Choice of Law clauses for TIPS Members If the vendor is awarded a contract with TIPS under this solicitation, the vendor agrees to make any Choice of Law clauses in any contract or agreement entered into between the awarded vendor and with a TIPS member entity to read as follows: "Choice of law shall be the laws of the state where the customer resides" or words to that effect.
STANDARD CLAUSES FOR NYS CONTRACTS The parties to the attached contract, license, lease, amendment or other agreement of any kind (hereinafter, "the contract" or "this contract") agree to be bound by the following clauses which are hereby made a part of the contract (the word "Contractor" herein refers to any party other than the State, whether a contractor, licenser, licensee, lessor, lessee or any other party):
Priority of agreements, clauses and schedules i This Agreement, and all other agreements and documents forming part of or referred to in this agreement are to be taken as mutually explanatory and, unless otherwise expressly provided elsewhere in this Agreement, the priority of this Agreement and other documents and agreements forming part hereof or referred to herein shall, in the event of any conflict between them, be in the following order:
(a) this Agreement; and
(b) The Bid/Tender Document along with all the corrigendum issued.
(c) all other agreements and documents forming part hereof or referred to herein;
Terms of AAU; Certain Definitions; Construction Each AAU will relate to an Offering, and will identify: (i) the securities to be offered in the Offering (the “Securities”), their principal terms, the issuer or issuers (each, an “Issuer”) and any guarantor (each, a “Guarantor”) thereof, and, if different from the Issuer, the seller or sellers (each, a “Seller”) of the Securities, (ii) the underwriting agreement, purchase agreement, standby underwriting agreement, distribution agreement, or similar agreement (as identified in such AAU and as amended or supplemented, including a terms agreement or pricing agreement pursuant to any of the foregoing, collectively, the “Underwriting Agreement”) providing for the purchase, on a several and not joint basis, of the Securities by the several underwriters, initial purchasers, or others acting in a similar capacity (the “Underwriters”) on whose behalf the Manager (as defined below) executes the Underwriting Agreement, and whether such agreement provides for: (x) an option to purchase Additional Securities (as defined below) to cover sales of shares in excess of the number of Firm Securities (as defined below), or (y) an offering in multiple jurisdictions or markets involving two or more syndicates (an “International Offering”), each of which will offer and sell Securities subject to such restrictions as may be specified in any Intersyndicate Agreement (as defined below) referred to in such AAU, (iii) the price at which the Securities are to be purchased by the several Underwriters from any Issuer or Seller thereof (the “Purchase Price”), (iv) the offering terms, including, if applicable, the price or prices at which the Securities initially will be offered by the Underwriters (the “Offering Price”), any selling concession to dealers (the “Selling Concession”), reallowance (the “Reallowance”), management fee, global coordinators’ fee, praecipium, or other similar fees, discounts, or commissions (collectively, the “Fees and Commissions”) with respect to the Securities, and (v) other principal terms of the Offering, which may include, without limitation: (A) the proposed or actual pricing date (“Pricing Date”) and settlement date (the “Settlement Date”), (B) any contractual restrictions on the offer and sale of the Securities pursuant to the Underwriting Agreement, Intersyndicate Agreement, or otherwise, (C) any co-managers for such Offering (the “Co-Managers”), (D) your proposed participation in the Offering, and (E) any trustee, fiscal agent, or similar agent (the “Trustee”) for the indenture, trust agreement, fiscal agency agreement, or similar agreement (the “Indenture”) under which such Securities will be issued.
Standard of Care; Uncontrollable Events; Limitation of Liability SMC shall use reasonable professional diligence to ensure the accuracy of all services performed under this Agreement, but shall not be liable to the Company for any action taken or omitted by SMC in the absence of bad faith, willful misfeasance, negligence or reckless disregard by it of its obligations and duties. The duties of SMC shall be confined to those expressly set forth herein, and no implied duties are assumed by or may be asserted against SMC hereunder. SMC shall maintain adequate and reliable computer and other equipment necessary or appropriate to carry out its obligations under this Agreement. Upon the Company's reasonable request, SMC shall provide supplemental information concerning the aspects of its disaster recovery and business continuity plan that are relevant to the services provided hereunder. Notwithstanding the foregoing or any other provision of this Agreement, SMC assumes no responsibility hereunder, and shall not be liable for, any damage, loss of data, delay or any other loss whatsoever caused by events beyond its reasonable control. Events beyond SMC's reasonable control include, without limitation, force majeure events. Force majeure events include natural disasters, actions or decrees of governmental bodies, and communication lines failures that are not the fault of either party. In the event of force majeure, computer or other equipment failures or other events beyond its reasonable control, SMC shall follow applicable procedures in its disaster recovery and business continuity plan and use all commercially reasonable efforts to minimize any service interruption. SMC shall provide the Company, at such times as the Company may reasonably require, copies of reports rendered by independent public accountants on the internal controls and procedures of SMC relating to the services provided by SMC under this Agreement. Notwithstanding anything in this Agreement to the contrary, in no event shall SMC, its affiliates or any of its or their directors, officers, employees, agents or subcontractors be liable for exemplary, punitive, special, incidental, indirect or consequential damages, or lost profits, each of which is hereby excluded by agreement of the parties regardless of whether such damages were foreseeable or whether either party or any entity has been advised of the possibility of such damages.
WAIVER CLAUSE The parties acknowledge that during negotiations which resulted in this Agreement each had the unlimited right and opportunity to make demands and proposals with respect to any subject or matter not removed by law from the area of collective bargaining, and that the understandings and agreements arrived at by the parties after the exercise of that right and opportunity are set forth in this Agreement. Therefore, the Board and the Union for the life of this Agreement each voluntarily and unqualifiedly waives the right, and agrees that the other shall not be obliged to bargain collectively with respect to any subject or matter not specifically referred to or covered in this Agreement, unless mutually agreed, even though such subject or matter may not have been within the knowledge or contemplation of either or both parties at the time that they negotiated or signed this Agreement.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Early Construction of Base Case Facilities Developer may request Connecting Transmission Owner to construct, and Connecting Transmission Owner shall construct, subject to a binding cost allocation agreement reached in accordance with Attachment S to the ISO OATT, including Section 25.8.7 thereof, using Reasonable Efforts to accommodate Developer’s In-Service Date, all or any portion of any System Upgrade Facilities or System Deliverability Upgrades required for Developer to be interconnected to the New York State Transmission System which are included in the Base Case of the Class Year Study for the Developer, and which also are required to be constructed for another Developer, but where such construction is not scheduled to be completed in time to achieve Developer’s In-Service Date.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
