Construction of the Improvements Once development of the Property has commenced, the construction of the Improvements shall be pursued with due diligence and continuity, in a good and workmanlike manner, and in accordance with sound building and engineering practices, all applicable governmental requirements, and the Development Plan. Borrower shall not permit cessation of work for a period in excess of thirty (30) days during any period of time during which development on the Property is scheduled to be performed without the prior written consent of Lender, which may be given or withheld in Lender’s sole discretion, except for delays due to strikes, riots, acts of God, war, unavailability of labor or materials, governmental laws, regulations or restrictions and Borrower shall promptly notify Lender of any such delays; provided, however, that in no event shall work cease for a period in excess of sixty (60) days regardless of the cause. Borrower shall cause all materials supplied for, or intended to be utilized in, the development of any part of the Property, but not affixed to or incorporated into the Property, to be stored on the Property or at such other location as may be approved by Lender in writing, with adequate safeguards, as required by Lender, to prevent loss, theft, damage, or commingling with other materials or projects.
Construction of the Tenant Improvements 3.1 The Leased Premises consists of two existing, contiguous spaces which were previously leased to other tenants. Tenant is taking the Leased Premises in its “as is” condition, subject to modifications as shown on the Plans (as hereafter defined) to be prepared by Tenant (“Tenant Improvements”). The Landlord shall provide all necessary labor and materials and perform all the work required to complete the Tenant Improvements in order to ready the same for Tenant’s occupancy. Tenant’s designated representative for all work pertaining to the Tenant Improvements shall be Xxxx Xxxxxxxx or such other person as is designated in writing by Tenant (“Representative”). The Landlord shall supervise and direct the work on the Tenant Improvements using Landlord’s best skill and attention, and Landlord shall be solely responsible for all construction means, methods, techniques, sequences and procedures and for coordinating all portions of the work on the Tenant Improvements. Landlord warrants to the Tenant that all materials and equipment incorporated in the Tenant Improvements will be new unless otherwise specified, and that all work on the Tenant Improvements will be of good quality, free from known faults and defects, and in substantial conformity with the Plans.
(a) Landlord shall complete the Tenant Improvements in a good and workmanlike manner and in substantial accordance with plans and specifications (“Plans”) to be prepared by Tenant’s architect, CUH2A. The Plans shall be provided to Landlord on or before September 1, 2003 and shall be in sufficient detail to permit Landlord to apply for a building permit for the Tenant Improvements (which Landlord shall promptly do), and to prepare a construction budget for the construction of the Tenant Improvements (“Construction Budget”). In the event Tenant does not deliver the Plans to Landlord by the date set forth above, such failure shall not delay the date for commencement of the rent, which shall be presumed to be the projected Commencement Date set forth in paragraph 2. The Construction Budget shall set forth the lump sum amount payable by Tenant to Landlord for the construction of the Tenant Improvements, which amount shall include Landlord’s standard xxxx-up for general conditions, overhead and profit, which total in the aggregate 20%. The only exception to the lump sum amount shall be the actual fees charged by the Township of South Brunswick for construction permits in connection with the Tenant Improvements, which sums shall be paid by Tenant as set forth hereafter. Landlord shall submit the Construction Budget to Tenant for its approval. Tenant shall give written notice to Landlord within five business days of receipt, as to whether or not the Construction Budget is acceptable. If Tenant does not accept the Construction Budget during such five business day period, then the parties agree to negotiate in good faith to reach an agreement on the Construction Budget. Landlord shall not be obligated to order any equipment or commence work until Tenant has approved the Construction Budget. A complete set of the agreed upon Plans, and the agreed upon Construction Budget, shall be initialed by and distributed to Landlord and Tenant.
(b) Neither the Construction Budget nor the Plans shall be changed or altered in any way except by change order approved in writing by Landlord and Tenant (“Change Order”). All Change Orders shall be valid and binding upon Landlord and Tenant only if authorized by written Change Order signed by Landlord and Tenant’s Representative prior to commencement of the work on the Tenant Improvements reflected thereby. The cost or credit to the Tenant due to any Change Order shall be determined per the terms of such Change Order. In the event the Change Order increases the cost set forth in the Construction Budget, then Landlord shall submit an invoice to Tenant and Tenant shall pay the invoice upon completion of work or upon the ordering of any equipment, whichever is applicable. The Landlord shall have the right to substitute for the materials and equipment required by the Plans, materials and equipment of equal quality and standard, provided said substitutions conform with applicable building codes and are the subject of a Change Order. Each and every Change Order shall state whether the change will entail a delay in the date of Substantial Completion. Any Change Order requested by Tenant which results in a delay to the date of Substantial Completion shall not delay the date for the commencement of the payment of rent.
(a) The Landlord may secure and advance payment for the construction permits and for all other permits and governmental fees, licenses and inspections necessary for the proper execution and completion of the Tenant Improvements. Tenant shall pay such amounts to Landlord not later than 10 business days after receipt of an invoice therefore Landlord shall not, however, be responsible for securing any environmental or operating permits or certifications which are required in order for Tenant to actually conduct its business.
(b) Tenant shall be responsible for providing Landlord with, and bearing the cost of sufficient copies of the Plans, and sufficient copies of any revisions made to the Plans, in order to obtain the permits and efficiently manage the construction of the Tenant Improvements. In the event any Change Orders are required during construction, Tenant shall be responsible for all costs related to the preparation and reproduction of plans therefore, unless the Change Order was solely initiated by Landlord, in which case Landlord shall be responsible for such costs. After construction is complete, Tenant shall be responsible for all costs related to the reproduction of “as built” Plans. In all instances where Plans are required, Tenant shall provide Landlord with a reproducible set. Landlord will also be provided with a current plot file containing the Plans at no cost to Landlord. Tenant agrees to have its Architect execute Exhibit “A” affirming Landlord’s right to the Plans.
(a) Tenant shall pay Landlord directly for the construction costs of Tenant Improvements in accordance with the schedule attached hereto as Exhibit “B”. The only exception to Tenant’s responsibility to pay for all construction costs shall be for the work necessary to upgrade the existing HVAC reheat system currently in the space previously occupied by Biomira, Inc. (currently known as 0000 Xxxxxxxx Xxxxxxxxx), which cost is estimated to be $150,000 and will he divided equally between the parties. In the event Tenant fails to pay to Landlord any sum set forth on Exhibit “B” when it is due, Landlord shall not be obligated to commence or continue work on the Tenant Improvements. Such failure to pay shall constitute a default under this Lease, but shall not delay the Commencement Date of this Lease, which shall be presumed to be the projected Commencement Date set forth in paragraph 2; or any of Tenant’s obligations hereunder including, without limitation, Tenant’s obligation to pay all Rent. In the event that Tenant fails to pay to Landlord, upon Substantial Completion of the Tenant Improvements, a sum equal to the remaining balance then due, such failure shall constitute a default under this Lease; and Tenant shall not be permitted to occupy the Leased Premises; and Tenant shall commence payment of all Rent; and Landlord shall be entitled to all rights and remedies available hereunder, at law or in equity, which rights shall be cumulative. All sums so owing to Landlord shall constitute Additional Rent and shall be subject to the imposition of late charges as provided in this Lease.
(b) Apart from extensions of time for delays and extensions of the date for the payment of rent, no payment or allowance of any kind shall be claimed by Tenant, or made to the Landlord as compensation for damages on account of any delay from any cause in the completion of the Tenant Improvements, whether such delay be avoidable or unavoidable, anything in this Agreement inconsistent herewith or to the contrary notwithstanding.
3.5 Tenant shall be responsible for the design and installation of its own phone, data and communication systems which systems shall be installed in a manner not to interfere with Landlord’s construction efforts. During construction of Tenant Improvements, a representative of Tenant shall inspect the site no less frequently than once a week and verify and agree that the work in progress has been completed in a manner acceptable to Tenant.
3.6 The Tenant Improvements shall be commenced upon issuance of the building permit by governmental entities having jurisdiction therefor and, subject to authorized adjustments, Substantial Completion is estimated to be achieved on or about January 15, 2004. As used herein the term “Substantial Completion” shall mean that the Leased Premises have been built and completed in substantial conformity with the Plans, and a temporary or permanent certificate of occupancy or a temporary or permanent certificate of acceptance (“CO/CA”) has been issued permitting Tenant to use and occupy the Leased Premises, even though minor details, adjustments or punch list items which shall not materially impair Tenant’s use and enjoyment of the Leased Premises may not have been finally completed, but which work Landlord agrees shall be diligently pursued to final completion. Tenant shall allow Landlord and its contractors to enter the Leased Premises during normal working hours after issuance of the CO/CA to complete remaining minor work or punch list items, provided Landlord gives advance notice and makes reasonable efforts not to interfere with Tenant’s operations. It is agreed that for the purpose of this Lease, wherever and whenever the term Substantial Completion is used, it shall not include items of maintenance, service, punch list, or guarantee. If the date of Substantial Completion occurs on a day other than the first day of a month, rent from such day until the first day of the following month shall be prorated (at a rate of 1/30th of the monthly rent per day). During said period of partial monthly occupancy, all other terms and conditions of this Lease shall apply.
CONSTRUCTION OF THE PROJECT/ APARTMENT The Allottee has seen the proposed layout plan, specifications, amenities and facilities of the [Apartment/Plot] and accepted the floor plan, payment plan and the specifications, amenities and facilities [annexed along with this Agreement] which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the said layout plans, floor plans and specifications, amenities and facilities. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent Authorities and shall also strictly abide by the bye-laws, FAR and density norms and provisions prescribed by the [Please insert the relevant State laws]and shall not have an option to make any variation /alteration / modification in such plans, other than in the manner provided under the Act, and breach of this term by the Promoter shall constitute a material breach of the Agreement.
Project Site The “Project Site” is the place where the Work is being carried on.
Additional Improvements Common Area Operating Expenses shall not include Real Property Taxes specified in the tax assessor's records and work sheets as being caused by additional improvements placed upon the Industrial Center by other lessees or by Lessor for the exclusive enjoyment of such other lessees. Notwithstanding Paragraph 10.1 hereof, Lessee shall, however, pay to Lessor at the time Common Area Operating Expenses are payable under Paragraph 4.2, the entirety of any increase in Real Property Taxes if assessed solely by reason of Alterations, Trade Fixtures or Utility Installations placed upon the Premises by Lessee or at Lessee's request.
Construction of Tenant Improvements Tenant shall install the Tenant Improvements (as described in Paragraph 2(a) below) in accordance with the terms and conditions of this Work Letter. The quantities, character and manner of installation of all of the work related to the Tenant Improvements shall be subject to the limitations imposed by any applicable governmental regulations, laws, ordinances, codes and rules. Notwithstanding the foregoing, Landlord may at Landlord’s sole election itself (with Landlord’s contractor) construct the portion of the Tenant Improvements that consist of the restrooms and related improvements that will service Building 2 (the “Restroom Improvements”), at Tenant’s cost up to a maximum amount of $322,764 (subject to Section 9(b) below), provided that (a) Landlord notifies Tenant in writing of such election prior to Tenant’s commencement of construction of the Tenant Improvements, and (b) Landlord shall use commercially reasonable efforts to not unreasonably interfere with or delay Tenant’s installation of the Tenant Improvements. If a certificate of occupancy or equivalent permit sign-off for the Premises is delayed beyond the Building 2 Scheduled Commencement Date solely as a result of Landlord’s failure to substantially complete the Restroom Improvements prior to such date, which failure does not result from Tenant Delays (as defined below) or Force Majeure, then the Building 2 Commencement Date shall be extended day for day by the number of days after the Building 2 Scheduled Commencement Date until the issuance of a certificate of occupancy or equivalent permit sign-off (but in no event shall the Building 2 Commencement Date be delayed beyond the date Tenant commences business in the Premises), provided, however, that Tenant delivers written notice to Landlord at such time as Tenant becomes aware that Landlord is in danger of causing such delay. “Tenant Delays” shall mean (i) Tenant’s delay in submittal of Tenant’s Plans and/or responses to Landlord’s comments to Tenant’s Plans beyond the time periods provided in this Work Letter, (ii) Tenant’s delay in any submittals for permits or other governmental approvals with respect to the Tenant Improvements (including without limitation the Restroom Improvements), (iii) changes in Tenant’s Plans as they relate to the Restroom Improvements after they have been submitted to governmental authorities for permits, (iv) delay in obtaining materials for reasons outside Landlord’s reasonable control, and (v) Tenant’s failure to provide reasonable access to the Premises to Landlord’s contractors to install the Restroom Improvements, or unreasonable interference with such installation by Tenant or its contractors or agents.
Building Renovations It is specifically understood and agreed that Landlord has made no representation or warranty to Tenant and has no obligation and has made no promises to alter, remodel, improve, renovate, repair or decorate the Premises, Building, or any part thereof and that no representations respecting the condition of the Premises or the Building have been made by Landlord to Tenant except as specifically set forth herein or in the Work Letter Agreement. However, Tenant hereby acknowledges that Landlord is currently renovating or may during the Lease Term renovate, improve, alter, or modify (collectively, the "Renovations") the Project, the Building and/or the Premises including without limitation the parking structure, common areas, systems and equipment, roof, and structural portions of the same, which Renovations may include, without limitation, (i) installing sprinklers in the Building common areas and tenant spaces, (ii) modifying the common areas and tenant spaces to comply with applicable laws and regulations, including regulations relating to the physically disabled, seismic conditions, and building safety and security, and (iii) installing new floor covering, lighting, and wall coverings in the Building common areas, and in connection with any Renovations, Landlord may, among other things, erect scaffolding or other necessary structures in the Building, limit or eliminate access to portions of the Project, including portions of the common areas, or perform work in the Building, which work may create noise, dust or leave debris in the Building. Tenant hereby agrees that such Renovations and Landlord's actions in connection with such Renovations shall in no way constitute a constructive eviction of Tenant nor entitle Tenant to any abatement of Rent. Landlord shall have no responsibility or for any reason be liable to Tenant for any direct or indirect injury to or interference with Tenant's business arising from the Renovations, nor shall Tenant be entitled to any compensation or damages from Landlord for loss of the use of the whole or any part of the Premises or of Tenant's personal property or improvements resulting from the Renovations or Landlord's actions in connection with such Renovations, or for any inconvenience or annoyance occasioned by such Renovations or Landlord's actions.
Common Areas - Changes Lessor shall have the right, in Lessor's sole discretion, from time to time:
(a) To make changes to the Common Areas, including, without limitation, changes in the location, size, shape and number of driveways, entrances, parking spaces, parking areas, loading and unloading areas, ingress, egress, direction of traffic, landscaped areas, walkways and utility raceways;
(b) To close temporarily any of the Common Areas for maintenance purposes so long as reasonable access to the Premises remains available;
(c) To designate other land outside the boundaries of the Industrial Center to be a part of the Common Areas;
(d) To add additional buildings and improvements to the Common Areas;
(e) To use the Common Areas while engaged in making additional improvements, repairs or alterations to the Industrial Center, or any portion thereof; and
(f) To do and perform such other acts and make such other changes in, to or with respect to the Common Areas and Industrial Center as Lessor may, in the exercise of sound business judgment, deem to be appropriate.
Leasehold Improvements a. Tenant accepts the Premises “AS IS” without any agreements, representations, understandings or obligations on the part of Landlord to perform any alterations, repairs or improvements except as expressly set forth in this Lease. ADDITIONALLY, EXCEPT AS EXPRESSLY SET FORTH IN THIS LEASE, LANDLORD MAKES NO WARRANTIES, EXPRESS OR IMPLIED, AND ALL IMPLIED WARRANTIES WITH RESPECT TO THE PREMISES, INCLUDING WITHOUT LIMITATION THOSE OF SUITABILITY AND FITNESS FOR A PARTICULAR PURPOSE, ARE HEREBY EXPRESSLY NEGATED AND WAIVED.
b. Tenant agrees that it will make no exterior or structural alterations or additions to the Premises nor post or attach or affix to the exterior of the Premises, any signs, air conditioners or other objects without memorializing such proposed alterations, attachments, or fixtures in a Tenant work letter (in form acceptable to Landlord) and obtaining Landlord’s prior written consent to same. Notwithstanding the foregoing, Tenant shall have the right to make interior, non-structural alterations to the Premises without Landlord’s consent, so long as such alterations do not (i) affect the structure or electrical, plumbing, or mechanical systems of the Premises; or (ii) decrease the value of the Premises. Tenant shall be responsible for the cost of such alterations or signs. Tenant shall have the right to install its trade fixtures and equipment in, upon and about the Premises; provided, however, that Tenant shall remove the same on or before the expiration of this Lease, and if so requested by Landlord, promptly after any termination of this Lease; and provided, further, that Tenant shall promptly thereafter repair all damage caused to the Premises by reason of such installation or removal.
c. Tenant shall indemnify and hold Landlord harmless from and against all costs (including reasonable attorneys’ fees and costs of suit), losses, liabilities, or causes of action arising out of or relating to any alterations, additions or improvements made by Tenant to the Premises, including, but not limited to, work not completed in a workmanlike manner and any contractor’s, mechanics’ or materialman’s liens asserted in connection therewith. This indemnification obligation shall survive the Term of this Lease.
d. Should any contractor’s, mechanic’s or other liens be filed against any portion of the Premises by reason of Tenant’s acts or omissions or because of a claim against Tenant, Tenant shall cause the same to be canceled or discharged of record by bond or otherwise within thirty (30) days after notice by Landlord. If Tenant shall fail to cancel or discharge said lien or liens, within said thirty (30) day period, Landlord may, at its sole option, cancel or discharge the same and upon Landlord’s demand, Tenant shall promptly reimburse Landlord for all reasonable costs incurred in canceling or discharging such liens, including attorney fees in connection with same.
Tenant Improvements Tenants construction of the Tenant Improvements in the Suite 120 Premises shall be subject to the terms of the Work Letter attached to the Lease as Exhibit C, except that, notwithstanding anything to the contrary contained in the Work Letter:
a. The Tenant Improvements in the Suite 120 Premises shall be constructed pursuant to the space plans attached to this First Amendment as Exhibit B (the “Suite 120 Space Plans”) and the tenant improvement specifications attached to this First Amendment as Exhibit C (the “Suite 120 TI Specifications”), which have been approved by both Landlord and Tenant, and the TI Construction Drawings for the Tenant Improvements for the Suite 120 Premises shall be prepared substantially in accordance with the Suite 120 Space Plans and the Suite 120 TI Specifications (and Landlord may not disapprove any matter in connection therewith that is consistent with the Suite 120 Space Plans and the Suite 120 TI Specifications).
b. The Tenant Improvement Allowance and the Additional Tenant Improvement Allowance provided for in Section 6(b) of the Work Letter shall not apply with respect to the Suite 120 Premises and Landlord shall provide a tenant improvement allowance with respect to the Tenant Improvements in the Suite 120 Premises, as follows:
(i) a “Suite 120 Tenant Improvement Allowance” in the maximum amount of $185.00 per rentable square foot in the Suite 120 Premises, which is included in the Base Rent set forth in the Lease; and
(ii) an “Additional Suite 120 Tenant Improvement Allowance” in the maximum amount of $40.00 per rentable square foot in the Suite 120 Premises, which shall, to the extent used, result in Suite 120 TI Rent as set forth in Section 5(c) below. For the avoidance of doubt, (A) the definition of “TI Allowance” in the Work Letter shall include the Tenant Improvement Allowance, the Additional Tenant Improvement Allowance, the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance, as applicable, and (B) in connection with the Tenant Improvements in the Suite 120 Premises, Landlord shall be entitled to Administrative Rent equal to 1.5% of the “hard” TI Costs incurred in connection with such Tenant Improvements and a fee shall be payable to Tenant’s third party project manager, Xxxxxxxxx XxxXxxx of Xxxxx Xxxx LaSalle, not to exceed 1.5% of the “hard” TI Costs of such Tenant Improvements, which amounts shall be payable out of the TI Fund. Landlord and Tenant acknowledge and agree that the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance, to the extent utilized, must be used toward the cost of Tenant Improvements in the Suite 120 Premises.
c. Pursuant to the terms of the Work Letter (as amended by this First Amendment), Landlord shall, subject to the terms of the Work Letter (as amended by this First Amendment), make available to Tenant the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance. Commencing on the Rent Commencement Date and continuing thereafter on the first day of each month during the Base Term, Tenant shall pay the amount necessary to fully amortize the portion of the Additional Suite 120 Tenant Improvement Allowance actually funded by Landlord, if any, in equal monthly payments with interest at a rate of 7% per annum over the Base Term, which interest shall begin to accrue on the date that Landlord first disburses such Additional Suite 120 Tenant Improvement Allowance or any portion(s) thereof (“Suite 120 TI Rent”). Any outstanding and unamortized Suite 120 TI Rent remaining unpaid as of the expiration or earlier termination of the Lease shall be paid to Landlord in a lump sum at the expiration or earlier termination of this Lease. For the avoidance of doubt, Landlord and Tenant acknowledge and agree that Suite 120 TI Rent, if any, shall not be subject to adjustment pursuant to Section 4(a) of the Lease during the Term.