Selection of Architect/Construction Drawings Tenant shall retain an architect/space planner reasonably and mutually agreed upon by Landlord and Tenant (the “Architect”) to prepare the “Construction Drawings,” as that term is defined in this Section 3.1. The Contractor (as that term is defined in Section 4.1 of this Work Letter) shall provide design-build services from qualified, Landlord-approved mechanical, electrical and plumbing contractors for the preparation of plans and engineering working drawings related to the Improvements. Landlord hereby approves Gensler as the Architect if Tenant decides to select them. Tenant shall retain the engineering consultants designated by Landlord (the “Engineers”) to prepare all plans and engineering working drawings relating to the structural, HVAC, lifesafety, and sprinkler work in the Premises, which work is not part of the Base Building, provided that Tenant shall retain the subcontractors designated in Schedule 2 attached hereto for the fire alarm design and programming work (the “Fire Alarm Subcontractor”) and for building management systems (the “BMS Subcontractor”). Landlord hereby approves Gensler as the Engineer if Tenant decides to select them. Should Tenant choose to prepare fully engineered drawings in lieu of the design-build approach described above, then Tenant shall retain the Engineers to prepare all plans and engineering working drawings relating to the mechanical, electrical and plumbing work of the Improvements. The plans and drawings to be prepared by Architect, the design-build contractors (unless Tenant selects the fully engineered drawings approach described above), the Fire Alarm Subcontractor, the BMS Subcontractor and the Engineers hereunder shall be known collectively as the “Construction Drawings.” Landlord hereby approves Gensler and Revel to be the Architect if Tenant selects them. All Construction Drawings shall comply with the drawing format and specifications reasonably determined by Landlord, and shall be subject to Landlord’s reasonable approval. Tenant and Architect shall verify, in the field, the dimensions and conditions as shown on the relevant portions of the Base Building plans, and Tenant and Architect shall be solely responsible for the same, and Landlord shall have no responsibility in connection therewith. Landlord’s review of the Construction Drawings as set forth in this Section 3, shall be for its sole purpose and shall not imply Landlord’s review of the same, or obligate Landlord to review the same, for quality, design, Code compliance or other like matters. Accordingly, notwithstanding that any Construction Drawings are reviewed by Landlord or its space planner, architect, engineers and consultants, and notwithstanding any advice or assistance which may be rendered to Tenant by Landlord or Landlord’s space planner, architect, engineers, and consultants, Landlord shall have no liability whatsoever in connection therewith and shall not be responsible for any omissions or errors contained in the Construction Drawings, and Tenant’s waiver and indemnity set forth in the Lease, as amended, shall specifically apply to the Construction Drawings.
Construction Drawings After approving the Additional Programming Information, Landlord shall cause the Architect and the Engineers to prepare and deliver to Tenant Construction Drawings that conform to the approved Space Plan and the approved Additional Programming Information. Such preparation and delivery shall occur within 15 business days after the later of Landlord’s approval of the Additional Programming Information or the mutual execution and delivery of this Agreement. Tenant shall approve or disapprove the Construction Drawings by notice to Landlord. If Tenant disapproves the Construction Drawings, Tenant’s notice of disapproval shall specify any revisions Tenant desires in the Construction Drawings. After receiving such notice of disapproval, Landlord shall cause the Architect and/or the Engineers to revise the Construction Drawings, taking into account the reasons for Tenant’s disapproval (provided, however, that Landlord shall not be required to cause the Architect or the Engineers to make any revision to the Construction Drawings that is inconsistent with the Landlord Requirements or that Landlord otherwise reasonably disapproves), and resubmit the Construction Drawings to Tenant for its approval. Such revision and resubmission shall occur within five (5) business days after the later of Landlord’s receipt of Tenant’s notice of disapproval or the mutual execution and delivery of this Agreement if such revision is not material, and within such longer period of time as may be reasonably necessary (but not more than 15 business days after the later of such receipt or such mutual execution and delivery) if such revision is material. Such procedure shall be repeated as necessary until Tenant has approved the Construction Drawings. The Construction Drawings approved by Landlord and Tenant are referred to in this Work Letter as the “Approved Construction Drawings”.
Initial Construction Landlord shall fully construct the base Building in accordance with the preliminary base building plans, including, without limitation, floor plans, elevations and site plan(s) (collectively, the "PBBP") and Base Building Outline Specifications attached hereto as Exhibits B-1 and B-2, respectively (all of such work being collectively referred to as the "Landlord's Work"). In the event of differences between the PBBP or the Landlord's Plans (as hereinafter defined) and the Base Building Outline Specifications, the Base Building Outline Specifications shall govern and control until the Landlord's Plans (as hereinafter defined) are prepared. A complete set of final base Building plans and construction drawings and specifications, such drawings and specifications to include a detail schedule of core base Building finish items such as, but not limited to, carpets, doors, hardware, ceiling grids/tiles, lavatory fixtures, light fixtures, window blinds, lobby finishes and paint/wall coverings (collectively, the "Landlord's Plans") shall be prepared by Landlord, at its sole cost and expense. Landlord and Tenant agree to work together with Landlord's architect, Symmes Maini and McKex Xxxociates, Inc. in order to achieve a design that meets the standard set forth below. Furthermore, Landlord agrees to use good faith and diligent efforts to deliver the Landlord's Plans to Tenant on or before May 1, 2000. Upon receipt, Tenant shall have seven (7) business days to comment upon the Landlord's Plans. Landlord and Tenant shall use reasonable efforts to reach agreement on the Landlord's Plans as soon thereafter as possible. In reaching agreement, Landlord and Tenant shall each approve portions of the Landlord's Plans that are in acceptable form and shall note their respective objections to the portions that are unacceptable to each of them so as to enable Landlord to continue construction and order materials in a timely manner. In the event that Landlord's Plans conform with the PBBP, but Tenant does not approve the Landlord's Plans within seven (7) business days of receipt thereof from Landlord, then the Outside Delivery Date (as hereinafter defined) shall be extended for a number of days equal to the number of Tenant Plan Delay Days, as such term is hereinafter defined. The number of Tenant Plan Delay Days are defined as and shall be calculated by determining the actual number of days as certified by Landlord and its architect that the Term Commencement Date was delayed by such Tenant's failure to approve the Landlord's Plans within the required seven (7) business days. Landlord agrees to provide Tenant with written notice of such determination, such notice to include reasonable detail describing the cause of the delay and the number of Tenant Plan Delay Days as certified by Landlord and its architect. If Tenant and Tenant's Architect (as hereinafter defined)
Space Plan Tenant or Tenant’s Architect shall prepare a proposed space plan for the Tenant Improvements in the Premises which shall include a layout and designation of all partitioning, intended use for such space and equipment to be contained therein (the “Space Plan”) and shall deliver the proposed Space Plan to Landlord with a request for Landlord’s approval. Landlord shall approve or disapprove the Space Plan by written notice given to Tenant within ten (10) Business Days after receipt of the Space Plan. Landlord shall not unreasonably withhold its approval of the Space Plan, provided that, without limiting the generality of the foregoing, Landlord shall be entitled to withhold its consent to the Space Plan if, in Landlord’s good faith judgment, any one or more of the following conditions exist: (a) the proposed Tenant Improvements will adversely affect the exterior appearance of the Building; (b) the proposed Tenant Improvements may impair the structural strength of the Building, affect any of the Base Building Systems or adversely affect the value of the Building; or (c) the proposed Tenant Improvement Work would trigger the necessity under Applicable Laws or otherwise for work to be performed outside the Premises. If Tenant’s proposed interior partitioning or other aspects of the Tenant Improvement Work will, in Landlord’s good faith judgment, require changes or alterations in the Base Building Systems located outside of the Premises, and Landlord approves such changes or alterations, such changes or alterations shall be made at Tenant’s expense. If Landlord disapproves the Space Plan, Landlord shall return the Space Plan to Tenant with a statement of Landlord’s reasons for disapproval, or specifying any required corrections and/or revisions. Landlord shall approve or disapprove of any revisions to the Space Plan by written notice given to Tenant within five (5) Business Days after receipt of such revisions. This procedure shall be repeated until Landlord approves the Space Plan (as so approved, the “Approved Space Plan”).
Neutral Construction The parties to this Agreement agree that this Agreement was negotiated fairly between them at arm's length and that the final terms of this Agreement are the product of the parties' negotiations. Each party represents and warrants that it has sought and received legal counsel of its own choosing with regard to the contents of this Agreement and the rights and obligations affected hereby. The parties agree that this Agreement shall be deemed to have been jointly and equally drafting by them, and that the provisions of this Agreement therefore should not be construed against a party or parties on the grounds that such party or parties drafted or was more responsible for the drafting of any such provision(s).
Architect 4.1.1 The Architect is the person lawfully licensed to practice architecture or an entity lawfully practicing architecture identified as such in the Agreement and is referred to throughout the Contract Documents as if singular in number. The term "
Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shal] submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the genera] conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over- Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (1), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease. 4.2.2
Construction, Etc Each covenant contained herein shall be construed (absent express provision to the contrary) as being independent of each other covenant contained herein, so that compliance with any one covenant shall not (absent such an express contrary provision) be deemed to excuse compliance with any other covenant. Where any provision herein refers to action to be taken by any Person, or which such Person is prohibited from taking, such provision shall be applicable whether such action is taken directly or indirectly by such Person. For the avoidance of doubt, all Schedules and Exhibits attached to this Agreement shall be deemed to be a part hereof.
Construction Budget Administrative Agent shall have received each of the Construction Budget in form and substance reasonably satisfactory to Administrative Agent (in consultation with the Independent Engineer).
Plans and Specifications Tenant shall be solely responsible for the preparation of the final architectural, electrical and mechanical construction drawings, plans and specifications (called “plans”) necessary for Tenant to construct the Premises for Tenant’s occupancy, which plans shall be subject to approval by Landlord’s architect and engineers and shall comply with their reasonable requirements to avoid aesthetic or other conflicts with the design and function of the balance of the Building. Landlord’s approval is solely given for the benefit of Landlord, and neither Tenant nor any third party shall have the right to rely upon Landlord’s approval of Tenant’s plans for any purpose whatsoever other than that Landlord does not object thereto under this Lease. Landlord’s architects and engineers shall respond (with approval or disapproval) to any plan submission by Tenant within 8 business days after Landlord’s receipt thereof. If Landlord fails to respond to any such submission within such 8 business day period, which failure continues for more than 2 business days after Tenant gives Landlord a written notice (the “Deemed Approved Notice”) advising Landlord that such plan submission shall be deemed approved within 2 business days of Landlord’s receipt of the Deemed Approved Notice, then such plan submission shall be deemed approved hereunder. The Deemed Approved Notice shall, in order to be effective, contain on the first page thereof, in a font at least twice as large as the font of any other text contained in such notice, a legend substantially as follows: “FAILURE TO RESPOND TO THIS NOTICE WITHIN TWO (2) BUSINESS DAYS AFTER RECEIPT HEREOF SHALL CONSTITUTE LANDLORD’S APPROVAL OF SUBMITTED PLANS.” In the event Landlord’s architect’s or engineers’ approval of Tenant’s plans is withheld or conditioned, Landlord shall send prompt written notification thereof to Tenant and include a reasonably detailed statement identifying the reasons for such refusal or condition, and Tenant shall promptly have the plans revised by its architect to incorporate all reasonable objections and conditions presented by Landlord and shall resubmit such plans to Landlord. Landlord’s architects and engineers shall respond (with approval or disapproval) to any plan re-submission by Tenant within 8 business days after Landlord’s receipt thereof. Such process shall be followed until the plans shall have been approved by Landlord’s architect and engineers without unreasonable objection or condition. Without limiting the foregoing, Tenant shall be responsible for all elements of the design of Tenant’s plans (including, without limitation, compliance with law, functionality of design, the structural integrity of the design, the configuration of the Premises and the placement of Tenant’s furniture, appliances and equipment), and Landlord’s approval of Tenant’s plans shall in no event relieve Tenant of the responsibility for such design. Tenant agrees it shall be solely responsible for the timely preparation and submission of all such plans and for all elements of the design of such plans and for all costs related thereto. (The word “architect” as used in this Section 3.2 shall include an interior designer or space planner.) Tenant shall reimburse Landlord Landlord’s reasonable out-of-pocket expense incurred in connection with the review of Tenant’s plans.
