responsible for any freight damage, concealed or otherwise.
No Transmission Delivery Service The execution of this Agreement does not constitute a request for, nor agreement to provide, any Transmission Service under the NYISO OATT, and does not convey any right to deliver electricity to any specific customer or Point of Delivery. If Developer wishes to obtain Transmission Service on the New York State Transmission System, then Developer must request such Transmission Service in accordance with the provisions of the NYISO OATT.
Service Delivery Grantee shall:
1. Adhere to the Priority Populations for Treatment Programs as stated in the SUD UM Guidelines.
2. Maintain Daily Capacity Management Report in CMBHS as required in the SUD UM Guidelines.
3. Maintain a Waiting List to track all eligible individuals who have been screened but cannot be admitted to SUD treatment immediately.
i. Grantee that has an individual identified as a federal and state priority population on the waiting list shall confirm this in the Daily Capacity Management Report.
ii. Grantee shall arrange for appropriate services in another treatment facility or provide access to interim services as indicated within 48 hours when efforts to refer to other appropriate services are exhausted.
iii. Grantee shall offer directly or through referral interim services to wait-listed individuals.
iv. Establish a wait list that includes priority populations and interim services while awaiting admission to treatment services.
v. Develop a mechanism to maintain contact with individuals awaiting admission.
4. If unable to provide admissions to individuals within Priority Populations for Treatment Programs according to SUD UM Guidelines:
i. Implement written procedures that address maintaining weekly contact with individuals waiting for admissions as well as what referrals are made when a client cannot be admitted for services immediately.
ii. When Grantee cannot admit a client, who is at risk for dangerous for withdrawal, Grantee shall ensure that an emergency medical care provider is notified.
iii. Coordinate with an alternate provider for immediate admission.
iv. Notify Substance Use Disorder (Xxxxxxxxx_Xxx_Xxxxxxxx@xxxx.xxxxx.xx.xx) so that assistance can be provided that ensures immediate admission to other appropriate services and proper coordination when appropriate.
v. Provide pre-admission service coordination to reduce barriers to treatment, enhance motivation, stabilize life situations, and facilitate engagement in treatment.
vi. Adhere to Informed Consent Document for Opioid Use Disorder applicable to the individual as stated in the SUD UM Guidelines.
vii. When an individual is placed on the Wait List, Grantee shall document interim services as referrals that provides applicable testing, counseling, and treatment for Human Immunodeficiency Virus (HIV), tuberculosis (TB) and sexually transmitted infections (STIs).
Transmission Delivery Service Implications Under ER Interconnection Service, Interconnection Customer will be eligible to inject power from the Generating Facility into and deliver power across the Transmission System on an “as available” basis up to the amount of MW identified in the applicable stability and steady state studies to the extent the upgrades initially required to qualify for ER Interconnection Service have been constructed. After that date FERC makes effective MISO’s Energy Market Tariff filed in Docket No. ER04-691-000, Interconnection Customer may place a bid to sell into the market up to the maximum identified Generating Facility output, subject to any conditions specified in the Interconnection Service approval, and the Generating Facility will be dispatched to the extent the Interconnection Customer’s bid clears. In all other instances, no transmission or other delivery service from the Generating Facility is assured, but Interconnection Customer may obtain Point-To-Point Transmission Service, Network Integration Transmission Service or be used for secondary network transmission service, pursuant to the Tariff, up to the maximum output identified in the stability and steady state studies. In those instances, in order for Interconnection Customer to obtain the right to deliver or inject energy beyond the Point of Interconnection or to improve its ability to do so, transmission delivery service must be obtained pursuant to the provisions of the Tariff. The Interconnection Customer’s ability to inject its Generating Facility output beyond the Point of Interconnection, therefore, will depend on the existing capacity of the Transmission or Distribution System as applicable, at such time as a Transmission Service request is made that would accommodate such delivery. The provision of Firm Point-To-Point Transmission Service or Network Integration Transmission Service may require the construction of additional Network or Distribution Upgrades.
Delivery Location All Goods shall be delivered to the address specified in this Order (the "Delivery Location") during Buyer's normal business hours or as otherwise instructed by Buyer.
Service Delivery Requirements The following sections describe in detail the work activity required by this program. All CONTRACTORS will be expected to fulfill the work activity requirements in these areas.
A. Staff Requirements & Policies CONTRACTOR shall provide the necessary management and administrative personnel whose expertise will ensure efficient operation of SNEMT services. OoA recognizes that a high quality operation begins with key personnel. Therefore, a minimum level of required staffing is described for the positions and functions described below.
1. Program Manager/Director The program manager/director will be in charge of all management and day- to-day operations of the CONTRACTOR’s SNEMT program. The position will maintain consistent and sufficient contact and communication with the OoA and be responsible for all CONTRACT obligations.
Delivery Time Vendors shall specify the estimated delivery time in calendar days for each item. The purchaser should consult the vendor regarding vehicle production schedules. Delivery shall be within the normal working hours of the user, Monday through Friday, excluding holidays.
Delivery Term The period for which prices for All-Requirements Power Supply have been established, as set forth in Exhibit A.
PRODUCT DELIVERY Delivery must be made as ordered to the address specified on the Purchase Order and in accordance with the terms of the Contract or Contract Award Notice. Unless otherwise specified in the Bid Documents, delivery shall be made within thirty calendar days after receipt of a Purchase Order by the Contractor. The decision of the Commissioner as to compliance with delivery terms shall be final. The burden of proof for delay in receipt of Purchase Order shall rest with the Contractor. In all instances of a potential or actual delay in delivery, the Contractor shall immediately notify the Commissioner and the Authorized User, and confirm in writing the explanation of the delay, and take appropriate action to avoid any subsequent late deliveries. Any extension of time for delivery must be requested in writing by the Contractor and approved in writing by the Authorized User. Failure to meet such delivery time schedule may be grounds for cancellation of the order or, in the Commissioner’s discretion, the Contract.
How to Obtain Warranty Service The Warranty Holder must inspect the Flooring for Manufacturing Defects caused by improper milling, grading, staining, and coating, and report any such defects to Cali Bamboo, prior to installation of the Flooring. To obtain warranty service, the Warranty Holder must contact Cali Bamboo’s Customer Experience Department: xxxxxxxxxxxxxxx@xxxxxxxxxx.xxx/ 000- 000-0000. Warranty claims must be received within 30 calendar days after the Warranty Holder identifies the Manufacturing Defect or other basis for a warranty claim. To be covered under this Cali Bamboo limited warranty, the Warranty Holder must provide documentation of sales order and proof that the Flooring was properly installed in accordance with the Installation Guide (defined below). Cali Bamboo reserves the right to retain a certified and independent National Wood Flooring Association inspector (“NWFA Inspector”) to verify the Warranty Holder’s warranty claims. The determination of the NWFA Inspector regarding the warranty claim is not binding on either Cali Bamboo or on the Warranty Holder. A determination that does not verify the warranty claim shall not affect the Warranty Holder’s right to submit its claim to arbitration in accordance with the terms of the Arbitration Agreement (as defined in Cali Bamboo’s Terms and Conditions of Purchase). The performance of the inspection, however, if requested by Xxxx Xxxxxx and assuming that Xxxx Xxxxxx advances the full cost of the inspection as described above, is a requirement for the Warranty Holder to submit a warranty claim to arbitration under the Arbitration Agreement. For specific instructions on how to obtain warranty service for defective Flooring, visit the Cali Bamboo website xxxxx://xxx.xxxxxxxxxx.xxx/flooring-warranty/. This limited warranty covers Flooring that is both (i) installed with strict adherence to Cali Bamboo’s Odyssey Engineered flooring installation guide found online at xxxxx://xxx.xxxxxxxxxx.xxx/flooring-installation/ (the “Installation Guide”) and
