Supply of Services 7.1 Supplier shall provide the Services to Purchaser in accordance with the Order in all material respects using reasonable care and skill.
7.2 Supplier shall use reasonable endeavours to meet any performance dates for the Services specified in the Order but any dates shall be estimates only and time shall not be of the essence for the performance of the Services.
7.3 Supplier shall have the right to make any changes to the Services which are necessary to comply with any applicable law or safety requirements or which do not materially affect the nature or quality of the Services.
7.4 Purchaser shall: (a) ensure that the terms of Order are complete and (if submitted by Purchaser) the service specification are complete and accurate; (b) co-operate with Supplier in all matters relating to the Services; (c) provide Supplier, its employees, agents, consultants and subcontractors with access to Purchaser’s premises, machinery and other facilities as reasonably required by Supplier to provide the Services; and (d) provide Supplier with such information and materials as Supplier may reasonably require to supply the Services, and ensure that such information is accurate in all material respects.
7.5 If Supplier’s performance of any of its obligations in respect of the Services is prevented or delayed by an any act or omission by Purchaser or failure by Purchaser to performs its obligations (“Purchaser Default”) Supplier shall without limiting its other rights or remedies have the right to suspend performance of the Services until Purchaser remedied Purchaser Default and relieves Supplier from its obligations to the extent the Customer Default prevents or delays Supplier’s performance. Purchaser shall indemnify Supplier against all liabilities costs, losses and expenses which Supplier may incur by reason of Purchaser Default.
7.6 Where the Services consist of any experimental or developmental work, the results supplied or recommendations made under the Services are given in good faith within the limitations of the data available, but no warranty, expressed or implied, is given as to the ability of Supplier to achieve a specific outcome, nor the accuracy of results obtained.
7.7 Any claims by Purchaser which is based on defect in the Services shall be notified to Supplier within twenty-one (21) days of the services being performed and promptly after discovery of defect or failure. The sole and exclusive remedy of Purchaser for such defect hereunder shall be the re-performance or re- fund, at Supplier’s option, of any defective or non-conforming Services.
Quality of Services (a) The Consultant shall be responsible for the professional quality, technical accuracy, and the coordination of all designs, drawings, specifications, and other services furnished pursuant to this Agreement.
(b) To that end, the Consultant shall correct or shall revise, without additional compensation, any errors or omissions in its work product or shall make such revisions as are necessary as the result of the failure of the Consultant to provide an accurate, more efficient, and properly constructable product in its designs, drawings, specifications, or other services.
(c) The County's review/approval/acceptance of or payment for the services required by this Agreement shall NOT be construed to operate as a waiver of any rights or of any cause of action arising out of the performance of this Agreement. Additionally, the Consultant shall be and remain liable to the County in accordance with applicable law for all damages to the County caused by the Consultant's negligent performance of any of the services furnished under this Agreement.
(d) The rights and remedies of the County provided for under this Agreement are in addition to any other rights and remedies otherwise provided by law.
Quality of Service Contractor shall perform its services with care, skill, and diligence, in accordance with the applicable professional standards currently recognized by such profession, and shall be responsible for the professional quality, technical accuracy, completeness, and coordination of all reports, designs, drawings, plans, information, specifications, and/or other items and services furnished under this Agreement. Contractor shall, without additional compensation, correct or revise any errors or deficiencies immediately upon discovery in its reports, drawings, specifications, designs, and/or other related items or services.
COMMERCIAL REUSE OF SERVICES The member or user herein agrees not to replicate, duplicate, copy, trade, sell, resell nor exploit for any commercial reason any part, use of, or access to 's sites.
Scope of Services The specific scope of work for each job shall be determined in advance and in writing between TIPS Member, Member’s design professionals and Vendor. It is permitted for the TIPS Member to provide a general scope description, but the awarded vendor should provide a written scope of work, and if applicable, according to the TIPS Member’s design Professional as part of the proposal. Once the scope of the job is agreed to, the TIPS Member will issue a PO and/or an Agreement or Contract with the Job Order Contract Proposal referenced or as an attachment along with bond and any other special provisions agreed by the TIPS Member. If special terms and conditions other than those covered within this solicitation and awarded Agreements are required, they will be attached to the PO and/or an Agreement or Contract and shall take precedence over those in this base TIPS Vendor Agreement.
Attachment A, Scope of Services The scope of services is amended as follows:
Compensation for Services Provided As compensation for providing portfolio supervisory services in its capacity as Portfolio Supervisor, evaluation services in its capacity as Evaluator, and for providing bookkeeping and other administrative services to the Trust of a character described in Section 26(a)(2)(C) of the Investment Company Act of 1940, and to the extent that such services are in addition to, and do not duplicate, the services to be provided hereunder by the Trustee, First Trust Advisors L.P. shall receive, in arrears, against a statement or statements therefor submitted to the Trustee monthly or annually an aggregate annual fee in the per Unit amount set forth in Part II of the Trust Agreement for the Trust, calculated based on the largest number of Units outstanding during the calendar year, except during the initial offering period as determined in Section 4.01 of this Indenture, in which case the fee is calculated based on the largest number of Units outstanding during the period for which the compensation is paid (such annual fee to be pro rated for any calendar year in which First Trust Advisors L.P. provides services described herein during less than the whole of such year). Such fee may exceed the actual cost of providing such services for the Trust, but at no time will the total amount received for such services rendered to unit investment trusts of which the Depositor is the sponsor in any calendar year exceed the aggregate cost to First Trust Advisors L.P. of supplying such services in such year. Such compensation may, from time to time, be adjusted provided that the total adjustment upward does not, at the time of such adjustment, exceed the percentage of the total increase after the date hereof in consumer prices for services as measured by the United States Department of Labor Consumer Price Index entitled "All Services Less Rent of Shelter" or similar index, if such index should no longer be published. The consent or concurrence of any Unit holder hereunder shall not be required for any such adjustment or increase. Such compensation shall be paid by the Trustee, upon receipt of an invoice therefor from First Trust Advisors L.P., which shall constitute the representation by First Trust Advisors L.P. that the bookkeeping and administrative services for which compensation is claimed are properly compensable hereunder and that the aggregate cost incurred by First Trust Advisors L.P. of providing portfolio supervisory, evaluation and bookkeeping and administrative services hereunder was not less than the compensation claimed, upon which representation the Trustee may conclusively rely. Such compensation shall be charged against the Income and/or Capital Accounts in accordance with Section 3.05. If the cash balance in the Income and Capital Accounts shall be insufficient to provide for amounts payable pursuant to this Section 4.03, the Trustee shall have the power to sell (i) Securities from the current list of Securities designated to be sold pursuant to Section 5.02 hereof, or (ii) if no such Securities have been so designated, such Securities as the Trustee may see fit to sell in its own discretion, and to apply the proceeds of any such sale in payment of the amounts payable pursuant to this Section 4.03. Any moneys payable to First Trust Advisors L.P. pursuant to this Section 4.03 shall be secured by a lien on the Trust prior to the interest of Unit holders, but no such lien shall be prior to any lien in favor of the Trustee under the provisions of Section 6.04 herein.
SCOPE OF SERVICES/CASE HANDLING A. Upon execution by GPM, attorneys are retained to provide legal services for the purpose of seeking damages and other relief in the Litigation. Client provides authorization to seek appointment as Lead Plaintiff in the class action, while the Attorneys will seek to be appointed Class Counsel. If this occurs, the Litigation will be prosecuted as a class action.
B. If you obtain access to non-public information during the pendency of the Litigation, you must not engage in transactions in securities.
C. Attorneys are authorized to prosecute the Litigation. The appointed Lead Plaintiffs will monitor, review and participate with counsel in the prosecution of the Litigation. The Attorneys shall consult with the appointed Lead Plaintiffs concerning all major substantive matters related to the Litigation, including, but not limited to, the complaint, dispositive motions and settlement. Because of potential differences of opinion between Clients concerning, among other things, strategy, goals and objectives of the Litigation, the Attorneys shall consult with the appointed Lead Plaintiffs as to the courses of action to pursue. The Client agrees to abide by the decisions of the appointed Lead Plaintiffs, which shall be final and binding on all Clients.
D. GPM is given the authority to opt the Client out of any class action proceeding relating to the claims authorized herein and/or pursue the Client claim individually in a group action, if the Client is not appointed Lead Plaintiff and GPM is not appointed Class Counsel.
E. The Attorneys shall provide sufficient resources, including attorney time and capital for payment of costs and expenses, to vigorously prosecute the Litigation.
F. Any recovery from defendants that the Attorneys are responsible for will be divided among class members based on the recognized loss by each class member as calculated by a damage allocation plan which will be prepared by a financial expert or consultant, provided to the appointed Lead Plaintiffs, be subject to the Court's approval and will account for such factors as size of securities ownership, date of purchase, date of sale and continued holdings, if any. Under the rules governing class action litigation, while the Lead Plaintiffs recover according to the same formula as other class members, the Court may approve, upon application therefore, reimbursement of the Lead Plaintiffs’ reasonable costs and expenses directly related to the representation of the class. Examples are lost wages and travel expenses associated with testifying in the action.
Routing for Operator Services and Directory Assistance Traffic For a Verizon Telecommunications Service dial tone line purchased by CBB for resale pursuant to the Resale Attachment, upon request by CBB, Verizon will establish an arrangement that will permit CBB to route the CBB Customer’s calls for operator and directory assistance services to a provider of operator and directory assistance services selected by CBB. Verizon will provide this routing arrangement in accordance with, but only to the extent required by, Applicable Law. Verizon will provide this routing arrangement pursuant to an appropriate written request submitted by CBB and a mutually agreed-upon schedule. This routing arrangement will be implemented at CBB's expense, with charges determined on an individual case basis. In addition to charges for initially establishing the routing arrangement, CBB will be responsible for ongoing monthly and/or usage charges for the routing arrangement. CBB shall arrange, at its own expense, the trunking and other facilities required to transport traffic to CBB’s selected provider of operator and directory assistance services.
Subcontracting for the Provision of Services (a) The parties acknowledge that, subject to the provisions of the Enabling Legislation, the HSP may subcontract the provision of some or all of the Services. For the purposes of this Agreement, actions taken or not taken by the subcontractor, and Services provided by the subcontractor, will be deemed actions taken or not taken by the HSP, and Services provided by the HSP.
(b) When entering into a subcontract the HSP agrees that the terms of the subcontract will enable the HSP to meet its obligations under this Agreement. Without limiting the foregoing, the HSP will include a provision that permits the Funder or its authorized representatives, to audit the subcontractor in respect of the subcontract if the Funder or its authorized representatives determines that such an audit would be necessary to confirm that the HSP has complied with the terms of this Agreement.
(c) Nothing contained in this Agreement or a subcontract will create a contractual relationship between any subcontractor or its directors, officers, employees, agents, partners, affiliates or volunteers and the Funder.
(d) When entering into a subcontract, the HSP agrees that the terms of the subcontract will enable the HSP to meet its obligations under the FLSA.
