System and Software Design Development and Integration Sample Clauses

Open Split View

Download

Share

Cite

System and Software Design Development and Integration 

Sample 1

Save

Copy

Related to System and Software Design Development and Integration

• Software Development Software designs, prototypes, and all documentation for the final designs developed under this agreement must be made fully transferable upon direction of NSF. NSF may make the software design, prototype, and documentation for the final design available to competitors for review during any anticipated re-competition of the project.

• Statement of Work The Statement of Work to which Grantee is bound is incorporated into and made a part of this Grant Agreement for all purposes and included as Attachment A.

• Project Design Applicants must design a project that provides access to health services to enable eligible women and men experiencing health needs to secure and maintain safe and accessible quality screening and diagnostic services, comprehensive family planning, and/ or other women’s health services. A. Applicants are encouraged to emphasize the following components in the design of their projects. Projects must: 1. Use a collaborative approach to maximize existing community resources and avoid duplication of effort; 2. Enhance systems and local processes to make it easier for people to transition to, from, and between services; 3. Address barriers to ensure services are accessible to people regardless of setting or location; and 4. Promote improvement and positively impact health and well-being through coordinated service delivery. B. To be effective, services and activities provided or made available as part of the Proposed Project should have policies and procedures in place and include with the application as an attachment that: 1. Delineate the timely provision of services; 2. Deem Client eligibility and service provision as soon as possible and no later than 30 calendar days from initial request; 3. Require staff to assess and prioritize Client needs; 4. Implement with model fidelity to an evidence-based program or based upon best available research; 5. Plan in partnership with the person and are inclusive; 6. Provide in an environment that is most appropriate and based on a person’s preference including reasonable clinic/reception wait times that are not a barrier to care; 7. Provide referral sources for Clients that cannot be served or receive a specific service; 8. Are culturally and linguistically sensitive; 9. Tailor services to a person’s unique strengths and needs; 10. Manage funds to ensure established Clients continuity of care throughout budget year; 11. Continue to provide services to established Clients after allocated funds are expended; 12. Have processes to identify and eliminate possible barriers to care; 13. Do not deny services due to inability to pay; 14. Have appropriate key personnel and required staff to meet the medical and health needs of Clients; 15. Bill services appropriately and timely through TMHP; 16. Effectively communicate and document information related to health care needs with next steps available to Client; 17. Establish outreach and education plan for the community; and 18. Outline successful delivery of direct clinical services to Clients By submitting an Application under this RFA, the Applicant certifies that Applicant has or will have at time of grant award services, policies, or procedures that conform with the requirements in this section as applicable. HHSC, in its sole discretion, may request to review relevant documentation during the project period as necessary to ensure program fidelity.

• Construction Phase Services 3.1.1 – Basic Construction Services

• Design Development Phase 1.3.1 Based on the approved Schematic Design Documents, model(s) and any adjustments to the Program of Requirements, BIM Execution Plan or Amount Available for the Construction Contract authorized by the Owner, the Architect/Engineer shall prepare, for approval by the Owner and review by the Construction Manager, Design Development Documents derived from the model(s) in accordance with Owner’s written requirements to further define and finalize the size and character of the Project in accordance with the BIM Execution Plan, “Facility Design Guidelines” and any additional requirements set forth in Article 15. The Architect/Engineer shall review the Design Development documents as they are being modeled at intervals appropriate to the progress of the Project with the Owner and Construction Manager at the Project site or other location specified by Owner in the State of Texas. The Architect/Engineer shall utilize the model(s) to support the review process during Design Development. The Architect/Engineer shall allow the Construction Manager to utilize the information uploaded into Owner’s PMIS to assist the Construction Manager in fulfilling its responsibilities to the Owner. 1.3.2 As a part of Design Development Phase, Architect/Engineer shall accomplish model coordination, aggregation and “clash detection” to remove conflicts in design between systems, structures and components. Architect/Engineer shall utilize Owner’s PMIS to accomplish model coordination and collaborate with Construction Manager in the resolution of critical clashes identified by the Construction Manager. Architect/Engineer shall demonstrate and provide written assurance to Owner that conflicts/collisions between models have been resolved. 1.3.3 The Architect/Engineer shall review the Estimated Construction Cost prepared by the Construction Manager, and shall provide written comments. 1.3.4 Before proceeding into the Construction Document Phase, the Architect/Engineer shall obtain Owner’s written acceptance of the Design Development documents and approval of the mutually established Amount Available for the Construction Contract and schedule. 1.3.5 The Architect/Engineer shall prepare presentation materials including an animation derived from the model(s) as defined in “Facility Design Guidelines” at completion of Design Development and if so requested shall present same to the Board of Regents at a regular meeting where scheduled within the state. 1.3.6 The Architect/Engineer shall prepare preliminary recommended furniture layouts for all spaces where it is deemed important to substantiate the fulfillment of program space requirements, or to coordinate with specific architectural, mechanical and electrical elements. 1.3.7 Architect/Engineer shall assist the Owner, if requested, with seeking approval of the Project by the Texas Higher Education Coordinating Board (THECB). Such assistance shall include (i) the preparation of a listing of the rooms and square footages in the Project, and (ii) the preparation of project cost information, in accordance with THECB Guidelines. This information shall be provided at the completion of the Design Development Phase when requested by the Owner. The listing of rooms and square footages shall then be updated to reflect any changes occurring during construction and provided to the Owner at Substantial Completion. 1.3.8 At the completion of the Design Development Phase, or such other time as Owner may specify to Architect/Engineer, at Owner’s sole option and discretion, Owner will furnish Architect/Engineer with a Guaranteed Maximum Price proposal prepared by Construction Manager based upon the Design Development documents prepared by the Architect/Engineer and approved by the Owner. The Architect/Engineer shall assist the Owner and endeavor to further and advocate the Owner’s interests in Owner’s communications with the Construction Manager in an effort to develop a Guaranteed Maximum Price proposal acceptable to Owner, in Owner’s sole option and discretion. If the Owner does not accept the Construction Manager’s Guaranteed Maximum Price proposal, the Architect/Engineer shall participate with the Owner and Construction Manager in constructability reviews and shall revise the documents as necessary in order to reach an agreement. If the Construction Manager’s Guaranteed Maximum Price proposal exceeds the Schematic Design Phase Estimated Construction Cost prepared by, or otherwise accepted by the Construction Manager due to an increase in the scope of the Project caused by further development of the design documents by the Architect/Engineer to the extent that such could not be reasonably inferred by the Construction Manager from the Schematic Design documents, and Owner directs Architect/Engineer to revise the documents, the Architect/Engineer shall revise the documents at its own expense so that the Guaranteed Maximum Price proposal for constructing the Project shall not exceed the Owner’s Amount Available for the Construction Contract and any previously approved Estimated Construction Costs. If it is determined to be in the Owner’s best interest, instead of requiring the Architect/Engineer to revise the Drawings and Specifications, the Owner reserves the right to accept a Guaranteed Maximum Price proposal that exceeds the stipulated Amount Available for the Construction Contract. The Architect/Engineer shall analyze the final Guaranteed Maximum Price proposal document, together with its supporting assumptions, clarifications, and contingencies, and shall submit a detailed written analysis of the document to the Owner. Such analysis shall include, without limitation, reference to and explanation of any inaccurate or improper assumptions and clarifications. The A/E will not be required to make revisions to the documents at its own expense under the provisions of this paragraph if the Owner’s rejection of the Guaranteed Maximum Price proposal is not due to a failure of the A/E to provide the services otherwise required herein. 1.3.9 After the Guaranteed Maximum Price has been accepted, the Architect/Engineer shall incorporate necessary revisions into the Design Development documents. The A/E will not be required to make revisions to the documents at its own expense under the provisions of this paragraph if the revisions are required as the result of inaccurate assumptions and clarifications made in the development of the Guaranteed Maximum Price proposal that are not due to a failure of the A/E to provide the services otherwise required herein.

• Scope of Work For the 2022/2023 Grant Period, the Provider will maintain a victim services program that will be available to provide direct services to victims of crime who are identified by the Provider or are presented to the Provider, as specified in the Provider’s 2022/2023 Grant Application as approved by the OAG and incorporated herein by reference.

• Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.

• Equipment and Software To use the Mobile Remote Deposit Services, you must obtain and maintain at your expense, compatible equipment and software that we may specify from time to time.

• Network Interconnection Architecture Each Party will plan, design, construct and maintain the facilities within their respective systems as are necessary and proper for the provision of traffic covered by this Agreement. These facilities include but are not limited to, a sufficient number of trunks to the point of interconnection with the tandem company, and sufficient interoffice and interexchange facilities and trunks between its own central offices to adequately handle traffic between all central offices within the service areas at a P.01 grade of service or better. The provisioning and engineering of such services and facilities will comply with generally accepted industry methods and practices, and will observe the rules and regulations of the lawfully established tariffs applicable to the services provided.

• Start-Up and Synchronization Consistent with the mutually acceptable procedures of the Developer and Connecting Transmission Owner, the Developer is responsible for the proper synchronization of the Large Generating Facility to the New York State Transmission System in accordance with NYISO and Connecting Transmission Owner procedures and requirements.